Fidic Info
Fidic Info
Fidic Info
KEEP IN TOUCH
Login
Basket (0)
Home
o About FIDIC
o
FIDIC Members
Membership Categories
Member Benefits
Membership Brochure
Federation
Executive Committee
FIDIC Committees
FIDIC Presidents
Secretariat
FIDIC History
FIDIC Policies
Business Integrity
FIDIC YPs
ASPAC YP Group
GAMA
ASPAC
Capacity Building
Adjudicators
FIDIC Logo
o
FIDIC Awards
o Bookshop
o
Collections
Additional resources
o
FAQ
o
About Publications
Events list
Training Courses
o
Training Modules
Contracts Modules
Accredited Trainers
Accredited Regional Training
Training Newsletters
o
Conferences
Industry events
o Other Resources
o
Quality
Integrity
o
Sustainability
Sustainable Infrastructure
Decision-support
Calculators
Guidelines
Search
QUESTION
The following query is in relation to a situation which has occurred in the context of the execution of
a Lump Sum contract, regulated by a standard FIDIC (Red Book) terms and conditions. The
Specifications call for "Cast Iron" pipes, while the BOQ calls for "UPVC" pipes. The Contractor and
upon the approval of the Engineer, and without having any instructions to do so, executed the Works
in UPVC. Does this entitle the Employer to request cost saving on this item? And on what basis?
Your response to the above is highly appreciated.
ANSWER
You say that you have a Lump Sum Contract. The FIDIC Construction Contract Book is a
remeasurement contract so the payment provisions must have been changed to provide for the
Lump Sum. The answer to your question will depend on the wording of these Lump Sum provisions.
I regret that FIDIC can only comment on questions which on the interpretation of the FIDIC General
Conditions, so we are unable to answer your question. We fear that this is an indication of what
happens if General Conditions are modified by Special Provisions without due care.
SUBCONTRCATOR'S EXPERIENCE
QUESTION
I would like your advice on the definition of a subcontractor, and of the following tender criteria:
"subcontractors' experience and resources shall not be taken into account in determining the
bidder's compliance with qualifying criteria". In other words, does this mean that if a bidder has
worked as a subcontractor, he is not permitted to add that experience as part of his qualification? I
would like your clarification.
ANSWER
The FIDIC definition of a subcontractor is given at Sub-Clause 1.1.2.8 of the 1999 Contract for
Construction as: "Subcontractor" means any person named in the Contract as a subcontractor, or
any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to
each of these persons. Different clients have different criteria when evaluating tenders. FIDIC would
certainly expect that any client will want to ensure that the tenderer has adequate experience as a
main contractor and has not just worked as a subcontractor. However, in FIDIC's opinion, this would
normally be worded as "Experience as a subcontractor ....". FIDIC has also known clients to be
concerned that tenderers have relied on a proposed subcontractor's experience and resources when
preparing a tender and then the named subcontractor is withdrawn and another, less experienced,
company is proposed after the tender has been accepted. However, for an international tender,
some clients require that a certain percentage of the Works must be subcontracted to local
companies. In this case the experience and resources of the proposed subcontractors will be an
important part of the tender. The client's criteria when evaluating tenders depend on a number of
different factors, including the past experience of the particular client. In order to ascertain the exact
intentions for evaluating your particular tender you would need to raise the question with the client.
FREE-ISSUE MATERIALS
QUESTION
I have a question regarding Clause 69.1 for Default of Employer. We are executing a Contract for a
Project in Pakistan under FIDIC Fourth Edition, 1987. The Employer has assigned The Engineer and
also an Employer's Representative. The Employer's Representative is form time-to-time acting like
The Engineer and would like to physically check the works at site. They are also applying deductions
on the certificates of The Engineer, such as retention money on escalation, and also Quantities, etc.
The amount of the unauthorized deductions are around 5 % of the total amount certificates issued by
The Engineer. We have served a notice under Clause 69.1 and 69.4, of the Conditions of Contract to
reduce the rate of work and furthermore, clarify that the Clause 69.1 explains the default of the
Employer, regardless of the quantum of amount in case of Employer's failure to pay to the Contractor
total amount due under any certificate of the Engineer. Do you think that the above statement is true
and it is a case of default of the Employer ?
ANSWER
Depending on what is written in the Contract and the Particular Conditions, generally speaking you
have a case against the Employer. The damages which the Contractor may claim would include
interest and/or financing charges. However, you must check the provisions of the Sub-clause 2.1
Engineer's duties and authority ,to see what is mentioned there. It is not very clear what is this
Employer's Representative and what are his duties under the Contract,. However, one would
suspect that you have a case against the Employer.
BOGUS CLAIMS
QUESTION
I request to give me clarification about the correct interpretation of Clause 60.6 Final statement in the
FIDIC Conditions of Contract 1987 revised in 1992. This is about submission by the Contractor of
final statement containing the following (a) 'the value of all work done in accordance with the
contract, and (b)any further sums which the contractor considers to be due to him under the contract
or otherwise'. I want clarification with respect to (b) above. Does it include the Claims which the
Contractor has never raised during the currency of contract according to provisions of the contract? I
am confronted with a dispute In which the contractor for a value of total work of Rs 70 million has
submitted final accounts of Rs 280 millon by including various type of claims which he never claimed
during the contract period and now claims in the final statement and since the Engineer/Employer
failed to respond, the Contractor claims that the final account has become final. I would request for
an early response as to the true and intended purpose of the sub-clause (b) of Clause 60.6 of the
General Conditions of the above mentioned FIDIC version for civil works construction. Should I
include all bogus claims what I intend to include for the purpose that if I claim USD 100 I would at
least get USD 1. How I can rebut this?
ANSWER
The provisions of Sub-clause 60.6 have to be read together with the provisions of Sub-clause 60.5
and of course with the provisions of the Sub-clause 60.9. In order for the Contractor to maintain any
claim, he must include it in his Statement at Completion, if it has arisen by then, and in his Final
Statement. There are a number of incidences under the contract when the Employer gives to the
Contractor indemnities or is otherwise responsible to the Contractor. Clauses in which this occurs
and where the Contractor's resulting claims against the Employer could arise for the first time after
the Statement at Completion or Final Statement have been submitted by the Contractor include the
following: Clause 19.2 (Employer's responsibilities) in relation to safety; Clause 21.3 (Responsibility
for amounts not recovered); Clause 22.3 (Indemnity by Employer); Clause 24.1 (Accident or injury to
workmen); Clause 25.4 (Compliance with policy conditions); Clause 26.1 (Compliance with statutes,
regulations); Clause 70.2 (Subsequent legislation); and Clause 71.1 (Currency restrictions). In each
of the above cases, it is conceivable that the Contractor would wish to make a claim against the
Employer after the date of the Final Statement. Further, if the Contractor was made liable under the
applicable law to a third party in respect of design which had been carried out by the Engineer, the
Contractor would wish to bring a claim against the Employer to recover any damages paid out. Subclause 60.9 in fact bars the claims not mentioned in the Statement at Completion and in the Final
Statement. The purpose of the sub-clause is sensible, namely to enable the Employer to achieve a
reasonable degree of certainty as to his ultimate liability.
APPOINTING AN ENGINEER
QUESTION
Is it recommended to have in a contract based on FIDIC's Electrical and Mechanical Works Contract
an external expert acting as the Engineer? Or is there no problem in recruiting the Engineer from
amongst the Beneficiary (in our case a "public" authority)? We are signing a contract shortly. The
Engineer is according to the Red Book, Clause 2.4 Part I bound to act impartially. The question is if
there is an internal incompatibility in the relationship to his Employer.
ANSWER
The basis upon which the 1987 Yellow Book and Red Book is written is that the Engineer is
appointed by the Employer, but that he is independent of both parties - i.e., he is an independent
third party. In many cases he is required to give impartial decisions - in fact under Clause 2.4 of the
Yellow Book he is required to act impartially at all times when exercising his discretion. If the
Engineer is an employee of the Employer - e.g., someone from the Employer's Engineering Division
- there is a big risk that he will not be in a position to act impartially. Although he may be very
experienced and capable from a technical point of view, and able to handle all technical matters, he
may not be free to make decisions which involve financial arrangements, etc. in a fair and impartial
manner. It is not impossible, nor unknown, for the Employer to nominate himself or one of his own
staff as Engineer, but it is rare and certainly causes problems. The text of any clauses referring to
the impartiality of the Engineer will probably need revising at some stage, as will the provisions for
handling claims and disputes (Clauses 2 and 50). The principle of using an employee of the
Employer as Engineer would be more acceptable if a Dispute Adjudication Board (DAB) was
introduced to replace the principal provisions of Clauses 2 and 50.1 to deal with claims and disputes.
STANDARD LETTERS
QUESTION
I am a Civil Engineer, presently working as Contracts Manager. Foreign (non-British nationality)
engineers usually have an understanding of the contract document and the associated
entitlements/obligations, but always express difficulty in composing (or responding to, if they are on
"the other side" , correctly worded "standard" letters to the RE, Engineer or Employer in compliance
with the requirements of the various sub-clauses. Do you have such a publication?
ANSWER
The only book which we can recollect is "Musterbriefe in Englisch" (ISBN 3-7625-2607-9) although
its standard letters are not such as we would prefer to endorse. Although we will review the situation
with regard to the new FIDIC Contracts Guide, FIDIC lack enthusiasm for the very concept of
standard letters, which seems to be tied up with the concept of avoiding thinking about the situation.
However, we do recognise the validity of concerns expressed by those whose first language is not
English. Thus, "Musterbriefe in Englisch" has been republished as an electronic edition (it goes with
the 1987 Red Book civil works contract). An updated version for use with the Construction Contract
1st Edition, 1999, the Red Book successor, will be published by FIDIC in 2009 (FIDIC has acquired
the copyright of Musterbriefe in Englisch). It should be noted that Edward Corbett's book "FIDIC 4th
"contains some standard letters. These have been incorporated with permission in the electronic
version of "Musterbriefe in Englisch" published by FIDIC.
QUESTION
I believe this case does not constitute a question of mistake in contract to be decided under the
applicable law. The schedule of prices of labour and materials is a provision for the tenderer to
indicate his price (cost plus profit) on which he had based his Contract Price, in order for the
Engineer to ascertain the value of an item of work that had been executed (possibly under a
variation order) and for which, or for a similar item of work of which, no price could be found in the
Bill of Quantities (BOQ). Thus the schedule of prices of materials and labour only assists the
Engineer to determine the overheads and profits of the Contractor, under the terms of the contract,
that has to be added to the basic cost of executing an item of work, which the Engineer can always
readily determine. If provison had been made in the contract for payment for price escalations, then
such payments had to be determined by reference to price escalation indices, published by an
accepted authority. As to which source or publication is to be used for this purpose, depends on what
would have been reasonably expected to be in the minds of the two parties at the time of entering
into contract.
ANSWER
We assume that this inquiry is about FIDIC 1999 Conditions of Contract where in the 199 Red Book
Sub-Clause 13.8 it says: "13.8 (Adjustments for Changes in Cost) - In this Sub-Clause, "table of
adjustment data" means the completed table of adjustment data included in the Appendix to Tender.
If there is no such table of adjustment data, this Sub-Clause shall not apply. If this Sub-Clause
applies, the amounts payable to the Contractor shall be adjusted for rises or falls in the cost of
labour. Goods and other inputs to the Works, by the addition or deduction of the amounts
determined by the formulae prescribed in this Sub-Clause. To the extent that full compensation for
any rise or fall in Costs is not covered by the provisions of this or other Clauses, the Accepted
Contract Amount shall be deemed to have included amounts to cover the contingency of other rises
and falls in costs. The adjustment to be applied to the amount otherwise payable to the Contractor,
as valued in accordance with the appropriate Schedule and certified in Payment Certificates, shall
be determined from formulae for each of the currencies in which the Contract Price is payable. No
adjustment is to be applied to work valued on the basis of Cost or current prices. The formulae shall
be of the following general type: Pn=a+bxLn/Lo+cxEn/Eo+dxMn/Mo where: "Pn" is the adjustment
multiplier to be applied to the estimated contract value in the relevant currency of the work carried
out in period "n", this period being a month unless otherwise stated in the Appendix to Tender; "a" is
a fixed coefficient, stated in the relevant table of adjustment data, representing the non-adjustable
portion in contractual payments; "b", "c", "d", ... are coefficients representing the estimated
proportion of each cost element related to the execution of the Works, as stated in the relevant table
of adjustment data; such tabulated cost elements may be indicative of resources such as labour,
equipment and materials; "Ln", "En", "Mn",... are the current cost indices or reference prices for
period "n", expressed in the relevant currency of payment, each of which is applicable to the relevant
tabulated cost element on the date 49 days prior to the last day of the period (to which the particular
Payment Certificate relates); and "Lo", "Eo", "Mo", ... are the base cost indices or reference prices,
expressed in the relevant currency of payment, each of which is applicable to the relevant tabulated
cost element on the Base Date. The cost indices or reference prices stated in the table of adjustment
data shall be used. If their source is in doubt, it shall be determined by the Engineer. For this
purpose, reference shall be made to the values of the indices at stated dates (quoted in the fourth
and fifth columns respectively of the table) for the purposes of clarification of the source; although
these dates (and thus these values) may not correspond to the base cost indices. In cases where
the "currency of index" (stated in the table) is not the relevant currency of payment, each index shall
be converted into the relevant currency of payment at the selling rate, established by the central
bank of the Country, of this relevant currency on the above date for which the index is required to be
applicable. Until such time as each current cost index is available, the Engineer shall determine a
provisional index for the issue of Interim Payment Certificates. When a current cost index is
available, the adjustment shall be recalculated accordingly. If the Contractor fails to complete the
Works within the Time for Completion, adjustment of prices thereafter shall be made using either (i)
each index or price applicable on the date 49 days prior to the expiry of the Time for Completion of
the Works, or (ii) the current index or price: whichever is more favourable to the Employer. The
weightings (coefficients) for each of the factors of cost stated in the table(s) of adjustment data shall
only be adjusted if they have been rendered unreasonable, unbalanced or inapplicable, as a result of
Variations." The clause is very clear and unfortunately the question raised is not related to an
interpretation of a Sub-Slause.
FAIRNESS OF DEDUCTIONS
QUESTION
As our project is a lump-sum contract, the client has reduced some of the items and is deducting
suome of our payment amounts from the monthly certificate. Is it fair to deduct an amount?
ANSWER
Although it is not for FIDIC to comment on the "fairness" of a particular circumstance, it is the FIDIC
philosophy to publish Conditions of Contract that adopt an approach of fairness and balanced risk
allocation between the parties as a primary focus. Further, FIDIC can only comment in general terms
on the interpretation of a FIDIC clauses, and it should be noted that for the application of a clause to
a particular problem situation, one should always consult a specialist. With that being said, in
general, the Sub-Clause entitled Variations (Sub-Clause 52.1 in the 4th Edition or 13.1 in the 1999
Edition of the Construction Contract) does provide the right for the Engineer to vary the work
downward; specifically the Engineer may decrease quantities or omit work, provided of course that
this work is not carried out the Employer or another contract. Further, Sub-Clause 51.1 provides that
such variations will be valued in accordance with the Clause 52, in the case of the 4th edition or
Clause 12 in the case of the 1999 editions. Both of these clauses provide the rules for the valuation
of these variations, which include the possibility of reduction in price. Please note that the above
represents a general answer only, and specific advice to the particular facts surrounding your
situation, we recommend you consult a specialist.
LIQUIDATED DAMAGES
QUESTION
I am working as a Resident Engineer for Highways with consultants. A brief detail of our project is as
as follows: The project is a repair project and is divided in 3 sections. The sections are of varying
lengths with 150m for the shortest one and 1.5 Km for the longest one. Completion date for the
project has already elapsed early this year and no time extension has been granted to the contractor
owing to delay on his own behalf. Two sections have already been completed (opened to traffic) and
the 3rd section is near completion. No separate times for completion have been provided in the
contract for either section. Clause 47.2 of FIDIC Conditions of Contract (4th edition) recommends
the reduction in penalty subject to taking over of different sections. As sated above, none of the
sections have been acquired by the client contractually. The referred clause also states that the
provisions of the sub clause shall only apply to the rate of liquidated damages and shall not affect
the limit thereof. What I infer from this part is that even after the reduction of penalty, it shall be
applicable from the original date of expiry of the contract. Is this the right interpretation? My second
query is regarding the reduction in liquidated damages. Under the above circumstances where the
sections have not been acquired, but opened to traffic and general public, can the penalties be
reduced contractually subject to mutual agreement with the client? Thirdly, during the currency of the
project, some savings have been there (which couldn't be estimated at design stage due to repairing
nature). The savings are less than 15% (considering Clause 52.3). If penalties are applied and
reduced thereof, are they to be calculated on the original contract price or the revised one?
ANSWER
If understood correctly, your first question relates to sub-clause 47.2, specifically the last sentence,
which reads "The provisions of this Sub-Clause shall only apply to the rate of liquidated damages
and shall not affect the limit thereof." The meaning of this sentence is that although this clause
allows for the amount of liquidated damages to be reduced proportionately to the work being handed
over, if the work is handed over in parts, the maximum limit of liquidated damages (as specified in
the appendix to tender (see Sub-Clause 47.1)) is not affected. In regard to your second question,
Clause 47 should be read in conjunction with Clause 48. In the background to your question, you
stated that none of the sections have been 'acquired by the Client contractually', yet earlier you state
that '2 sections have already been completed (opened to traffic)'. In this light, we would suggest that
you may review both sub-clause 48.2 and 48.3, which, depending on the particular fact pattern
surrounding your contract, may be applicable. In answer to your third question, liquated damages
are not penalties. You are kindly referred to the verbiage contained in Sub-Clause 47.1, which reads,
in part "... and not as a penalty ...". As explained in the Guide to the Red Book, Liquidated damages
are an amount determined by the Employer, before tenders are invited, as a reasonable assessment
of the actual damages which he would suffer in the event of delay in completion of the Works.
Hence, in general, Liquadated Damages should be calculated from the vantage point that will result
in a reasonable assessment of the actual damages.
QUESTION
In terms of the FIDIC 1987 Red Book, is the Contractor entitled to a portion of the saving as provided
for in the terms of Sub-Clause 13.2 (Value Engineering) in the 1999 Red Book?
ANSWER
The FIDIC 1987 eRed Book does not have a similar provision as the one mentioned in the FIDIC
1999 edition Value Engineering, Sub-Clause 13.2 However you may find in the 1987 Red Book a so
called bonus for early completion.
ADDITIONAL WORKS
QUESTION
Being a project manager from the client side, I would like to know as per FIDIC can I force a
contractor to carry out additional works prior to approval of his financial claim?
ANSWER
The basic answer is YES, provided you follow the correct contract procedures. There are a number
of Sub-Clauses which are relevant including, from the 1999 Construction Contract: a) S/Cl 3.1: The
Employer may have imposed constraints on the Engineer's authority in the Particular Conditions. b)
S/Cl 3.3: The Contractor shall comply with instructions given by the Engineer. c) S/Cl 13.1: The
Contractor shall execute and be bound by each Variation initiated by the Engineer. Subject to
exceptions as stated in the Sub-Clause. d) S/Cl 13.3: Procedures for the Engineer to value the
Variation. The Engineer may have asked for and accepted a proposal, or he proceeds as Clause 12.
NEW RATES
QUESTION
In a civil marine work contract of FIDIC conditions, disputes quite often occurs on fixing of revision of
rates. though clauses 51 and 52 of Fourth Edition - Red Book - clearly provide causes for variation
and valuation of rates, ambiguity still persists with respect to adoption of revised rates for varied
quantities only or for full quantity executed as long asthere are no major changes in deployment of
workmen, equipment and materials. Leaving the decision to engineer may not give an appropriate
solution as persons holding the post of engineer may have different views and their decisions may
not exactly match with the views of FIDIC authors. Please clarify the situations when revised rates
are applicable for the entire quantity or for increased quantities only.
ANSWER
The decision whether a new rate applies to the total quantity of an item, or just to the Variation
quantity, will depend on the reason why a new rate is necessary. This may depend on the reason
and details of the change to the Contractor's cost. Sometimes the original quantity will already have
been executed and paid at the BQ rate, before the Variation is ordered. However, sometimes the fact
of the quantity being changed by the Variation will change the circumstances and costs and makes it
reasonable to pay the total quantity at the new rate. The new rate may differ if it is being applied to
the total quantity or just to the Variation quantity. The Engineer will, of course, take all these factors
into account when calculating a new rate. You should also refer to the commentary on Clauses 51
and 52 in the FIDIC Guide to the Fourth Edition. The commentary emphasises the importance of
consultation with both the parties.
QUESTION
A contract was signed under the FIDIC Conditions of Contract which require that indices for the
skilled and unskilled labour should be filled by the Contractor in the relevant Appendix while
submitting the tender. This requirement including the source of the indices was however not fulfilled
by the Contractor. This fact was noted but employer failed to get this requirement met and the
contract was signed without this information. The dispute arose when the contractor submitted
escalation claim due change in prices of the labour component according to relevant provision. The
contractor insists the use source indices issued by the local government for calculation of adjustment
which is near the place of the construction and because this condition is more profitable to
contractor. The Client insists that he will use the indices issues by a gevernment office which are
normally used in government contracts. I am the Arbitrator in one such case and need advice of
FIDIC what will be the judicious coarse of action in this scenario. I however feel that entire
responsibility of not providing this information cannot be placed on the Contractor and the Employer
should have insured that Contractor provide this information before signing of the contract. omission
was made and the contract was signed without this information (source of indices). I will be
anxiously waiting for advice from your expert what reasonable coarse of action should be adapted in
this dispute resolution as the Contractor has gone in dispute on this issue.
ANSWER
It seems that the Contractor made a mistake by not adding the information to the Appendix to
Tender. The Employer then accepted the Tender and the Parties signed a Contract which included
the mistake. Unfortunately you say that they cannot agree on the information which should be added
to the Appendix to Tender. To correct the mistake requires a change to the signed Contract to add
this information. Correcting a mistake in a Contract is a legal question which must be studied under
the applicable law. FIDIC cannot comment on such legal questions.
ENGINEER'S DECISION
QUESTION
Our firm has a contract for consulting services with the Government of El Salvador for the
construction of major transportation infrastructure in the country. The project is divided into three
packages that are governed by FIDIC Conditions of Contract for Works of Civil Engineering (Red
book, 4th Ed. 1987). The construction of the first package of project, which included two 400-meter
bridges over the most important river in El Salvador, was completed last April.The Contractor is a
Joint Venture of firms that is now claiming additional payments based on the contract documents. In
order to have a clear interpretation of the documents, we would like to clarify the following: Clause
67.1 Engineer's Decision - we would like to confirm if under this Clause the Contractor can claim for
matters that happened during the construction period, even after the Take-Over Certificate has been
issued and the Statement at Completion has been certified and paid.
ANSWER
Regarding Clause 67.1: if the Contractor is dissatisfied with an Engineer's evaluation of a claim
under Clause 53, he may refer the matter at any time (before or after completion) to the Engineer
under Clause 67.1 for an "Engineer's Decision". He can do this any time up to his Final Statement
and there is no time limit. The Engineer then has 84 days to respond. The Contractor cannot submit
a "new'" claim for normal determination under this clause. The claim must first be processed under
Clause 53, and only when a Clause 53 determination has been given which the Contractor finds to
be unacceptable do we have a "dispute" situation which can be handled under Clause 67.1.
CALCULATION OF CLAIMS
QUESTION
I would like to know if you can help me find information regarding the procedure and calculation of
claims (of any kind) arising out of a Civil Engineering Construction contract.
ANSWER
FIDIC publishes guides to each of its forms of construction contract, which may provide the guidance
you require on the procedures for claims. You would need to order the Guide for the use of whatever
Conditions you are using. If your enquiry relates to October 2000. FIDIC's guides do not elaborate
on the calculation of claims, so you might need to consult other publications. Personally, I am only
aware of "Building and Civil Engineering Claims in Perspective" by Geoffrey Arthur Hughes, which
was first published by Longman in 1983. It may have been republished and fulfil your needs.
QUESTION
I have the following problem and I can not find a solution in the FIDIC Red Book Fourth Edition 1887.
The problem is as follows: we have made a contract with a pre-hand over list made, with the
Engineer, in April 2000. A new contract, given to another company in the same building was given in
May 2000, it was an obligation for me to give the keys of the building. As the Engineer is in
Zimbabwe and the Building is in Burundi, no engineer was there for the hand over of the inside of
the building. Now, the Engineer asks us to repair some things which were not on the pre-hand over
list. Can you please tell me what I have to do.
ANSWER
FIDIC does not undertake to proffer advice relating to every situation which may arise under a
FIDIC-based contract. However, it appears that the answer to your question depends upon whether
a Taking Over Certificate has been issued. If so, the pre-hand over list presumably advised you of
the work described in Sub-Clause 49.2(a), and the Engineer has asked you to repair some things as
described in Sub-Clause 49.2(b). If not, the Engineer may be "specifying all the work which ... is
required to be done ... before the issue of such Certificate" under Sub-Clause 48.1. In either case,
you have not indicated any reason for not complying with the Engineer's instructions.
ADDITIONAL PAYMENTS
QUESTION
Our firm has a contract for consulting services with the Government of El Salvador for the
construction of major transportation infrastructure in the country. The project is divided into three
packages that are governed by FIDIC Conditions of Contract for Works of Civil Engineering (Red
book, 4th Ed. 1987). The construction of the first package of project, which included two 400-meter
bridges over the most important river in El Salvador, was completed last April.The Contractor is a
Joint Venture of firms that is now claiming additional payments based on the contract documents. In
order to have a clear interpretation of the documents, we would like to clarify the following: Clause
53.1 Notice of Claims - it is important to confirm if the Contractor can invoke this Clause to claim for
additional payment owing to construction works that were performed before the Take-Over
Certificate, once this Certificate has been issued. In other words, if the Contractor can claim for
matters that happened during the construction period even after the Take-Over Certificate has been
issued.
ANSWER
Regarding the application of Clause 53.1. This clause requires the Contractor to give Notice of a
potential claim within 28 days of the event occurring. This establishes his right to claim and he
should then proceed to substantiate the claim according to Clause 53.3. He can claim at any time before or after Taking-over - if events occur (before or after taking-over) which he considers entitle
him to claim. The intention of Clause 53.1 is to try to make sure claims are dealt with as and when
they occur so that everyone is familiar with the circumstances (thus the 28 day provision) - and not
to leave them to the end - when people have probably forgotten all the details. If he did this within
the time limits, then the claim should be evaluated according to the Contractor's submissions. If he
did not - as would appear to be the case - and has come in with a claim a considerable time after the
event, then we would suggest that you have two courses of action. Firstly you should perhaps try to
establish why he did not give notice within the 28 days. Either you can reject his claim on the ground
that he did not submit it within 28 days as required by Clause 53.1, or, under Clause 53.4 you can
make an assessment based on records which were kept at the time. Normally I would suggest it
depends on the circumstances. If the claim appears to be frivolous and confused with no
substantiation (possibly an event you knew nothing about) you may well decide to reject it. But if it
concerns an event of which you were aware which you knew had disrupted the Contractor, then
maybe you could consider it under Clause 53.4.
QUESTION
I have a question regarding adoption of FIDIC Red Book Fourth Edition reprinted 1992. The
particular Contract contains Clause 51/52 "Variations" and also contains Clause 56 "Works to be
Measured" and has BOQ. Design and Construct Services for Electrical and Mechanical were
tendered as diagramatic designs and are to be developed to the Approval of Engineer as part of
obligations under the Contract and have various BOQ items. This Design Development for
Mechanical/Electrical services is his obligation under the Contract, and in this way would not seem
to qualify as a Variation to the Contract. However new items to the original BOQ have been
necessitated by DD. Under which Clause can new rates be established for the re-measure of these
Works?
ANSWER
The Conditions of Contract for Works of Civil Engineering Construction (1992) do not contain
express provision for new rates being established for the re-measurement of non-varied Contractordesign works, where new items to the original BoQ have been necessitated by Design Development.
Typically, Contractor-design works are priced on a lump-sum basis, and are not subject to remeasurement after Design Development, so such express provision would be inappropriate in the
Conditions of Contract which FIDIC intended to be suitable for Employer-design works.
QUESTION
Has Employer got an authority according to FIDIC to terminate the contract of Engineer before
completion of project and appoint another engineering company or continue with its own resources?
I know that that Employer cannot do this according to Red Book FIDIC Clause 1.1 Definitions by
referring to Part II of the contract. What should we do as a contractor at this stage?
ANSWER
You appear to understand FIDIC's provisions, as summarised at the top of page 41 of the Red Book
Guide: "It should be noted that ... the effect of ... [1.1(a)(iv)] is to prevent the Employer from changing
the Engineer without the consent of the Contractor." In effect, provided the legal person defined as
"Engineer" continues to exist, such legal person continues to be the Engineer for the purposes of the
Contract, and the Employer has no power to name someone else as Engineer. By "continues to
exist", we mean does not (as a natural person) die, or is not (as a company) dissolved. FIDIC cannot
give specific advice in respect to the actions a party should take, and only undertakes to clarify
aspects of its own provisions. You do not seem to need such clarification, but may need to obtain
advice from a lawyer with expert knowledge of construction law.
There is always a possibility that some aspect of the situation (which you have not mentioned) would
entitle the Employer to replace the Engineer under the law governing the Contract. For FIDIC, it
seems that you should first decide whether the replacement "Engineer" is acceptable as such
because, if not, you could inform the Employer accordingly and seek to resolve the matter before it
escalates into a major dispute.
QUESTION
Regarding the correct application of the Red Book Contract, the Employer in compliance with subclause 63.1, after giving written notice to the Contractor upon his contravention of provision in subclause 4.1, enetered upon the site and the works, and terminated the employment of the Contractor.
The Employer wants to employ another Contractor, which took second place in the initial, public
tender, to complete the works. The further procedure will be in compliance with sub-clauses 63.2,
63.3, 63.4 and 64.1.The questions is: is this procedure in compliance with the General Conditions of
the Red Book 4th Edition?
ANSWER
We refer to your query whether a proposed procedure complies with the fourth edition of the General
Conditions of Contract for Works of Civil Engineering Construction.
FIDIC cannot undertake to provide advice on actual circumstances, and is only prepared to clarify
and explain the meaning and purpose of the provisions it publishes in its Conditions of Contract. In
the case of serious matters such as termination, legal advice should be sought.
However, we would make the following observations, without concluding whether the Employer is
entitled to proceed as you have described. For these purposes, we start by assuming that the
Employer's termination was valid by reason of the Contractor's breach of sub-clause 4.1. Such
validity may, of course, be challenged by the Contractor.
Following a valid termination, the Employer's options on employing another contractor would not
appear to be constrained by the General Conditions, other than under Clause 63 (with which you
state the further procedure will comply), although they may be constrained by the applicable law. You
mention compliance with sub-clause 63.4, which relates to assignment of subcontracts. Applicable
law may constrain the Employer's rights in respect of subcontracts which were associated with the
Contractor's breach of sub-clause 4.1.
You mention compliance with sub-clause 64.1, which relates to urgent remedial work which the
Contractor is unwilling or unable to do, prior to termination. After termination, his previous
unwillingness or inability would not seem to entitle the Employer to invoke sub-clause 64.1. As
regards employing a contractor which took "second place ... in the initial public tender", this is not a
matter to be decided by the General Conditions of the Contract under which the termination was
effected. The choice of replacement contractor is a matter to be decided by the law relevant to the
procurement procedures and any constraints imposed by those providing funds for the project.
DELAYED PAYMENT
QUESTION
I am an Architect registered with the RIBA in the UK since 1978 and the UAE Authorities in Abu
Dhabi, UAE since 1981.
I have recently been Engineer under a FIDIC Red Book 4th Edition Building Contract between a
UAE Government Agency and a local Contractor, and Employer's Representative/Adviser under a
FIDIC Design and Build Contract, same Employer but different Contractor.
Clauses of Particular Application have been prepared by a third party advising the Employer direct in
both cases, but largely ignored, the Employer paying late throughout, not paying the final Interim
Certificates on Taking Over the Works in either case, threatening the imposition of Penalties by
ignoring and/or rejecting the cases for Extensions of Time in both cases, and not paying at all until
forced agreement to reduced amounts has been accepted by the Contractors through barter.
As you may know, there is very limited recourse to the law here, especially for foreigners. Both
Contractors are likely to weigh the costs of Courts and further Delay against the benefit of any
payment at all; one has already given in, but the other is still fighting, or perhaps more realistically,
negotiating.
What should I do, please: indeed, is there anything that can be done ? This is the worst case of
abuse of Contract I have come across in more than 20 years here, though the amounts are relatively
small.
ANSWER
Whilst we can sympathise with the situation described in the question, there is not a lot FIDIC can
recommend or that he can do as Engineer in this case.
The situation described is, unfortunately, not all that uncommon in some Middle East countries and
the ultimate decision of what to do lies with the Contractor. If he feels the situation warrants extreme
measures, then he can terminate under Clause 69.1 (unless of course 69.1 has been changed - as it
very often is in these countries). Otherwise there is not a lot you can do.
Being fair and impartial the Engineer could (and perhaps should) write to the Employer reminding
him of the terms of the Contract - but he will probably bring down the wrath of the Employer on his
shoulders, and that may not help anybody.
You should perhaps also bear in mind that Contractors who choose to work in these countries are
usually (or should be) rather familiar with this situation and may well have allowed something in their
price to cover this sort of thing - especially, as the person asking the question says, the amount is
not very large.
QUESTION
For the Red Book, can the Engineer issue instructions under Clause 13.1 after the expiry of the
Defects Liability Period ?
ANSWER
After the Defects Liability Period expires, the Engineer may issue instructions under Clause 49, and
cannot rely upon Clause 13 as authority to issue other instructions.
PERFORMANCE SECURITY
QUESTION
Please inform us about the validity of the performance security if the duration of the contract is 90
days.
ANSWER
These principles would probably apply whichever FIDIC document is being used.
QUESTION
The question refers to FIDIC Conditions of Contract for Works of Civil Engineering Construction (4th
Edition 1987, reprinted 1988 with editorial amendments, reprinted 1992 with further amendments). I
am an employer who is negotiating with the contractor now. I have a trouble in using the FIDIC
conditions, and ask for your help urgently. Sub-Clause 1.1 (b)(v) "Tender" means the Contractor's
priced offer to the Employer for the execution and completion of the Works and the remedying of any
defects therein in accordance with the provision of the Contract, as accepted by the Letter of
Acceptance." And Sub-Clause 5.2 specifies the priority of the contract document, of which the
Tender is listed as third. Are those two "Tender" have the same meaning? Can we explain that the
Tender only refer to the document entitled letter of tender (maybe 1 or 2 pages, very short and
simple anyway), or all the documents submitted by the Contractor along with the letter of tender as
response upon the Bidding Document (a lot of documents, such as appendix to tender, priced BOQ,
technical proposal, evidence for construction experience and financial capacity)?
ANSWER
The Tender at Sub-Clauses 1.1(b)(v) and 5.2(3) means the form of Tender which is given at the end
of Part 1 of the Red Book. The form of Tender, at paragraph 2, confirms that the Appendix to Tender
forms part of the Tender and Sub-Clause 1.1(b)(iv) confirms that the priced bill of quantities forms
part of the Tender. If the Employer requires other documents to be included in the Contract as part of
the Tender then he must state this clearly in the Instructions to Tenderers and in the form of Tender.
QUESTION
Sub-Clause 11.1 tell us that the hired contracting party is responsible for the data contained in his
proposal based on the data supplied by the Contractor. Could you please tell me how I can obtain
the data?
ANSWER
The Contractor must have based his tender on information: 1) which was provided to all tenderers by
the Employer from the investigations which had been carried out by the Employer; 2) which the
Contractor obtained from his own inspection and examination of the Site and its surroundings.
Where the Contractor obtained this information will depend on the circumstances but he must have
satisfied himself that his tender was correct and sufficient to meet his obligations under the Contract.
INTERIM CERTIFICATES
QUESTION
Sub-Clause 60.4 stipulates that the Engineer may correct any error in an interim certificate in
subsequent certificates. Are there any limitations in the application of this provision?
ANSWER
You are referring to Sub-Clause 60.4 of the 1987 Contract for Civil Engineering Works. There is a
similar provision at Sub-Clause 14.6 of the 1999 Contracts. The Contract does not put any limitation
on this provision. However, under Sub-Clause 60.2 the Engineer has previously certified the amount
which he considered to be due and payable. If he has now found an error and changed his mind he
should explain the reasons for the change.
REFIXING OF RATE
QUESTION
I am interested in application of Clause 52.2 (Power of the Engineer to fix Rate). If circumstances
allow a refixing of rate, would it apply to the varied quantity(increased/decreased) or to the entire
quantity, i.e., quantities in the bid plus increase/decrease?
ANSWER
You are referring to the 4th Edition 1987 of the Contract for Works of Civil Engineering, Sub-Clause
51.1 (a) allows the Engineer to issue an instruction to increase or decrease the quantity of any work
included in the Contract. The rate which the Engineer agrees or fixes under Sub-Clause 52.2 would
only apply to the varied quantity (increased or decreased). The original quantity is not part of the
Variation and would be paid at the original rate.
RECOVERY OF COSTS
QUESTION
Working with 1987, 4th Edition, reprinted in 1992 FIDIC form of contract on a project where Clause
70, whist being modified does permit the recovery of changes in the prices of labour and materials.
Are there any legal precidents which reflect the provision reflected in the 1999 form of contract to
allow the recovery of costs, post the stated contract completion where the contractor has failed to
complete the works in the specified time? Or are there any precidents to reflect the recovery of costs
per sec, post the contract completion date? If there are any precidents, if there are in electronic,
format, could you forward them or, advise where they could be obtained.
ANSWER
FIDIC is unable to provide legal guidance or information on legal precedents. However, to be helpful,
the federation has asked an expert to comment so that your future research can guided in the
approriate direction. You are correct that the 1987 4th Edition does not include specific provision for
the recovery of price changes after the contract completion date when the Contractor has failed to
complete the work in the specified time. Alternative clauses can be found in the FIDIC Guide to the
4th Edition and in the 1999 Contracts. The problem with legal precedents is that no two dispute
situations are ever exactly the same and so need legal advice. Guidance and summaries of some
arbitration awards can be found in the international legal journals, newsletters from law firms and the
publications of the international arbitration centres such as the ICC Paris, the London Court of
International Arbitration and other centres in different parts of the world.
ENGINEER'S INSTRUCTIONS
QUESTION
A FIDIC standard Contract for civil engineering (Red Book 4th Edition 1987) is basis of a Contract for
a Wharf and Approach Bridge Construction and Causeway Reclamation project (The Contrac ). The
Contract is a Lumpsum Agreement and the BOQ refers as follows: All works in this section except
Provisional Quantities will be paid for as LumpSums. Quantities are estimates only. If the Contractor
wishes, additional items may be added to the Bill or quantities amended. Rates nominated will be
used only to assess variations (if any) to the Contract and to assess progress claims and payments.
Provisional Quantities and Items will be paid for as described in the Conditions of Contract. One of
the BoQ item was pertaining to Crane Rails to be provided by the Contractor. Later the Company
organized the Rails on their own and the Contractor is not required to provide the Crane Rails as per
the BoQ. In view of this the Crane Rail related Amount as stated in the BoQ is proposed to be
deducted out of the BoQ. Please confirm that this is proper approach under Article 51 and 52 or any
other conditions of FIDIC standard contract.
ANSWER
Under a FIDIC Contract, any change to add or omit work must be made by an instruction from the
Engineer under the appropriate sub-clause. You mention Sub-Clauses 51 and 52, which are from the
1987 4th Edition of the Contract for Civil Engineering Works. Sub-Clause 51.1, item (b) allows the
Engineer to issue instructions to omit work, but this is qualified by the statement in brackets "(but not
if the omitted work is to be carried out by the Employer or by another contractor)". Your proposal for
the crane rails would appear to contravene this requirement. Hence the change and price
adjustment may need to be negotiated between the Parties and would probably involve legal advice.
QUESTION
We are in the process of preparing a claim under Clause 52.3 of the FIDIC Conditions of Contract for
Works of Civil Engineering Construction and are seeking clarification on the application of the clause
especially as regards to which amount do we apply the percentage which is in excess of the 15%.
Do we apply it to: - The effective contract sum; or, - The difference between the amounts calculated
using the actual percentage by which the effective contract sum shall have been exceed by and the
15%. Please note that In this particular contract, the majority of Preliminary and General Items were
stated as provisional sums (as stated in the Bill of Quantities by the Engineer) it is not easy for us to
accurately determine the contractor's on-costs. We have since acquired a copy of the "Guide to the
Use of Fidlic Conditions of Contract for Works of Civil Engineering Construction" and the explanation
given does not adequately cover us, refer page 117 of the guide. Please advise us on how this
clause is to be applied.
ANSWER
The precise problem is not clear and we can only comment in general terms on the interpretation of
Sub-Clause 52.3. The Sub-Clause allows the Contractor and Engineer to discuss and agree a lump
sum addition or deduction to the Contract Price when the additions/deductions as described at (a)
and (b) are more than 15% of the "Effective Contract Price". It will be up to the Contractor to prove
the changes to his Site and general overhead costs. The details and calculation of the lump sum will
dependant on the reasons for the increase or decrease to the Contract Price.
UNIT RATES
QUESTION
1. The following addition has been made in Clause 52.2 (FIDIC 1987, Contract for Works of Civil
Engineering) in our contract by the Employer: "..Provided further that no change in the Unit Rates or
prices quoted shall be considered for any item in the Schedules to the Bill of Quantities, unless such
item individually accounts for an amount of more than 2 percent of the sum named in the Letter of
Acceptance, and the original billed quantity by more than 30 percent. Not withstanding above, for
variation exceeding 10% in quantity of any item of BOQ with respect to original BOQ quantities, the
following shall apply to the unit rate of that item: a) For rates quoted below CSR 2000 rates, no
change in quoted unit rate shall be allowed. b) For rates quoted above CSR 2000 rates, the quantity
exceeding 10% from original BOQ quantity of the items shall be paid to the contractor as per NHA
CSR 2000 rates applicable in the relevant district. Provided further that for non BOQ items appearing
in NHAs CSR 2000, CSR 2000 rates shall apply whereas the rates of non CSR & non BOQ items
shall be determined by the Engineer as stipulated in General Conditions of Contract." 2. The
Situation BOQ Item No.108b(i) Formation of embankment from roadway excavation in Rock material
(Hard Rock) and BOQ Item No. 106d(i) Excavate Surplus Rock material (Hard Rock) has increased
up to 453 % and 77.8 % respectively from the Original Billed Quantity and these Items are
individually accounting for more than 2.55% and 4.99 % respectively of the sum named in the Letter
of Acceptance. Therefore, we desire to request the Employer/The Engineer that the Unit Rates for
the said items as quoted in the BOQ for the entire quantity be changed and till the time new rates
are fixed, the provisional rates or prices be determined in accordance with CSR-2005 with 25%
Premium to enable on-account payment. 3.Questions a) Will the revision of rates be based on
composite schedule of rates 2005 (CSR- 2005) with 25% premium as requested by us? b) Are
sub- paragraphs a and b of the addition made in the said clause (refer to para 1 above ) applicable
to us as we consider that the said sub paragraphs are not relevant to us because our variation is
over 30%. c) Will Revised Rates be applicable to the entire quantity or only on varied quantity? d)
With so much variation, is it alright to ask for determination of Provisional rates?
ANSWER
As a general principle, FIDIC expressly prohibits users of its contracts to add and adjust Clauses in
the General Conditions. Any adjustments and changes should be made in the Particular Conditions.
However, since your Organization may not be responsible for misuse and breach of copyright we
shall attempt to help you. But here again, FIDIC is able to offer advice on interpreation of clauses,
but of course only on the clause of the contracts General Conditions, not on someone else's clauses.
This said, once again, we shall try to be helpful on the understanding that in future you try to impress
on clients that they should use the GCs correctly, and not risk legal action and contract invalidity
owing to breach of copyright. The changes to the GC mean that the interpretation of the FIDIC Subclause 52.2 may not be relevant to the amended contract. However the following may be helpful. a)
Impossible to answer because of the changes to the GC. b) Impossible to answer because of the
changes to the GC. c) Revised rates are normally only applicable to the additional quantity but this
depends on the circumstances and the make up of the revised rates. In determining revised rates
the Engineer should take all factors into consideration. d) The Contractor is entitled to be paid for
work done in accordance with Sub-Clause 60.2. If the revised rates cannot be agreed in time for the
next Interim Payment Certificate then the Engineer should determine provisional rates as the last
sentence of the first paragraph of Sub-Clause 52.2. If the final rate is different to this provisional rate
then Interim Payment Certificates can be corrected as Sub-Clause 60.4.
QUESTION
We are requesting a clarification of the intention of Clause 21.1 (b) Insurance of Works and
Contractor's Equipment of the FIDIC Civil Engineering Construction 1987 (4th Edition) Part1. There
appears to be a mixed Insurance market view as to whether the additional sum of "15% of such
replacement cost" for Professional Fees, Demolition and Removal of Debris applies to: (1) each of
these costs individually, or (2) as a combined amount, and (3) whether this amount should be
applied as a percentage of loss or a percentage of the sum insured (contract value). Our Contractors
are keen to have clarification.
ANSWER
The wording of Sub-Clause 21.1 (b) should be clear. The insurance shall cover the full replacement
cost as (a), plus an additional 15% of that figure. This additional 15% is to cover any additional and
incidental costs, INCLUDING professional fees etc. This figure may be changed in the Particular
Conditions and you should also refer to the FIDIC Guide to the 4th Edition, at page 72.
QUESTION
I am "The Engineer" of Project and have recommended re-rating of certain items of work under the
provisions of Clauses 52.2 of the Contract. I have however failed to understand from the given
provision is that: a) The Engineer shall evaluate at the time of Taking Over, if the Contract Cost has
increased or decreased () 15% of the original cost of contract, as a result of: i) all work executed &
measured is in excess of BOQ qualities. b) Then the Engineer shall determine such further "Sum"
that may be added or deducted from the contract price, taking into regard the Contractor's site and
general overhead costs of the Contract based upon only the amount by which such
additions/deductions will be in excess of 15% of the Effective Contract price. In my opinion the
Excess quantities of work have been taken care of by re-rating under Clause 52.2 and no further
Sum may be added to the Contract. Does the Clause 52.3 intend to apply the re-rating on quantities
that are more than 15%of the BOQ quantities thus re-rated. I quote an example: let us assume the
cost of Contract as USD 100000. A BOQ item costing USD 20000 is increased to value USD 50000
at contract rates. Hence re-rating under Clause 52.2 becomes applicable. On re-rating the value of
(original + increased) qty of work becomes USD 55000. Now the total value of contract, i.e., USD
55000. The value of work beyond 15% of contract price is $ 40,000. Is the Contractor entitled to
additional premium under Clause 52.3 for Executing work beyond 15% of Contract price. Is this what
is meant by the provision of the Clause 52.3?
ANSWER
Clause 52.2 refers to the re-rating of an individual variation. Clause 52.3 refers to the situation when
the total effect of all variations, plus the remeasurement of the approximate quantities in the BoQ
results in an increase or decrease of more than 15%. It is possible that each individual variation did
not have a significant effect on the Contractor's overheads but the total effect of all variations and the
remeasurement was significant. It is necessary to consider the actual effect of the additional
quantities on the Contractor's overheads. For example, part of the allowance for overheads may be
a fixed, or lump sum, figure which is not related to the quantity of work which has been carried out. A
substantial increase in the total quantity of work may not increase this part of the overheads. Hence,
the overheads per unit quantity would decrease. The allowance for overheads in the rates would
need to be reconsidered. Any re-rating under Clause 52.2 would be taken into account when
considering Clause 52.3. The Guide to the Fourth Edition published by FIDIC gives useful guidance
and examples at pages 115 and 117.
FREE HAULAGE
QUESTION
My inquiry is: are their any guidlines for maximum FREE HAULAGE distance ... for the TERM
BORROW materials to be engaged in EMBANKMENT CONSTRUCTION .... sinilarly....what free
distance limits are set/provided in FIDIC for any transportation of material .... from BORROW, from
the site of e.g., asphalt mixing or concrete mixing plant to the site of accomodating the finished
product in the road construction projects.
ANSWER
The FIDIC Conditions of Contract give the legal rights and obligations of the Parties to the Contract.
Matters such as the maximum free haulage distance will depend on the requirements and details of
the project. They will vary for different projects and should be given in the technical specifications
and/or bills of quantities.
ENFORCING A CLAIM
QUESTION
I am requesting an interpretation of Clause 63.2 and 63.3 of the FIDIC Red Book, 4th Edition. a)
When a Contractor has sums due to it arising out of a valuation under Clause 63.2 at the time of
termination, and the Employer/ Engineer delays certification of possible claims under Clause 63.3,
how does FIDIC envisage that the terminated Contractor may enforce its claim/obtain those sums
certified by the Engineer as being due to it? b) Once a new contractor has been engaged, is the date
scheduled for completion under the new contract relevant, and when is the new contractor liable for
further delays to the completion date? c) Is there a duty on the Employer or Engineer to inform the
first Contractor that the project has been completed? When the defects liability period is over? d) Is
there a duty on the Employer/Engineer to issue a certificate in accordance with Clause 63.3 within a
reasonable time? What may be considered a reasonable period for issuing such a certificate? e)
What are the possibilities for a Contractor to obtain the monies due under Clause 63.2 if the
Engineer fails to issue a certificate under Clause 63.3.?
ANSWER
This is really a legal question, but the key seems to be that the first sentence of Clause 67.1 says
that it continues after termination. A few additional comments may be helpful. One assumes the
enquiry is referring to the Fourth Edition, amended 1992, without any significant amendments.
Matters arising from termination under Clause 63.1 will depend on the provisions of the applicable
law as well as FIDIC Contract Clauses. Most legal systems include requirements for the termination
of a contract and also contain provisions based on the concept of "good faith" which may be
applicable. Any comments based on the FIDIC Contract must be reviewed in relation to the
applicable law, but some general comments may be helpful. a) Clause 67.1, first sentence, says that
it continues after termination. b) Clause 63.1 enables the Employer to "terminate the employment of
the Contractor". The Clause is clear that this does not release the Contractor from any of his
obligations or liabilities. So does the law require that the Employer also is not released from his
obligations? If so then other Clauses will also be relevant. c) The new contractor is presumably liable
for delays which he causes and which are not attributable to the previous contractor. d) Clause 1.5,
final sentence, requires that any consent, approval, certificate or determination shall not
unreasonably be withheld or delayed. e) Clauses 60.6 and 60.8 give time periods for the
Contractor's Final Statement and the Engineer's Final Payment Certificate. Clause 63.3 requires the
Engineer to issue a certificate, without stating a time period. By reference to Clause 1.5, this must be
issued in a reasonable time. Reasonable might be based on the Clause 60.6 and 60.8 time periods
unless there are special circumstances. f) It certainly seems necessary for the Contractor to be
informed, or his questions to be answered, in order that he knows when the construction and
Defects Liability Periods are completed. g) The Contractor's rights and procedures for obtaining
payment are covered by Clause 67 and the applicable law.
QUESTION
ANSWER
Under Sub-Clause 52.2, the Engineer only fixes a new rate or price when the BOQ rate or price has
become inappropriate or inapplicable for a particular Variation. In fixing the new rate or price he will
consider the reasons why the original rate or price should be changed. He will not fix a new rate or
price until he knows whether it involves an increase or decrease in quantity. The new rate or price
will probably be different for a decrease to that for an increase. It may be different for a large
increase to a small increase. The anomalies which you mention should not occur because the
Engineer will have considered these situations before he fixes the new rate or price.
QUESTION
A contract was drawn up for a specific length of highway. Re-alignment was required which
increased the length by a few kilometers. Should this additional work be included in a variation order
as per Clause 51 or should a seperate contract be floated. The contractor is asking for single
variation order with two different refixed rates (for the same item of BoQ ), one for the variation in the
original work and second for the additional work. I differ with his views. I feel that if one variation
order is considered for the whole work then only only one refixed rate for varied quantity can be
given. I require your advice on this issue.
ANSWER
If both the change to the original work and the additional work came from the same change of
requirement and instruction then it would be usual to issue a single variation order. However, it is
also quite normal for the price calculations for a variation order to include different rates for the same
BoQ item. The contractor's costs and the reasons why the BoQ rates are inappropriate may be
different for the varied work and for the additional work. It is then fairer and more transparent, to the
benefit of both parties, to negotiate different new rates.
QUESTION
A contract was drawn for a specific length of highway. Re-alignment was required which increased
the length by few kilometers.should this additional work be included in a variation order as per
Clause 51 or should a seperate contract be floated. The contractor is asking for single variation
order with two different refixed rates (for same item of BoQ),one for the variation in the original work
and second for the additional work. I differ with his views. I feel that if one variation order is
considered for the whole work then only only one refixed rate for varied quantity can be
given.irequire your advice on this issue.
ANSWER
If both the change to the original work and the additional work came from the same change of
requirement and instruction then it would be usual to issue a single variation order. However, it is
also quite normal for the price calculations for a variation order to include different rates for the same
BoQ item. The contractor's costs and the reasons why the BoQ rates are inappropriate may be
different for the varied work and for the additional work. It is then fairer and more transparent, to the
benefit of both parties, to negotiate different new rates.
QUESTION
We are executing a construction works project (18-floor tower), now there is an addition of two more
floors. I would like to know ... this addition would be dealt as a variation or separate contract
required, where we will have the liberty to revise the price, since this two floor's addition is less than
the 25 percent of the contract value, hence we dont have right to increase the price, incease if we
deal it by variation. please clarify.
ANSWER
Clause 51.1 allows the Engineer to issue instructions to vary the Works. Your question is whether the
additional two floors are just a change to the quantity of the work which is included in the Contract,
as Clause 51.1(a), or are outside the scope of the Works, which should be defined in the Contract.
The answer to your question therefore depends on the exact wording of the Contract Agreement, the
other contract documents and perhaps also the Tender Documents. It will also depend on the
interpretation of this wording in accordance with the applicable law. This is not something which
FIDIC can answer and you should obtain specialist advice.
QUESTION
We requested for the clarification regarding replies to a couple of questions which appear at the FAQ
Section of FIDIC website. Reply to the first question illustrates that under Sub Clause 52.2, Engineer
may fix a new rate or a price if the BOQ rate becomes inappropriate or inapplicable for a particular
variation, keeping in view the reasons for the change. In reply to the second question, FIDIC says
that the original quantity is not a part of the variation and cannot be paid at the revised rate. Replies
to the questions as noted above are contradictory to each other and we think that the matter should
further be clarified. Our elaborate note, which was submitted to this effect constitutes of our
understanding of the Clause 52.2 of the Red Book 4th Edition. The definition of the varied work
trickles to the Clause 52.2 from the Clause 51.1, which gives the definition/scope of the varied work
as following: (a) increase or decrease the quantity of any work included in the Contract, (b) omit any
such work (but not if the omitted works is to be carried out by the Employer or by another
contractor), (c) change the character or quality or kind of any such work, (d) change the levels, lines,
position and dimensions of ay part of the Works, (e) execute additional work of any kind necessary
for the completion of the Works, (f) change any specified sequence or timing of construction of any
part of the Works. The given definition thus holds that the varied work may not essentially comprise
of only the change in the quantity of certain item included in the contract. Varied work may also arise
out of the virtue of other reasons as noted above. Hence, restricting the definition of variation only to
the change in quantity may not be appropriate. The reply given at the FIDIC website to the first
question, as has been referred above, seems to hold the same view by the virtue of which the
decision to this effect has been left to the Engineer. However, the reply to the second question
forwards rather a restrictive interpretation of the Clause 52.2 by saying that a new rate would apply
only to the increased/decreased quantity. Such an interpretation falls in contradiction to the definition
of the varied work as well as the open ended spirit of the FIDIC Document in general and that of the
Clause 52.2, read in conjunction with the Clauses 51.1, 51.2 and 52.1 there-before, as well as that of
the Clauses 52.3 and 52.4 thereafter. ..... FIDIC's initial reply: FIDIC can only comment in general
terms on the interpretation of a FIDIC clause. If you require a more detailed opinion on the
application of a clause to a particular problem situation then you should consult a specialist. The
examples in your letter illustrate the wide range of situations which may arise on a project and result
in the application of Clause 52.2. For this reason, the clause cannot restrict the Engineer in the way
he calculates a new rate. The Engineer is aware of the exact situation and so can make the
appropriate decision to suit the wording and application of the Variation. A Variation normally, but not
always, only applies to work which has not yet been executed. If somew ork has already been
carried out on the same basis as was envisaged for the original bill rate then that work would
normally be valued at the bill rate. However a particular Variation, such as a decrease in
quantity,may be worded in such a way as to require a different approach. ........ Your reply also
narrates that our understanding of the issue falls closely to a certain project specific legal opinion.
We believe that such a concurrence on the matter has become evident only because of the proper
understanding of the rationale. This particularly holds when we also consider the possibility of
variation because of the decrease in the quantity of certain items of work. No logic would allow that
the decreased quantity which is not executed may be paid at some revised rate fixed by the
Engineer. The revised rate would certainly apply to the quantity executed. The rationale thus
demands the same treatment for fixing of the rate by the Engineer in case of variation in the quantity
of certain items of the work because of an increase, giving an obvious reason of our understanding
of the matter in line with the legal opinion in the similar context. Your reply dated 7th June 2007
further seems to acknowledge that the exact situation under such a case may only be determined by
the Engineer through an appropriate decision, as has been provided under the spirit of the FIDIC
Document. However, the comments thereafter, once again seem to restrict the definition of variation.
So, to continue: regarding fixing of a new rate (Red4: 52.2) Regarding our query regarding re-rating
of the varied quantity. We seek the clarification regarding the opinion of FIDIC on re-rating of the
varied quantity, as shown in the FAQ Section of the FIDIC website. Our debate/discussion as
appended with our query is only meant to express our understanding that the Sub-Clause 52.2 only
talks of the "varied work" and not the "varied quantity", which, however, remains subservient to the
definition of "varied work". The actual intention of our query thus remains to seek the clarification in
light of the Sub-Clause 52.2 of Civil Works contract 4th Edition, 1987. To this effect, it may be
deemed appropriate that the writers of this particular clause or the related backup material may be
consulted so that the ambiguity or the confusion, as has arisen regarding the varied work through
the opinion of FIDIC in the FAQ section, may be removed and the prestige of the organization like
FIDIC, which is considered as an apex body in contract administration, would be maintained.
ANSWER
Thank you for your more detailed explanation of your query. Our replies to previous questions were
in response to particular questions, whereas your question is rather different. You are, of course,
correct that Variations under Sub-Clause 52.1 can cover a wide range of situations, including
changes to the nature as well as to the quantity of an item of work. For this reason, Sub-Clause 52.2
must be general to cover the wide range of potential situations. It is then for the Engineer to assess
the particular situation and to agree or fix an appropriate rate. In deciding the quantum, and also the
application, of this rate the Engineer would take into account the consequences of a change in
nature as well as a change in quantity. You should also note the explanatory remarks in the FIDIC
Guide to the use of the FIDIC Conditions of Contract for Works of Civil Engineering Construction.
Sub-Clauses 52.1 and 52.2 are reviewed at pages 114 and 115 of the Guide and include the
statement: If the nature or amount of the work involved differs so much from that included in the
original Contract that the rates and prices are rendered inapplicable, it is the Engineer's task to
agree appropriate rates and prices with the Contractor, or, if agreement cannot be reached, to fix the
rates and prices. We trust this further explanation will answer your query. Any further comments
would require details of the specific contract and problem, which FIDIC could not consider.
QUESTION
Can you please identify what is meant by "without undue delay" under Red Book 4th Edition clause
44.3 considering that the Contractor and the Engineer have mutually agreed, under cl. 44.2(b), to
submit detailed particulars every first week of the month and noting that every month the contractor
is submitting the same. What is the duration needed by engineer to provide his interim/final
determination of extension of time claims under this clause?
ANSWER
Your question refers to Sub-Clause 44.3 in the Red Book, Fourth Edition 1987. Sub-Clause 44.2 has
imposed time limits for the submission of information by the Contractor, which you say have been
agreed. FIDIC does not impose a time limit on the Engineer because the actual time needed for him
to make his determination will depend on the circumstances and the details in the information
provided by the Contractor. However the "without undue delay" emphasises the need for the
determination to be made as soon as possible. Sub-Clause 1.5 also requires that any determination
"shall not unreasonably be withheld or delayed". This gives the Contractor the opportunity to raise a
query if he needs the determination in order to plan his work.
QUESTION
Concerning Clause 63.2 and 63.3 of the FIDIC Red Book 4th Edition . The Contract was terminated
by the Employer pursuant to Clause 63.1 (this is undisputed). It was agreed that the additional costs
to the Employer of executing the works by an alternative contractor has to be deducted from the
value of the works executed by the first Contractor. The wording of Clauses 63.2 and 63.3 was not
changed or amended. Contractor now requests a payment from the Employer calculated pursuant to
a Clause 63.2 valuation. In addition Contractor states that the whole of the Works has not completed
and, therefore, the Defects Liability Period has not expired, which is a precedent to any certification
of Employer's costs under Clause 63.3. Therefore, an Employer's application for Clause 63.3 costs is
premature, cannot be considered and Contractor is entitled to request a payment based on the
calculated Clause 63.2 valuation without any deduction pursuant to Clause 63.3. a) Is a contractor
entitled to ask for a payment based on a Clause 63.2 valuation, since an employer is not obliged to
make any further payment until the expiration of the Defects Liability Period? b) Is it correct to
interpret that Contractor's request for payment based on Clause 63.2 is not (currently) justified also
in cases, where a completion of the project was delayed due to circumstances caused by an
alternative contractor or the employer, if the terminated and requesting Contractor itself has formally
and explicit pleaded that the whole project is not completed without complaining the delay of
completing the project caused by the alternative contractor or the employer? c) Can the Contractor
simultaneously refer to and request a Clause 63.2 calculated claim and reject (alleged) unmatured
Employer's Clause 63.3 costs, if both clauses were agreed?
ANSWER
This is a complex technical/legal question arising from a specific request by the Contractor on your
project. FIDIC can only answer general questions of interpretation and cannot comment on specific
requests or claims. The FIDIC Guide to the Fourth Edition states at page 146 for Sub-Clause 63.3:
"If the Employer terminates the Contractor's employment, he is not liable to pay the Contractor any
further amounts (including damages) until the expiration of the Defects Liability Period and the
certification by the Engineer of the cost of execution and remedying of any defects, damages for
delay in completion (if any) and other expenses incurred by the Employer as a result of the
Contractor's default."
QUESTION
We are seeking a defintion as to when payment is actually made by the employer to the contractor.
Is it when the employer issues his payment instruction to his bank, or is payment deemed to be
made once the monies are received in the contractor's bank account. Are there FIDIC guidelines on
this matter?
ANSWER
your query is really a general legal question about when a payment is "made", rather than a question
of interpretation of a FIDIC contract. The answer may be different under different jurisdictions. You
should consult a lawyer with experience of the applicable law.
STATUTORY DECLARATION
QUESTION
My firm is executing a Contract with FIDIC terms and conditions and I require a Statutory Declaration
document for international use (Project location is Madagascar). Can you please advise where I can
find this in your documentation, or better yet can you e mail me the appropriate document.
ANSWER
Your Statutory Declaration would seem to conflict with the principles of the FIDIC Contracts.
Progress payments are referred to as 'interim', which suggests that they are provisional and not final.
EPCT Sub-Clause 14.6 allows the Employer to make corrections or modifications to previous
amounts considered due, which suggests that the Contractor can request modifications to a previous
valuation. It is only the requirement for the Application for the Final Payment, as Sub-Clause 14.11,
which uses words indicating finality. The Contractor then confirms the finality by his Discharge, as
Sub-Clause 14.12. The equivalent provision in the 1987 Red Book was Sub-Clause 60.7. The
Standard Letter for that Sub-Clause merely repeated the wording of the Sub-Clause. However, this
was a contractual letter and not a Statutory Declaration. A Statutory Declaration will presumably be
issued by the Government and will depend on the requirements of the applicable law, which will vary
for different countries.
QUESTION
In the 1992 reprinted version of the 1987 FIDIC Conditions as well as in the 1999 FIDIC Conditions it
is, in the relevant DAB Clauses, stated that the Contractor, Employer and Engineer shall give effect
forewith to every decision of the Board unless and until the decision is revised in an amicable
settlement or an arbitrational award. On the other hand it is stated that a Board decision becomes
FINAL and BINDING unless either party gives a notice of dissatisfaction within 28 days after
receiving the Board decision. A very basic legal principle is that only final and binding decisions are
enforceable. Are the FIDIC conditions really based on the very unusual principle that the Employer
has, on basis of un unbinding Board decision, to pay to the Contractor a compensation with the
consequence of running the risk of never being able to recover the paid amount from a foreign
contractor when the revised arbitration award is issued (long) after the completion of the works.
Please clarify whether the Employer has to pay a monetary compensation on basis of a Board
decision, which is NOT FINAL AND BINDING.
ANSWER
Sub-Clause 20.4 of the 1999 Contracts is clear that both parties shall promptly give effect to the DAB
Decision. The Employer must pay any sum awarded to the Contractor although the sum to be paid
may be changed by a later amicable settlement or arbitration. If a Notice of Dissatisfaction has been
issued then the dispute, not the DAB decision, may be reopened and finally determined by the
Arbitral Tribunal. The sum to be paid may then be increased, or decreased, and additional money
may need to be paid, or money may need to be repaid. An Arbitral Award, including such further
payment or repayment, would be Final and Binding and would be covered by arbitration law and the
New York Convention. It is normal practice that a DAB or Adjudicator's Decision is Binding and so
must be paid, but is not Final and so may be changed in this way. If no Notice of Dissatisfaction has
been issued then the DAB Decision becomes Final as well as Binding and the dispute cannot be
reopened.
QUESTION
Can you please advise how to calculate the lump sum to be added or dedcuted to the contract price
when the effective contract price execceds 15%. In addition, please advise on when do we deduct,
and when do we add such amount.
ANSWER
Commentary at page 117 of the FIDIC Guide to the 4th Edition is recommended. The Guide explains
that some of the Contractor's overhead costs are included in the rates for items of work and others
are included in separate items in the Bill of Quantities. Changes to the actual quantities may mean
that the overhead content of items which have paid is not appropriate to the actual overhead costs
incurred by the Contractor. In order to calculate any adjustment the Engineer will need to obtain
information from the Contractor, or would have to make his own assessment. Any calculation must
take into account any adjustment which has already been made under another Sub-Clause and only
applies to any increase or decrease in excess of 15% of the Effective Contract price. The SubClause starts with a reference to the situation "on the issue of the Taking-Over Certificate for the
whole of the Works". It is also necessary for the value of variations and other adjustments to have
been agreed in order to make the Sub-Clause 52.3 calculations. Any additional payment or
deduction would then be made in the next payment certificate after the figures have been agreed or
determined.
QUESTION
I am "The Engineer" for a road construction project. A difference of opinion has arisen on the
applicability of new rates fixed by the Engineer on the quantities, i.e whether the new rate will be
applicable only on the enhanced quantity beyond the original BoQ quantity, Oor it shall apply on the
entire quantity. To explain this further, the BoQ quantity for piles was 2000 cu m. The designer
increased the number of piles so that the quantity became 3000 cu m. The Engineer fixed a new rate
for pile work from X to Y. Will Y rate be applicable to enhanced quantity of 1000 cu m , or should it
apply to 3000 cu m?
ANSWER
FIDIC can only comment in general terms on the interpretation of a FIDIC clauses, and it should be
noted that for the application of a clause to a particular problem situation, one should always consult
a specialist. With that being said, in general, Sub-Clause 52.2 gives the power to the Engineer to fix
new rates and states the conditions when such new rates may be fixed, but Sub-Clause 52.2 does
not indicate a calculation method or the applicability for new rates. The reason for this is because
Sub-Clause 52.2 must allow for covering a wide range of potential situations. So, although it is true
that revised rates are normally only applicable to the additional quantity, it is for the Engineer to
assess the particular situation and circumstances surrounding, and to take all factors into
consideration in making his determination regarding the quantum and applicability of the new rates
fixed under Sub-Clause52.2. For reference, see page 127-128 of the FIDIC Red Book Guide to the
use of the FIDIC Conditions of Contract for Works of Civil Engineering Construction, and please note
that the above represents a general answer only, and specific advice to the particular facts
surrounding your situation, we recommend that you consult a specialist.
Privacy policy
Copyright
General Conditions
Contact
FIDIC World Trade Center II Geneva Airport Box 311 29 route de Prs-Bois CH-1215 Geneva 15 Tel
+41-22-799 49 00 Fax +41-22-799 49 01 Email fidic@fidic.org
ShareThis Copy and Paste
- See more at: http://fidic.org/node/911#sthash.z35T5XMH.dpuf