On GCC For Service Contract

Download as pdf or txt
Download as pdf or txt
You are on page 1of 37

GCC for Services

Eligibility of Bidders and Evaluation of Bids.

Bid Documentation.

General Obligations.

Variation, Measurement and Payment.

Labour Laws and Related Obligations.

Determination of Contract.

Settlement of Disputes- Indian Railway Arbitration Rules.

Annexures
II. Eligibility of Bidders and Bid Evaluation.
2.1.1- Essential elements of a service contracts:

Service contracts are generally defined by –

Scope
Governance
Operations
Financial Agreements
Performance and Implementations

Quality of services and timely availability of service is


essential for the satisfactory performance of a service
contract.
2.6.1- Minimum Eligibility Criteria for
Single/two packet System in Services
Contract:
Work experience:- The bidder should have satisfactorily
completed* in the last three previous financial years and the
current financial years up to the date of opening of the
tender, one similar single service contract** for a minimum
of 35% of advertised value of the bid.

*Completed service contract includes ongoing service contract


subject to payment of bills amounting to at least 35% of the
advertised value of the bid.

** Similar service contract means any contract that is so specified by the


competent authority

3/1/2022 IRIMEE JAMALPUR 4


2.6.1- Minimum Eligibility Criteria for Single/two
packet System in Services Contract:

Financial Standing: The Bidders will be qualified


only if they have minimum financial capabilities as
below: -

• (i) T1- Financial Turnover: - The bidder should have an


aggregate financial turnover not less than 1.5 times of
advertised Bid Value during the last three previous
financial years and in the current financial year up to the
date of opening of the tender.
• (ii) T2 Liquidity: The bidder should have access to or
has available liquid assets, lines of credit and other
financial means to meet cash flow that is valued at 5% of
the estimated bid value net of applicant's commitments
for other contracts.
3/1/2022 IRIMEE JAMALPUR 5
Eligibility Criteria for Two packet System
in Services Contract:

2.6.2- Evaluation
of Technical Bid

To scrutinize the capability, financial


strength, experience etc. of bidders.

Technical criteria & minimum qualifying


marks to be defined

2.6.3 - Evaluation of Financial Bid

3/1/2022 IRIMEE JAMALPUR 6


Tenderer Credentials:
• A copy of an affidavit on stamp paper to the effect that all the
documents submitted by her bid are true. This shall be mandatory
in all bids. The bid shall be summarily rejected if the bidder fails to
submit this undertaking along with the bid.
• The Railway reserves the right to verify all statements, information
and documents submitted by the bidder in his tender offer, and the
bidder shall, when so required by the Railway, make available all
such information, evidence and documents as may be necessary
for such verification. Any such verification or lack of such
verification, by the Railway shall not relieve the bidder of its
obligations or liabilities hereunder nor will it affect any rights of the
Railway thereunder.

3/1/2022 IRIMEE JAMALPUR 7


Partnership Deeds, Power of Attorney
etc.:
Documents to be Submitted Along
with Tender

Sole LLP
Proprietor Partnersh Registere (Limited
HUF ip Firm Company d Society Liability
ship Firm
/JV & Trust Partnersh
ip)

The power of attorney shall be submitted even if such specific person is


authorized for above purposes through partnership deed/Memorandum of
Understanding/Article of association or such other document, failing which
tender is liable to be rejected.

3/1/2022 IRIMEE JAMALPUR 8


Disqualification of Bidders:
Employment/ Partnership etc of Retired Railway
Employee –
(a) & (b) Engineer or officer not retired from government
service at least 1 year prior to the date of submission
of the tender.

(c) a relative(s) employed in gazetted capacity in the


Engineering or any other department of the railway or
having share of more than 1% in the tendering entity.
Bids without the information above referred to or a
statement to the effect that no such retired Manager or
Guzetted officer is so associated with the Bidder

3/1/2022 IRIMEE JAMALPUR 9


JOINT VENTURE (JV)

2.4.1.2 The other


Number of
Lead members shall
shall not Member have a share of
2.4 members not less than
be more shall have
Participati in a JV 20% each in
than five, if a
on of Joint 2.4.1.1 shall not case of JV with
the work
Venture Separate be more majority up to three
involves members and
(JV) firms identity/na than three, (at least
more than not less than
in Service me if the work 51%)
one 10% each in
Tender involves share of
Departmen case of JV with
bids: only one interest
t. more than
departmen three
t
in the JV.
members.

3/1/2022 IRIMEE JAMALPUR 10


JOINT VENTURE (JV)
Tender form shall be purchased and submitted only in the
name of the JV
Memorandum of Understanding (MoU)

Credentials & Qualifying Criteria: Technical, financial eligibility


and Bid capacity of the JV
Technical Eligibility Criteria (‘a’ or ‘b’ mentioned hereunder):

(a) For Services without composite components

(b) For Services with composite components

3/1/2022 IRIMEE JAMALPUR 11


Partnership Firms

3/1/2022 IRIMEE JAMALPUR 12


Qualification Criteria
Disqualification of Bidders

• Single Packet System- for bid


value up to and including Rs. 50
lakh (As decided by Rly Bd from
time to time).
Bid Evaluation • Two Packet System:- Bid value
System exceeding Rs. 50 lakh.
• Quality and Cost Based System
(QCBS):- used for consulting
services having bid value
exceeding Rs. 50 Lakh.

3/1/2022 IRIMEE JAMALPUR 13


III. Bid Documentation:
Earnest Money:3.3
Earnest Money Deposit (EMD)
Value of the Work

For works
estimated to cost
2% of the estimated cost of the work
up to ₹ 1 crore

₹ 2 lakh plus ½% (half percent) of


For works estimated
the excess of the estimated cost of
to cost more than
work beyond ₹ 1 crore subject to a
₹ 1 crore
maximum of ₹ 1 crore
e-Tender Forms shall be issued free of cost to all
tenderers.
3/1/2022 IRIMEE JAMALPUR 14
Earnest Money:
Shall be rounded off to the nearest ₹10.
Any firm recognized by Department of Industrial Policy
and Promotion (DIPP) as ‘Startups’ shall be exempted
100% Govt. owned PSUs shall be exempt
Labour Cooperative Societies shall deposit only 50% of
above earnest money deposit detailed above.
Note: Vide Rly.Bd.L.No.2020/CE-I/CT/3E/GCC/Policy dt 30.12.2020- Rly.
Bd. has advised to take ‘Bid Security Declaration’ in lieu of ‘Bid
Security/ Earnest Money Deposit’ except wherever compelling
circumstances to ask for Bid Security/Earnest Money Deposit.

3/1/2022 IRIMEE JAMALPUR 15


Care in Submission of Bids:
Clause 3.4

All conditions liable to be encountered during the


execution of the works has been taken into account.

The rates he enters in the tender forms are


adequate and all inclusive (Clause 37)

(CGST)/ (IGST)/ (UTGST)/ (SGST)

Signed by the individual legally authorized

3/1/2022 IRIMEE JAMALPUR 16


Care in Submission of Bids:

• The tenderers shall submit a copy certificate


stating that all their statements/documents
submitted along with bid are true and factual.
• Standard format of certificate to be submitted
by the bidder is enclosed as Annexure-V.
• Non submission of certificate by the bidder
shall result in summarily rejection of his/their
bid.
• Must submit supporting documents duly self
attested by which they/he is qualifying the
Qualifying Criteria mentioned in the Tender
Document.

3/1/2022 IRIMEE JAMALPUR 17


3.5 Execution of Contract Documents:
The Bidder whose bid is accepted required to appear in
person/representative in concerned office within 7 days
after receipt of notice. In case failure bidder may has
abandoned and earnest money/PG forfeit.

• 3.6 Forms of Contract Documents:


Atleast 03 Copies - Contractor
- Finance Department
- Contract manager

NOTE: Specimen Bid and Agreement Form are at Annexure II &


III in GCC for Services.

3/1/2022 IRIMEE JAMALPUR 18


4.11 Performance Guarantee in service
contract:
amounting to 10 % of the contract value in four separate parts of 2.5 % each
of contract value

within 30 (Thirty) days from the date of issue of Letter of Acceptance (LOA)

PG beyond 31 (Thirty one) days and up to 90 days -a penal interest of 15% per annum
but a notice to be served after 60 days .

after 90 days from the date of issue of LOA- the contract is liable to be terminated

Validity of PG – up to the stipulated date of completion plus 60 days beyond that


variation up to 25% (either increase or decrease / No addl. PG).An additional 10% PG
in 4 equal installment on excess value of the contract to be deposited by the
contractor.
Shall be released after physical completion of work. 25 % of PG would be retained till
the warranty/maintenance.

If the penalty imposed exceed 50 % of the applicable maximum penalty, a PG


equivalent to 25 % of the applicable PG shall be forfeited. If penalty exceeds 75 %- a
PG equivalent to 50 % shall be forfeited.
3/1/2022 IRIMEE JAMALPUR 19
The successful bidder shall submit the PG in any of the
following forms, amounting to 10% of the contract value:
• A deposit of cash.
• Irrevocable Bank Guarantee.
• Government Security including State Loan Bonds at 5%
below market value.
• Deposit Receipts, Pay Orders, Demand Drafts, and
Guarantee Bonds of SBI or any Nationalized Bank.
• A Deposit in the Post Office Savings Bank.
• A Deposit in the national Saving Certificates.
• Twelve Years National Defence Certificates
• Ten Years Defence Deposits.
• National Defence Bonds.
• UTI Certificates at 5% below market value etc.

3/1/2022 IRIMEE JAMALPUR 20


V - Variation, Measurement and Payments:
5.1 Extension of Time in Contracts

Extension of Time in Contracts:


(i) 5.1.1 Extension due to Modification
(ii) 5.1.2 Extension for Delay not due to Railway or
Contractor: external factor
(iii) 5.1.3 Extension for Delay due to Railways

5.2 Extension of Time with Liquidated Damages (LD)


for delay due to Contractor:
• time is essence of the contract
• 0.10% of the contract value of the service for each week or part of
the week may be recovered from the contractor for further
extension .(Manager’s decision)
• LD maximum 5 %

3/1/2022 IRIMEE JAMALPUR 21


VARIATIONS IN EXTENT OF CONTRACT
5.3 Modification to Contract to be in Writing:

5.3.1 Powers of Modification to Contract:

individual item
variation in quantity of each individual item of the contract would be up
to 25% of the quantity
Quantities operated in excess of 125% but up to 140% of the agreement quantity
Quantities operated in excess of 140% but up to 150% of the agreement
quantity
Variation in quantities of individual items beyond 150%

Minor Value Item

overall agreement value


“No Claim” certificate to be obtain by the Railway after final measurement to the
contractor to debarred from disputing and correctness of the items covered.
Details mentioned in SOP 2018 Part-A Works/Service matter, item
no. 9
3/1/2022 IRIMEE JAMALPUR 22
3/1/2022 IRIMEE JAMALPUR 23
3/1/2022 IRIMEE JAMALPUR 24
3/1/2022 IRIMEE JAMALPUR 25
3/1/2022 IRIMEE JAMALPUR 26
5.5 MEASUREMENTS

Measurement
5.5.1 Quantities in Schedule
of Works by Annexed to Contract .
Railway: 5.5.2 Measurement of
Services/Works- Check list or
any other methodology
provided in bid document.

3/1/2022 IRIMEE JAMALPUR 27


5.7 - Price Variation Clause
(PVC) in service contract:
5.7.1 Applicability: where delivery periods extend beyond 18 months.

46A.2 Base Month:

Month of opening of tender


The quarter for applicability of PVC shall commence from the month following the month
of opening of bid . The Price Variation shall be based on the average Price Index of the
quarter under consideration.
5.7.5 Components on which variation in prices be admissible, shall be Material,
Labour, Fuel etc.
However, for fixed components, no price variation shall be admissible.

5.8 Price Variation during Extended Period of Contract

3/1/2022 IRIMEE JAMALPUR 28


VI- LABOUR
54. Wages to Labour: as per provision of the Minimum Wages Act, 1948

55. Provisions of Payments of Wages Act, 1936

55-A. Provisions of Contract Labour (Regulation and Abolition) Act,


1970 and the Contract labour (Regulation and Abolition) Central
Rules 1971 as modified from time to time
55-B. Provisions of Employees Provident Fund and Miscellaneous
Provisions Act, 1952

55-C(i) website ‘www.shramikkalyan.indianrailways.gov.in’

60.(1) Non-Employment of Laborers below the age of 18.

3/1/2022 IRIMEE JAMALPUR 29


VII-DETERMINATION OF CONTRACT
• owing to paucity of funds or from any
7.1 Right of other cause whatever
Railway to • Notice in writing from the Railway of
Determine the such determination and the reasons
Contract: therefore shall be conclusive evidence
thereof

7.2 Payment on • Railways shall admit and consider


such claims as are deemed reasonable
Determination and are supported by vouchers to the
of Contract: satisfaction of the Manager.

3/1/2022 IRIMEE JAMALPUR 30


DETERMINATION OF CONTRACT:

7.4 Determination of Contract owing to Default of


Contractor:

Performance Notice as per Performa at Annexure-XII

Seven Days Notice as per Performa at Annexure-XIV

Final termination notice as per Performa at Annexure-XV

3/1/2022 IRIMEE JAMALPUR 31


3/1/2022 IRIMEE JAMALPUR 32
3/1/2022 IRIMEE JAMALPUR 33
3/1/2022 IRIMEE JAMALPUR 34
DETERMINATION OF CONTRACT:

7.4 - Right of Railway after Rescission of


Contract owing to Default of Contractor:
The balance The failed
work shall be Contractor shall
No claim to
got done be debarred
compensation PG shall be
independently from
for any loss enchased/
without risk & participating in
sustained by forfeited
cost of the the tender for
Contractor
failed executing the
Contractor. balance work.

3/1/2022 IRIMEE JAMALPUR 35


DETERMINATION OF
CONTRACT
7.4 - In the contract rescinded in part or
parts

The failed
The balance
The defaulting Contractor
The full work shall be
Contractor shall be
Performance got done
shall not be debarred from
Guarantee for independently
issued any participating
the contract without risk &
completion in the tender
shall be cost of the
certificate for for executing
recovered. failed
the contract. the balance
Contractor.
work.

3/1/2022 IRIMEE JAMALPUR 36


3/1/2022 IRIMEE JAMALPUR 37

You might also like