W E S T

AT SECTOR 76 & 77, GURUGRAM

APPLICATION FORM

HARERA Registration No. RC/REP/HARERA/GGM/819/551/2024/46 dated: 22.04.2024 | https://haryanarera.gov.in

Promoter: DLF LIMITED

 APPLICATION FOR ALLOTMENT OF A RESIDENTIAL APARTMENT IN DLF PRIVANA
WEST, SECTOR 76 & 77, GURUGRAM (HARYANA)

HRERA Registration No. RC/REP/HARERA/GGM/819/551/2024/46

dated: 22.04.2024 |https://haryanarera.gov.in
DLF LIMITED
Registered Ofce:
Shopping Mall 3rd Floor Arjun Marg,
Phase I DLF City, Gurugram,
Haryana 122002
Dear Sir/ Ma'am,
1. The Applicant(s) understands that DLF Limited (“Promoter”) and land owners are the
absolute and lawful owners of land admeasuring 470,633.479 square meters
(116.29625 acres) situated at village Shikopur and Kherki Daula, Sector 76-77, in
Gurugram Manesar Urban Complex, District Gurugram, Haryana (hereinafter
referred to as the “Licensed Land”) vide sale deed(s) registered at the ofce of the Sub-
Registrar. The land owners and the Promoter have entered into development
agreements with respect to the land respectively owned by them and forming part of
the Licensed Land, registered at the ofce of the Sub-Registrar. The Licensed Land has
been granted license for the purpose of development of residential colony under the
name of ‘DLF Privana’ (“Colony”). The residential colony on the Licensed Land i.e. DLF
Privana is being developed in a phased manner and the Promoter has earmarked an
area admeasuring 50,876.998 sq. mts. (12.572 acres) (“Said Land”) in the Licensed
Land for the purpose of development of an independent phase comprising of 5 multi
storied building(s) inter alia the Nursery School, etc. and the said phase shall be
known as ‘DLF Privana West’ (“Project”), which is the subject matter of this
Application. The Site/Location plan is annexed herewith as Schedule-A.
2. The Promoter has registered the Project under the provisions of the Real Estate
(Regulation and Development) Act, 2016 (“Act”) with the Real Estate Regulatory
Authority (“Authority”) at Gurugram, Haryana on 22.04.2024 under registration
number RC/REP/HARERA/GGM/819/551/2024/46.
3. The Applicant(s) request(s) the Promoter for the allotment of a residential apartment
in the Project having Carpet Area of approx. _______________ square meters
(______________sq. ft.) on _______ oor in ______ Tower no._____ (“Building”) along with
parking slot No(s). ______ , _______ and ______ located in _______ admeasuring approx.
______ square meters (_________square feet), ______ square meters (_________square
feet) and ______ square meters (_________square feet) in the _______________ as
permissible under the applicable law and right in the common areas (“Common
Areas”) as dened under Rule 2(1)(f) of Rules, 2017 of the State (hereinafter referred to
as the “Said Apartment”).
4. The Applicant(s) fully acknowledges that the Promoter has provided all the
information and clarications as required by the Applicant(s) and the Applicant(s) is
fully satised with the same. The Applicant(s) has fully acquainted himself with all the
particulars of the Project, as has been provided by Promoter on the ofcial website of
the Authority established as per the provisions of the Act (hereinafter dened) and

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

01
 Rules (hereinafter dened). The Applicant(s) has also satised himself/herself in
respect of the sanctions and building plan approvals based on which the Project is
being constructed.
5. The Applicant(s) states and conrms that the Promoter has made the Applicant(s)
aware of the terms and conditions of the Agreement for Sale (“Agreement”) available on
the ofcial website of the Promoter https://www.dlf.in/homes/luxury/privanawest,
ofcial website of the Authority and at the ofce of the Promoter. The Applicant(s)
conrms that the Applicant(s) have read and perused the Agreement containing the
detailed terms and conditions as per the applicable law. The Applicant(s) further
conrm(s) to have fully understood the terms and conditions of the Agreement and is
agreeable to perform his/her obligations as per the conditions stipulated in the
Agreement. Having understood and agreed, the Applicant(s) has/ have applied for
allotment of a residential apartment in the Project and has requested the Promoter to
allot the Said Apartment therein.
6. The Applicant(s) hereby conrms that he/she is signing this Application with full
knowledge of all the laws, rules, regulations, notications, etc., applicable in the State
of Haryana in relation to the Project. No oral or written representations or statements
shall be considered to be a part of this Application and that this Application is self-
contained and complete in itself in all respects.
7. The Applicant(s) has clearly understood that by submitting this Application, the
Applicant(s) does not become entitled to the nal allotment of the Said Apartment in
the Project, notwithstanding the fact that the Promoter may have issued a receipt in
acknowledgement of the money tendered with this Application by the Applicant(s).
8. Through this Application, the Applicant(s) requests the Promoter that the
Applicant(s) may be allotted the Said Apartment in the Project as per the Payment
Plan opted below.
Down Payment Plan Installment Payment Plan
9. The Applicant(s) encloses herewith a sum of Rs.__________________/- (Rupees _______
__________________________________________________________________________only) by
Bank Draft/Cheque No._____________________ dated _________________drawn in
favour of the Promoter payable at ______________________________________ or through
Electronic Transfer in account no. _________________, maintained with _______________
Bank, in _________________________ Branch, bearing IFSC Code ____________________,
towards part payment of the Booking Amount (as dened hereinafter). The
Applicant(s) agrees that the aforesaid payment which forms a part of the Booking
Amount shall be adjusted as part payment towards the Total Price (as dened below),
of the Said Apartment.
10. The Applicant(s) agrees that if the Promoter allots the Said Apartment, then the
Applicant(s) agrees to pay the Total Price of the Said Apartment as per the Payment
Plan annexed hereto as Schedule-C.
11. That the Applicant(s) understand that by just forwarding the Agreement to the
Applicant(s) by the Promoter, does not create a binding obligation on the part of the
Promoter or the Applicant(s) until, rstly, the Applicant(s) signs and delivers the

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

02
 Agreement with all the schedules along with the payments due as stipulated in the
Payment Plan within 30 (thirty) days from the date of receipt by the Applicant(s) and
secondly, the Applicant(s) and the Promoter execute and register the Agreement as
per the provision of the relevant Act of the State.
If the Applicant(s) fails to execute and deliver to the Promoter the Agreement within
30 (thirty) days from the date of its receipt by the Applicant(s) and further execute the
said Agreement and register the said Agreement before the Sub-Registrar, then the
Promoter shall serve a notice to the Applicant(s) for rectifying the default, which if not
rectied within sixty (60) days from the date of its receipt by the Applicant(s), the
application/allotment of the Applicant(s) shall be treated as cancelled and all sums
deposited by the Applicant(s) in connection therewith including the Booking Amount
shall be returned to the Applicant(s) without any interest or compensation
whatsoever. If, however, after giving a fair opportunity to the Applicant(s) to get the
Agreement executed, the Applicant(s) does not come forward or is incapable of
executing the same, then in such a case the Promoter has an option to forfeit the
Booking Amount.
12. Notwithstanding anything contained in this Application, the Applicant(s)
understands that this Application(s) will be considered as valid and proper only on
realization of the amount tendered with this Application.
13. The Applicant(s) agrees to abide by the terms and conditions annexed hereto in this
Application, and the terms as laid down in the Agreement.
1. SOLE OR FIRST APPLICANT(S)

Title Mr. Ms. M/s.

Name ________________________________________________________

Son / Daughter / Wife of ______________________________________

Nationality__________________________Age_______years__________

Profession__________________________Aadhar No.________________

Residential Status: Resident/ Non-Resident/ Foreign National of Indian Origin

_________________________________________________________________________________

Income Tax Permanent Account No._______________________________________________

Ward / Circle / Special Range / Place, where assessed to income tax_________________

Mailing Address__________________________________________________________________

_________________________________________________________________________________

Tel No._________________________________Mobile No.________________________________

E-mail ID:________________________________________________________________________

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

03
2. JOINT/SECOND APPLICANT(S)

Title Mr. Ms. M/s.

Name ________________________________________________________

Son / Daughter / Wife of ______________________________________

Nationality__________________________Age_______years__________

Profession__________________________Aadhar No.________________

Residential Status: Resident/ Non-Resident/ Foreign National of Indian Origin

_________________________________________________________________________________

Income Tax Permanent Account No._______________________________________________

Ward / Circle / Special Range / Place, where assessed to income tax_________________

Mailing Address__________________________________________________________________

_________________________________________________________________________________

Tel No._________________________________Mobile No.________________________________

E-mail ID:________________________________________________________________________

3. THIRD APPLICANT(S)

Title Mr. Ms. M/s.

Name ________________________________________________________

Son / Daughter / Wife of ______________________________________

Nationality__________________________Age_______years__________

Profession__________________________Aadhar No.________________

Residential Status: Resident/ Non-Resident/ Foreign National of Indian Origin

_________________________________________________________________________________

Income Tax Permanent Account No._______________________________________________

Ward / Circle / Special Range / Place, where assessed to income tax_________________

Mailing Address__________________________________________________________________

_________________________________________________________________________________

Tel No._________________________________Mobile No.________________________________

E-mail ID:________________________________________________________________________

OR

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

04
 M/s. ____________________________________________________________________________

Reg. Office/Corporate Office ______________________________________________________

_________________________________________________________________________________

Authorized Signatory _____________________________________________________________

_________________________________________________________________________________

Board Resolution dated/Power of Attorney ________________________________________

PAN No./TIN No. _________________________________________________________________

Tel No. _________________________________ Mobile No._______________________________

E-mail ID: ________________________________ Fax No._______________________________

(attach a certified true copy of the Board Resolution/Power of Attorney)

4. DETAILS OF THE SAID APARTMENT AND ITS PRICING

Tower No. _____ Rate of Said Apartment per

square meter*
Said Apartment No. _________

Type ________

Floor ________

Parking Slot No(s) _____, ______ and ______

Unit Price (in rupees)

Applicable taxes and cesses payable by

the Applicant(s). (This includes GST
payable at rates as specified from time
to time, which at present is 5%)

Total Price (in rupees)

*NOTE:

1. The Total Price for the Said Apartment based on the Carpet Area.

2. The Promoter has taken the conversion factor of 10.764 sq.ft. per sqm. for the purpose
of this Application (1 feet = 304.8 mm)

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

05
Carpet Area: ______square meter (_________square feet)

Parking Area: ______square meter (_________square feet)

______square meter (_________square feet)

______square meter (_________square feet)

5. DECLARATION

The Applicant(s) hereby declares that the above particulars / information given by the
Applicant(s) are true and correct and nothing has been concealed therefrom.

Yours Faithfully

Date: _____________________

Place: _____________________

Signature of Applicant(s)

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

06
 --------------------------------------------FOR OFFICE USE ONLY------------------------------------------

RECEIVING/OFFICER

Name ______________________________ Signature ____________________________

Date _______________________________

1) ACCEPTED / REJECTED

2) Residential Apartment No. _________________ Floor _________________

3) Carpet Area: ________square meter [ ________square feet]

4) Total Price payable for the Said Apartment : Rs. _________________________________/-

(Rupees _____________________________________________________________________only)

5) Parking Area: _________________square meter [ ___________square feet]

_________________square meter [ ___________square feet]

_________________square meter [ ___________square feet]

6) Payment Plan: Down Payment / Instalment Payment Plan

7) Payment received vide Cheque/ DD/ Pay Order No. __________________ dated
___________________ for Rs. ____________ out of NRE/ NRO/ FC/ SB/ CUR/ CA Acct
__________________________________________________________

8) Booking Receipt No. _________________ dated __________________________

9) BOOKING DIRECT/Real Estate Agent

Name _____________________________________,

Address _____________________________________

_____________________________________,

Registration no. _____________________________________,

Stamp with Signature _____________________________________

8) Checklist for Receiving Officer:

a) Amount paid along with Application.

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

07
 b) Applicant's signature on all pages of the Application form at places marked as
"X".

c) PAN No. & copy of PAN Card/Form60/Form 49A.

d) Aadhar No. & Copy of Aadhar Card.

e) For Companies: Certified copies of Memorandum & Articles of Association and

board resolution in support of the authorized signatory under common seal of
the company.

f) For Foreign Nationals of Indian Origin: Foreign Inward Remittance from the
account of the Applicant(s) / NRE/ FCNR A/c of the Applicant(s) / IPI-7/
Passport Photocopy.

g) For NRI: Copy of Passport/Foreign Inward Remittance from the account of the
Applicant(s) /NRE/NRO/of the Applicant(s).

h) For Partnership Firm/LLP Firm: Copy of Partnership Deed and authorization to

purchase.

Place: _______________________

Date: _______________________

Cleared by stock on ________________

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

08
In this Application, following words and expressions when capitalized, shall have the
meanings assigned herein. When not capitalized, such words and expression shall be
attributed their ordinary meaning. For all intents and purposes and for the purpose of the
terms and conditions set out in this Application, singular means plural and masculine
includes feminine gender.

DEFINITIONS:

For the purpose of this Application, unless the context otherwise requires-

(a) “Act” means the Real Estate (Regulation and Development) Act, 2016 (16 of
2016);

(b) “Booking Amount” means 10% of the Total Price which shall also be the
earnest money for the Said Apartment and has been more clearly set out in the
Payment Plan (Schedule -C);

(c) “Government” means the Government of the State of Haryana;

(d) “Rules” means the Real Estate (Regulation and Development) Rules, 2017 for
the State of Haryana and as amended from time to time;

(e) “Section” means a section of the Act.

TERMS AND CONDITIONS FORMING PART OF THIS APPLICATION FORM FOR

ALLOTMENT OF A RESIDENTIAL APARTMENT IN DLF PRIVANA WEST, SECTOR 76 &
77, GURUGRAM (HARYANA).

The terms and conditions given below shall be read together with the terms and conditions
more comprehensively set out in the Agreement.

1. The Applicant(s) confirms that the Applicant(s) has examined and conducted due
diligence of all the documents relating to the Said Land and has/have satisfied
himself/themselves about the title/interest/rights of the Promoter/Owners in the
Said Land.

2. The Total Price for the Said Apartment, based on the Carpet Area is Rs. ._________/-
(Rupees ______________________________________________________only) (“Total Price”):

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

09
 Tower No. _____ Rate of Said Apartment per
square meter*
Said Apartment No. _________

Type ________

Floor ________

Parking Slot No(s) _____, ______ and ______

Unit Price (in rupees)

Applicable taxes and cesses payable by

the Applicant(s). (This includes GST
payable at rates as specified from time
to time, which at present is 5%)

Total Price (in rupees)

*NOTE:

1. The Total Price for the Said Apartment based on the Carpet Area.

2. The Promoter has taken the conversion factor of 10.764 sq.ft. per sq. mts. for the
purpose of this Application (1 feet = 304.8 mm

Explanation:

(i) The Total Price as mentioned above includes the Booking Amount paid/payable by
the Applicant(s) to the Promoter towards the Said Apartment for residential usage
along with parking. It is hereby clarified that the amount paid by the Applicant(s) at
the time of Application, forms part of the Booking Amount. It is further clarified that
the Booking Amount is payable in more than one instalment for the convenience of
the Applicant(s) and the same shall be treated as earnest money for due performance
of the obligations of the Applicant(s) under this Application and the Agreement.

(ii) The Total Price as mentioned above includes taxes (GST and Cess or any other taxes/
fees/ charges/ levies etc.) which may be levied, in connection with the
development/construction of the Project paid/payable by the Promoter up to the date
of offer of handing over the possession of the Said Apartment for residential usage
along with parking to the Applicant(s) after obtaining the necessary approvals from
competent authority for the purposes of such possession.

Provided that, in case there is any change / modification in the taxes / charges/ fees /
levies etc., the subsequent amount payable by the Applicant(s) to the Promoter shall
be increased / decreased based on such change/ modification.

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

10
 Provided further, if there is any increase in the taxes / charges / fees / levies etc. after
the expiry of the scheduled date of completion of the Project as per registration with
the authority, which shall include the extension of registration, if any, granted to the
said Project by the authority, as per the Act, the same shall not be charged from the
Applicant(s).

(iii) The Promoter shall periodically intimate in writing to the Applicant(s), the amount
payable as stated in (i) above and the Applicant(s) shall make payment demanded by
the Promoter within the time and in the manner specified therein. In addition, the
Promoter shall provide to the Applicant(s) the details of the taxes/ charges/ fees/
levies etc. paid or demanded along with the acts/rules/notifications together with
dates from which such taxes/ charges/ fees/ levies etc. have been imposed or become
effective.

(iv) The Total Price of Said Apartment includes recovery of price of land, development/
construction of not only the Said Apartment but also the common areas, internal
development charges, infrastructure augmentation charges, external development
charges, taxes, fees, levies etc., cost of providing electric wiring, electrical connectivity
to the Said Apartment, lift, waterline and plumbing, fire detection and firefighting
equipment in common areas, maintenance charges as per para 14, and includes cost
for providing all other facilities, amenities and specifications to be provided within the
Said Apartment for the residential usage along with parking in the Project, i.e. DLF
Privana West.

3. Time is of essence and the Applicant(s) shall make the payment as per the Payment
Plan set out in Schedule-C (“Payment Plan”).

4. The Total Price is escalation-free, save and except increases which the Applicant(s)
hereby agrees to pay, due to increase on account of development charges payable to
the competent authority and/or any other increase in charges which may be levied or
imposed by the competent authority from time to time. The Promoter undertakes and
agrees that while raising a demand on the Applicant(s) for increase in development
charges / cost / charges / fees / levies, etc., imposed by the competent authorities, the
Promoter shall enclose the said notification / order / rule / regulation to that effect
along with the demand letter being issued to the Applicant(s), which shall only be
applicable on subsequent payments. Provided that if there is any new imposition or
increase of any development charges after the expiry of the scheduled date of
completion of the Project as per registration with the Authority, which shall include
the extension of registration, if any, granted to the Project by the Authority, as per the
Act, the same shall not be charged from the Applicant(s).

5. The Applicant(s) has/ have seen the layout plan/ demarcation-cum-zoning/site

plan/ building plans, specifications, amenities and facilities etc. depicted in the
advertisement/ brochure/ Agreement/ Website (as the case maybe) regarding the

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

11
 Project where the Said Apartment is located and has/ have accepted the unit/floor/
site plan, payment plan and the specifications, amenities, facilities, etc. which has
been approved by the competent authority, as represented by the Promoter.

6. Subject to Para 13, the Promoter agrees and acknowledges, the Applicant(s) shall
have the right to the Said Apartment for residential usage along with parking as
mentioned below:

(i) The Applicant(s) shall have exclusive ownership of the Said Apartment for
residential usage along with parking;

(ii) The Applicant(s) shall also have rights in the common areas, as provided under
Rule 2(1)(f) of Rules. The Applicant(s) shall use the common areas along with
other occupants, maintenance staff etc. without causing any inconvenience or
hindrance to them. It is clarified that the Promoter shall hand over the common
areas to the association of allottees/competent authorities after duly obtaining
the occupation certificate /part occupation certificate/part completion/
completion certificate from the competent authority, as the case may be, as
provided under Rule 2(1)(f) of Rules;

(iii) The Applicant(s), with prior written request, has the right to visit the project
site to assess the extent of development of the Project and the Said Apartment
for residential usage, and adherence to security guidelines as maybe issued by
the Promoter.

7. Schedule for possession of the Said Apartment

The timely delivery of possession of the Said Apartment to the Applicant(s) and the
common areas to the association of allottees or the competent authority, as the case
may be, as provided under Rule 2(1)(f) of the Rules, is the essence of the Agreement.

The Promoter assures to obtain the Occupation Certificate for the Building by
31.12.2031 and thereafter offer to hand over possession of the Said Apartment for
residential usage along with parking as per agreed terms and conditions by
31.03.2032, unless there is delay due to “force majeure”, epidemic, pandemic and
lock down, Court orders, Government policy/guidelines, decisions effecting the
regular development of the Project. If, the completion of the Project is delayed due to
the above conditions, then the Applicant(s) agrees that the Promoter shall be entitled
to the extension of time for delivery of possession of the Said Apartment for residential
usage.

The Applicant(s) agrees and confirms that, in the event it becomes impossible for the
Promoter to implement the Project due to ‘force majeure’ and above-mentioned
conditions, then the allotment shall stand terminated and the Promoter shall refund

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

12
 to the Applicant(s) the entire amount received by the Promoter from the Applicant(s)
within ninety days. The Promoter shall intimate the Applicant(s) about such
termination at least thirty days prior to such termination. After refund of the money
paid by the Applicant(s), the Applicant(s) agrees that he/ she shall not have any
rights, claims etc. against the Promoter and that the Promoter shall be released and
discharged from all its obligations and liabilities under the allotment / Agreement.

8. Procedure for taking possession of Said Apartment

The Promoter obtaining the occupation certificate or part thereof of the building
blocks/tower in the Project shall offer in writing the possession of Said Apartment
within 3 (three) months, from the date of above approval, to the Applicant(s) as per
terms of the Agreement.

The Promoter agrees and undertakes to indemnify the Applicant(s) in case of failure
of fulfilment of any of the provisions, formalities, documentation on part of the
Promoter. The Promoter shall provide a copy (on demand) of the occupation certificate
or part thereof in respect of the Building at the time of conveyance of the same. The
Applicant(s), after the offer of handing over the possession, agrees to pay the
maintenance charges and holding charges (as mentioned in Schedule-C) as
determined by the Promoter/association of allottees/competent authority, as the case
may be.

9. Failure of Applicant(s) to take Possession of Said Apartment for residential usage

Upon receiving a written intimation from the Promoter as per para 8 above, the
Applicant(s) shall take possession of the Said Apartment from the Promoter by
executing necessary indemnities, undertakings and such other documentation
(including but not limited to the Undertaking cum Indemnity Bond, Maintenance
Agreement, Conveyance Deed, Application Form for membership of the association of
allottees) as maybe prescribed in the Agreement, and the Promoter shall give
possession of the Said Apartment for residential usage to the Applicant(s) as per
terms and conditions of the Agreement.

In case the Applicant(s) fails to comply with essential documentation, undertaking

etc. or fails to take possession within the time provided in Para 8, such Applicant(s)
shall continue to be liable to pay maintenance charges and holding charges as
specified in Para 8.

10. Possession by the Applicant(s)

After obtaining the occupation certificate of the building blocks in respect of the
Project and handing over the physical possession of the Said Apartment for
residential usage along with parking to the Applicant(s), it shall be the responsibility
of the Promoter to hand over the necessary documents and plans, and common areas

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

13
 to the association of allottees or the competent authority, as the case may be as
provided under Rule 2(1)(f) of Rules.

11. Cancellation by Applicant(s)

The Applicant(s) shall have the right to cancel/withdraw his allotment in the Project
as provided in the Act:

Provided that where the Applicant(s) proposes to cancel/withdraw from the Project
without any fault of the Promoter, the Promoter herein is entitled to forfeit the
Booking Amount paid for the allotment and interest component on delayed payment
(payable by the customer for breach of Application/Agreement and non-payment of
any due payable to the Promoter). The rate of interest payable by the Applicant(s) to
the Promoter shall be the State Bank of India highest marginal cost of lending rate
plus two percent. The balance amount of money paid by the Applicant(s) shall be
returned by the Promoter to the Applicant(s) within 90 (ninety) days of such
cancellation.

12. Refund of money and interest at such rate as may be prescribed, payment of
interest at such rate as may be prescribed or payment of compensation:

The Promoter shall compensate the Applicant(s) in case of any loss caused to him
due to defective title of the Said Land, on which the Project is being developed or has
been developed, in the manner as provided under the Act and the claim for
compensation under this provision shall not be barred by limitation provided under
any law for the time being in force.

Except for occurrence of a force majeure, epidemic, pandemic and lock down, Court
order, Government policy/ guidelines, decisions, if the Promoter fails to complete or is
unable to offer to handover possession of the Said Apartment for residential usage
along with parking.

(i) in accordance with the terms of the Agreement, duly completed by the date
specified in Para 7; or

(ii) due to discontinuance of his business as a developer on account of suspension

or revocation of the registration under the Act; or for any other reason; the
Promoter shall be liable, on demand to the Applicant(s), in case the
Applicant(s) wishes to withdraw from the Project, without prejudice to any
other remedy available, to return the total amount received by him in respect of
the Said Apartment for residential usage, with interest at the rate prescribed
in the Rules including compensation in the manner as provided under the Act
within ninety (90) days of it becoming due.

Provided that if the Applicant(s) does not intend to withdraw from the Project, the
Promoter shall pay the Applicant(s) interest at the rate prescribed in the Rules for

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

14
 every month of delay, till the offer of the possession of the Said Apartment for
residential usage, which shall be paid by the Promoter to the Applicant(s) within
ninety (90) days of it becoming due.

In case obligation is not complied with by the Promoter:

(i) the authority shall order to return the total amount received by the Promoter in
respect of the Said Apartment for residential usage, with interest at the rate
prescribed in the Rules in case the Applicant(s) wishes to withdraw from the
Project.

(ii) in case Applicant(s) claims compensation in this regard he may make an

application for adjudging compensation to the adjudicating officer who shall
order quantum of compensation having due regards to the factors in Section
72.

(iii) if the Applicant(s) does not intend to withdraw from the Project the authority
shall order the Promoter to pay the Applicant(s) interest at the rate prescribed
in the Rules for every month of delay till the offer of the possession of the Said
Apartment for residential usage.

(iv) Timelines for refund of money and interest at such rate as may be prescribed,
payment of interest at such rate as may be prescribed in Rule 16 of Rules.

13. The Applicant(s) shall be considered under a condition of Default, on the occurrence of
the following events:

(i) In case the Applicant(s) fails to make payment of any instalment due as per the
Payment Plan annexed hereto as Schedule-C, the Applicant(s) shall be liable
to pay interest to the Promoter on the unpaid amount from the due date of such
instalment at the rate prescribed in the Rules;

(ii) In case the default by Applicant(s) under the condition listed above continues
for a period beyond ninety (90) days after notice from the Promoter in this
regard, the Promoter may cancel the allotment of the Said Apartment for
residential usage along with parking in favour of the Applicant(s) and refund
the money paid to him by the Applicant(s), by forfeiting the Booking Amount
paid for the allotment and interest component on delayed payment (paid /
payable by the Applicant for breach of Application/Agreement and non-
payment of any due payable to the Promoter). The rate of interest payable
by the Applicant(s) to the Promoter shall be the State Bank of India's highest
marginal cost of lending rate plus two percent (2%). The balance amount of
money paid by the Applicant(s) shall be returned by the Promoter to the
Applicant(s) within ninety (90) days of such cancellation. On such default, the

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

15
 Application/Agreement and any liability of the Promoter arising out of the
same shall thereupon, stand terminated. Provided that the Promoter shall
intimate the Applicant(s) about such termination at least thirty days prior to
such termination.

14. The Promoter shall be responsible to provide and maintain essential services in the
Project till the taking over of the maintenance of the Project by the association of
allottees or competent authority, as the case may be, upon the issuance of the
occupation certificate/part thereof, part completion certificate/completion certificate
of the Project, as the case may be. The cost of maintenance till the date of occupation
certificate / part thereof, has been included in the Total Price of the Said Apartment
for residential usage.

The Applicant(s) agrees to execute a maintenance agreement along with other

necessary documents, undertakings etc. in the standard format, with the association
of allottees / the maintenance agency as appointed for maintenance and upkeep of the
Project. Execution of the maintenance agreement and payment of the Interest-
Bearing Maintenance Security (IBMS) shall be a condition precedent for handing over
possession of Said Apartment by the Promoter and also for executing the conveyance
deed of the Said Apartment.

In case, the Applicant(s)/association of allottees fails to take possession of the said

essential services as envisaged in the Agreement or prevalent laws governing the
same, then in such a case, the Promoter or the developer has right to recover such
amount as spent on maintaining such essential services beyond the date of occupation
certificate / part thereof from the Applicant(s) on pro-rata basis.

15. The parkings are inseparable from and forms an integral part of the Said Apartment.
The Applicant(s) confirms that the Applicant(s) has no right to sell/transfer or deal
with the parking(s) independent of the Said Apartment. The Applicant(s) undertakes
to park his/her vehicle in the parking slots and not anywhere else in the
Building/Project.

16. The Applicant(s), if resident outside India, shall be solely responsible for complying
with the necessary formalities as laid down in Foreign Exchange Management Act,
1999, Reserve Bank of India Act, 1934 and the Rules & Regulations made thereunder,
or any other statutory amendment(s) modification(s) made thereof and all other
applicable laws in India and shall keep the Promoter indemnified in this regard. The
Applicant(s) acknowledges that the Promoter shall not be responsible towards any
third-party making payment/ remittances on behalf of any Applicant(s) and such
third party shall not have any right in the application/ allotment of the Said
Apartment and the Promoter shall issue the payment receipts in favour of the
Applicant(s) only.

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

16
17. The Applicant(s) may with the permission from the Promoter raise and/ or avail loan
from banks and other housing finance companies for purpose of raising finance
towards the purchase of the Said Apartment. Any delay on account of raising and/ or
availing loan from banks and other housing finance companies shall not absolve the
Applicant(s) from making timely payment of the Total Price or any part thereof.

18. The Applicant(s) shall have no objection in case the Promoter creates a charge on the
entire Project during the course of development of the Project for raising loan from any
banking and/or Financial Institution provided, creation of such charge shall not affect
the rights and interest of the Applicant(s) to the Said Apartment.

19. In case of joint Applicant(s), all communication shall be sent to the Applicant(s),
whose name appears first and all the addresses given by him, which shall for the
purposes be considered as served on all the Applicant(s) and no separate
communication shall be necessary to the other named Applicant(s).

20. Whenever there is any change in the residential status of the Applicant(s) subsequent
to the submitting this Application, it shall be the sole responsibility of the
Applicant(s) to intimate the same in writing to the Promoter immediately and comply
with necessary formalities, as specified and under the applicable laws.

21. The Applicant(s) shall inform the Promoter in writing of any change in the mailing
address mentioned failing which all demands, notices etc. by the Promoter shall be
mailed to the address given in the Application and shall be deemed to have been
received by the Applicant(s).

22. The Applicant(s) shall indemnify and keep the Promoter, its directors, agents,
representatives, employees, estate and effect indemnified and harmless against the
payment and observance and performance of all the covenants and conditions and any
loss, damage or liability that may arise due to non-payment, non-observance or non-
performance of the said covenants or said conditions by the Applicant(s) as
mentioned in the Application and Agreement.

23. The Applicant(s) understands that the final allotment of the Said Apartment is
entirely at the discretion of the Promoter.

24. The Colony on the Licensed Land i.e. DLF Privana is being developed in phases and the
Applicant(s) acknowledges and confirms that the Applicant(s) shall have no right,
title or interest in any other lands, facilities and amenities outside the Said
Land/Project i.e. DLF Privana West, and such other lands, facilities and amenities in
the Licensed Land or outside it, are specifically excluded from the scope of this
Application and the Agreement. The Applicant(s) agrees and understand that
though the Nursery School are part of Said Land/Project but these amenities are for

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

17
 entire Colony and all the buyers of apartments/units of entire Colony shall have the
right of usage of these amenities. Further, the Applicant(s) agrees and acknowledges
that the nursery in the Said Land/Project i.e. DLF Privana West are not for exclusive
and restricted to the usage of and/or benefit of the Project and the same are facilities
for usage by the allottees of the entire Licensed Area. The Promoter may, acquire
more lands (to be added to the Licensed Land) and/or be entitled to enhancement in
the FAR as maybe allowed by the competent authority from time to time, and the
Applicant(s) shall have no objection in this regard. The Applicant(s) understands that
the Promoter may alter/change/amend the layout plans, architectural design, maps
etc. of the Said Apartment /Project as per the applicable laws.

25. The Applicant(s) agrees and understands that terms and conditions of this
Application and those of the Agreement may be modified/amended in accordance
with any directions/order which may be passed by any Governmental Authority(ies),
court of law, tribunal, or Commission in compliance with applicable laws and such
amendment shall be binding on the Applicant(s) and the Promoter.

26. The rights and obligations of the Parties under or arising out of this Application Form
shall be construed and enforced in accordance with the Act and the Rules and
Regulations made thereunder including other applicable laws prevalent in the State of
Haryana for the time being in force.

The Applicant(s) has/ have fully read and understood the above conditions and agrees to
abide by the same.

___________________________________________

Signature of Sole/First Applicant

___________________________________________

Signature of Second Applicant (if any)

___________________________________________

Signature of Third Applicant (if any)

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

18
 SCHEDULE - A
LOCATION

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

19
 SCHEDULE - B
SITE PLAN

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

20
 SCHEDULE - B
SITE PLAN

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

21
 SCHEDULE - B
FLOOR/ UNIT PLAN OF THE SAID APARTMENT

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

22
 SCHEDULE - B
FLOOR/ UNIT PLAN OF THE SAID APARTMENT

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

23
 SCHEDULE - C
PAYMENT PLAN
1. Standard Payment Plan:

Sl. No. Instalment Description

% Due
Construction Stage Time

1 Amount on Application INR 50 lacs

2 Booking Amount (Within 30 days of Application Form) 10% (Less INR 50 lacs)

3 Within 4 months of Application Form 15%

4 Start of Foundation Works* 9 months* 10%

5 Completion of GF Floor Slab* 17 months* 10%

6 Completion of 10th Floor roof slab* 25 months* 10%

7 Completion of 24th Floor roof slab* 31 months* 10%

8 Completion of Terrace slab* 40 months* 10%

9 On application for Occupation Certificate 10%

10 On receipt of Occupation Certificate 10%

11 On offer of possession 5%

TOTAL 100%

*Whichever is later.

2. Down Payment Plan:

Sl. No. Instalment Description % Due

1 Amount on Application INR 50 lacs

2 Booking Amount- 10% (less INR 50 Lacs)

(Within 30 days of Application Form)

3 Within 120 days of Application Form 80% (Less Down Payment Rebate)

4 On Offer of Possession 10%

Notes:
1. Down Payment Rebate = 10%
2. Stamp duty and registration charges as applicable will be extra.
3. GST/ Taxes as applicable. GST additional on each instalment as applicable.
4. Interest Bearing Maintenance Security Deposit (IBMS)* shall be payable @ INR 10 lacs per
apartment on the offer of possession, which shall be over and above the Total Price.
5. Holding Charges at the rate of Rs. 25 per sqft per month on the carpet area
(*detailed T&C shall be as per Maintenance Agreement)

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

24
 SCHEDULE - D
SPECIFICATIONS, AMENITIES, FACILITIES (WHICH ARE PART OF THE SAID
APARTMENT FOR RESIDENTIAL USAGE)

APARTMENT SPECIFICATION
Living / Dining / Lobby / Passage
Floor Imported Marble
Walls Acrylic Emulsion / OBD
Ceiling Acrylic Emulsion / OBD
Bedroom/Study
Floor Laminated Wooden Flooring
Walls Acrylic Emulsion / OBD
Ceiling Acrylic Emulsion / OBD
Wardrobes Modular wardrobes of standard make in bedrooms
(except in utility & Study)
Kitchen
Walls Tiles up-to 2' above counter & Acrylic Emulsion
paint in balance area
Floor Anti-skid Tiles
Ceiling Acrylic Emulsion / OBD
Counter Granite / Marble / Engineered Stone
Fittings / Fixtures CP ttings, Double bowl single drainboard SS Sink,
Exhaust fan
Kitchen Appliances Modular Kitchen with Hob, Chimney, Oven,
Microwave, Dishwasher Refrigerator, Washing
Machine (at utility balcony) of reputed make
Balcony
Floor Tiles
Ceiling Exterior grade paint / OBD
Toilets
Walls Combination of Tiles, stone, Acrylic Emulsion Paint
& Mirror
Floor Marble / Granite / tiles
Ceiling Acrylic Emulsion Paint / OBD
Counter Granite / Marble / Engineered stone

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

25
 SCHEDULE - D
SPECIFICATIONS, AMENITIES, FACILITIES (WHICH ARE PART OF THE SAID
APARTMENT FOR RESIDENTIAL USAGE)
Fixtures/Accessories Glass Shower-partition with door in toilets (7'Ht),
Vanity & Medicine cabinet, Exhaust Fan, Towel rail
/ ring, Geyser, Toilet paper holder, all of standard
make.
Sanitary ware/CP ttings CP ttings, Wash Basin, Floor mounted / Wall hung
WCs
Plumbing
CPVC piping for water supply & UPVC piping for RWP, Soil waste & Vent.
Fire Fighting System
Fire Fighting System with sprinklers, smoke detection system etc.
Utility
Floor Tiles / IPS
Walls / Ceiling Oil bound Distemper/Whitewash
Toilet Flooring & walls in Tile/ plaster/ mirror/ cladding,
Conventional CP Fittings and Chinaware
Door
Internal Doors Painted/Polished frame with Painted/laminated/
Polished/Veneered ush doors.
Entrance Doors Painted/Polished frame with Painted/laminated/
Polished/Veneered ush door.
External Glazing
Windows/ External Glazing UPVC / Aluminium / MS Frames with Single/
double glass unit with clear glass in shutters and
Wire mesh shutters in habitable rooms. UPVC /
Aluminium / MS Frames with Frosted / Clear Glass
in toilets.
Electrical Fixtures/Fittings Modular touch switches with copper wiring,
standard ceiling fans in all rooms (except toilets).
Exhaust fan in toilets & kitchen and ceiling light
xtures in Balconies. Home Automation for selected
services as per design.
Power Back-up
1. For Typical apartment of 4 BHK+Utility load not exceeding - 12 KVA
2. For Penthouse load not exceeding - 16 KVA
DG capacity shall be at 70% of load factor of individual apartment and 70 % overall diversity
for total diversied load of apartments as well as diversied load of common areas.

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

26
 SCHEDULE - D
SPECIFICATIONS, AMENITIES, FACILITIES
(WHICH ARE PART OF THE PROJECT)
COMMON AREAS
Security System
Secured gated community with access control at entrances. CCTV surveillance.
Passenger Lift Lobby
Lifts lobby oors Tile/ Marble/ Granite/ Engineered Stone
Lifts lobby Walls Combination of marble/ Acrylic Emulsion Paint/
Wallpaper/ Veneer/ Films / mirror
Service Lift Lobby
Lifts lobby oors Tile/ Stones/ IPS
Lifts lobby Walls Flat oil paint / OBD
Staircase
Floor Indian Stone / Tile/ Coated surface
Walls Flat oil Paint / OBD

● For better safety, structure designed for India's highest seismic considerations of Zone
V against Zone IV as stipulated by the Indian codes.
● Air-Conditioned apartment, with energy efcient VRV/VRF system excluding toilets
● Air-Conditioned Entrance halls and Main passenger lift lobbies
● Eco friendly environment with Rainwater Harvesting system to recharge aquifer, and
use of treated water from STP for ushing and horticulture.
Conversion Scale
1ft = 304.8 mm
DISCLAIMER: Marble/Granite being natural material have inherent characteristics of color
and grain variations. Specications are indicative and are subject to change as decided by the
Promoter or Competent Authority. Marginal variations may be necessary during
construction. The extent/number/variety of the equipment/appliances and their
make/brand thereof are tentative and liable to change at sole discretion of the Promoter as
per applicable law.

X______________________ X______________________ X______________________

Sole/First Applicant Second Applicant Third Applicant

27
 DLF LIMITED

Registered Office:
Shopping Mall 3rd Floor Arjun Marg,
Phase I DLF City, Gurugram,
Haryana 122002

HARERA Registration No. RC/REP/HARERA/GGM/819/551/2024/46 dated: 22.04.2024 | https://haryanarera.gov.in