This document outlines the details required for contractors to submit details of completed works for consideration of enlistment with CPWD in 2022. It includes 12 items such as the name and location of the work, agreement details, completion details, costs, details of any delays or legal cases, and contact information for the owner of the work. The applicant must submit this form separately for up to three eligible completed works and includes a certification that no adverse actions have been taken against the applicant.
This document outlines the details required for contractors to submit details of completed works for consideration of enlistment with CPWD in 2022. It includes 12 items such as the name and location of the work, agreement details, completion details, costs, details of any delays or legal cases, and contact information for the owner of the work. The applicant must submit this form separately for up to three eligible completed works and includes a certification that no adverse actions have been taken against the applicant.
This document outlines the details required for contractors to submit details of completed works for consideration of enlistment with CPWD in 2022. It includes 12 items such as the name and location of the work, agreement details, completion details, costs, details of any delays or legal cases, and contact information for the owner of the work. The applicant must submit this form separately for up to three eligible completed works and includes a certification that no adverse actions have been taken against the applicant.
This document outlines the details required for contractors to submit details of completed works for consideration of enlistment with CPWD in 2022. It includes 12 items such as the name and location of the work, agreement details, completion details, costs, details of any delays or legal cases, and contact information for the owner of the work. The applicant must submit this form separately for up to three eligible completed works and includes a certification that no adverse actions have been taken against the applicant.
Details of Completed Works: Eligible works completed during the last seven years
1 Name of work/project & location
2 Name of agency 3 Agreement number 4 Agreement amount 5 Gross value of completed work 6 Stipulated date of start 7 Date of completion (a) Stipulated date of completion (b) Actual date of completion (c) Justified extended date of completion, if any 8 Details and cost of services included (a) Civil (water supply, sanitary installation, drainage and water proofing work, etc.) (b) Electrical (internal electrical installation, firefighting, fire alarm, HVAC, lift, electrical substation, and DG set, etc.) (c) Number of storeys constructed. 10 Details of compensation levied for delayed completion, if any (a) Whether case of levy of compensation for delay has been decided or not? Owner department officers are requested to only mention either Yes or No against this option. Option of writing “Not applicable” is only acceptable where work is completed before stipulated date of completion. (b) If EOT case has been decided i.e answer to (a) above is Yes, then please intimate amount of compensation levied for delayed completion. 11 Details of Conciliation/Mediation/Arbitration/Court Cases (from start of work till issue of this certificate), if any 12 Details of owner (a) Name (b) Address (c) Phone (d) e-mail
Owner’s Signature with seal and designation
(Project Manager or Executive Engineer or Equivalent
32 168 Years of CPWD's dedicated service to the Nation
RULES FOR ENLISTMENT OF CONTRACTORS IN CPWD, 2022
Certificate: This is to certify that no adverse action has been taken by the department concerned against me/us. I/We understand that if any information is found incorrect, our enlistment is liable to be cancelled.
Self-attestation by Applicant
Notes:- 1. Scan of original documents to be uploaded in the portal 2. This proforma shall be filled up separately for all three (maximum) eligible works proposed for works experience. 3. Annexure-III without valid signature of owner is invalid. Owner means department who owns the project/work executed by the applicant.
168 Years of CPWD's dedicated service to the Nation 33
