Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

A single copy of this

FIDIC
publication is licensed to

UWE
on
13/12/2021

This is an uncontrolled copy - not for contract use

UNIVERSITY OF THE WEST OF ENGLAND
 AGREEMENT

GENERAL CONDITIONS
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

SHORT FORM of Contract RULES FOR ADJUDICATION

EN
NOTES FOR GUIDANCE

First Edition 1999

ISBN 2-88432-024-5
IM
EC
SP

FEDERATION INTERNATIONALE DES INGENIEURS-CONSEILS

INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS
INTERNATIONALE VEREINIGUNG BERATENDER INGENIEURE
FEDERACION INTERNACIONAL DE INGENIEROS CONSOLTORES
 ACKNOWLEDGEMENTS
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

The Fédération Internationale des Ingénieurs-Conseils (FIDIC) extends special

thanks to the following members of its Task Group: Philip Jenkinson (Task
Group Leader), WS Atkins, UK; AEJ (Tony) Sanders, Mouchel, UK; and
Edward Corbett, Corbett & Co, UK. Liaison with other active Task Groups was
provided by Peter L Booen, GIBB Ltd, UK.

The preparation was carried out under the general direction of the FIDIC
Contracts Committee comprising John B Bowcock (Chairman), Consulting

EN
Engineer, UK; Michael Mortimer-Hawkins, SwedPower, Sweden; Axel-Volkmar
Jaeger, Schmidt Reuter Partner, Germany; and KB (Tony) Norris (Special
Adviser), Consulting Engineer, UK.

Drafts were commented on by the following persons and organisations: Mushtaq

Ahmad, NESPAK, Pakistan; Peter Batty, Post Buckley International, USA; Nael G
Bunni, Consulting Engineer, Ireland; Kathryn Josephine T. dela Cruz, Construction
Industry Authority of the Philippines; Michael Dudley, UNOPS; Hans Enhörning, ABB
IM
Asea Brown Boveri Ltd, Switzerland; Mark Griffiths, Griffiths & Armour, UK; Geoffrey F
Hawker, Consulting Engineer and Barrister, UK; Adam K Heine, Consulting Engineer,
Poland; HS Kwong, Secretary for Works, Hong Kong; Jan Cees Overbosch/Evert Jan
Wijers, DHV Beheer BV, The Netherlands; Marek Rdultowski, Cosmopoli Consultants,
Poland; J G Rees, Binnie Black & Veatch, UK; Asian Development Bank; European
EC

Bank for Reconstruction and Development; Inter-American Development Bank;

International Association of Dredging Companies; Inter-Pacific Bar Association;
Organisme de Liaison Industries Métalliques Européennes (“ORGALIME”); and The
World Bank. Acknowledgement of reviewers does not mean that such persons or
organizations approve the wording of all clauses.

FIDIC wishes to record its appreciation of the time and effort devoted by all the above.
SP

The ultimate decision on the form and content of the document rests with FIDIC.
 FOREWORD
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

These Conditions of Contract have been prepared by the Fédération Internationale

des Ingénieurs-Conseils (FIDIC) and are recommended for engineering and building
work of relatively small capital value. However, depending on the type of work and the
circumstances, the Conditions may be suitable for contracts of greater value. They are
considered most likely to be suitable for fairly simple or repetitive work or work of short
duration without the need for specialist sub-contracts.

The main aim has been to produce a straightforward flexible document which includes

EN
all essential commercial provisions and which may be used for all types of engineering
and building work with a variety of administrative arrangements. Under the usual
arrangements for this type of contract, the Contractor constructs the Works in
accordance with design provided by the Employer or by his representative (if any).
However, this form may also be suitable for contracts which include, or wholly
comprise, contractor-designed civil, mechanical and/or electrical works.

In addition, the Employer has a choice of valuation methods. Furthermore, although

IM
there is no reference to an impartial Engineer, the Employer may appoint an
independent Engineer to act impartially, should he wish to do so.

The form is recommended for general use, though modifications may be required in
some jurisdictions. FIDIC considers the official and authentic text to be the version in
EC

the English language.

The intention is that all necessary information should be provided in the Appendix to
the Agreement, the latter incorporating the tenderer's offer and its acceptance in one
simple document. The General Conditions are expected to cover the majority of
contracts. Nevertheless, users will be able to introduce Particular Conditions if they
wish, to cater for special cases or circumstances. The General Conditions and the
Particular Conditions will together comprise the Conditions governing the rights and
SP

obligations of the parties.

To assist in the preparation of tender documents using these Conditions, Notes for
Guidance are included. These Notes will not become one of the documents forming
the Contract. Finally, applicable Rules for Adjudication are also included.

The attention of users is drawn to the FIDIC publication "Tendering Procedure", which
presents a systematic approach to the selection of tenderers and the obtaining and
evaluation of tenders.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

CONTENTS

Agreement ..........................................i

Offer

EN
Acceptance

Appendix

General Conditions
IM
1 GENERAL PROVISIONS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1

1.1 Definitions
The Contract
Persons
EC

Dates, Times and Periods

Money and Payments
Other Definitions
1.2 Interpretation
1.3 Priority of Documents
1.4 Law
1.5 Communications
1.6 Statutory Obligations
SP

2 THE EMPLOYER . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2

2.1 Provision of Site

2.2 Permits and Licences
2.3 Employer's Instructions
2.4 Approvals

3 EMPLOYER’S REPRESENTATIVES . . . . . . . . . . . . . . . . . . . . . . . . . . 3

3.1 Authorised Person

3.2 Employer's Representative

4 THE CONTRACTOR . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3

4.1 General Obligations

4.2 Contractor's Representative
4.3 Subcontracting
4.4 Performance Security
a
 5 DESIGN BY CONTRACTOR . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3

5.1 Contractor's Design

5.2 Responsibility for Design

6 EMPLOYER’S LIABILITIES . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

6.1 Employer's Liabilities

7 TIME FOR COMPLETION . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5

7.1 Execution of the Works

7.2 Programme
7.3 Extension of Time
7.4 Late Completion

EN
8 TAKING-OVER . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5

8.1 Completion
8.2 Taking-Over Notice

9 REMEDYING EFFECTS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5

9.1 Remedying Defects

IM
9.2 Uncovering and Testing

10 VARIATIONS AND CLAIMS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 6

10.1 Right to Vary

EC

10.2 Valuation of Variations

10.3 Early Warning
10.4 Right to Claim
10.5 Variation and Claim Procedure

11 CONTRACT PRICE AND PAYMENT . . . . . . . . . . . . . . . . . . . . . . . . . . 7

11.1 Valuation of the Works

SP

11.2 Monthly Statements

11.3 Interim Payments
11.4 Payment of First Half of Retention
11.5 Payment of Second Half of Retention
11.6 Final Payment
11.7 Currency
11.8 Delayed Payment

12 DEFAULT . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8

12.1 Default by Contractor

12.2 Default by Employer
12.3 Insolvency
12.4 Payment upon Termination

13 RISK AND RESPONSIBILITY . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9

13.1 Contractor's Care of the Works

13.2 Force Majeure
b
 14 INSURANCE . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9

14.1 Extent of Cover

14.2 Arrangements
14.3 Failure to Insure

15 RESOLUTION OF DISPUTES . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 10
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

15.1 Adjudication
15.2 Notice of Dissatisfaction
15.3 Arbitration

INDEX . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 11

Particular Conditions

EN
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . 13

IM Rules for Adjudication . . . . . . . . . . . . . . . . . . . . . . . . . . . . 15

Notes for Guidance . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 21

Notes . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 31
EC
SP

c
 Agreement

The Employer is of
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

The Contractor is of

The Employer desires the execution of certain Works known as

OFFER

EN
The Contractor has examined the documents listed in the Appendix which forms part of this
Agreement and offers to execute the Works in conformity with the Contract for the sum of

(in words)

( in figures ) ( )
IM
or such other sum as may be ascertained under the Contract.

This offer, of which the Contractor has submitted two signed originals, may be accepted by
the Employer by signing and returning one original of this document to the Contractor before
EC

(date)

The Contractor understands that the Employer is not bound to accept the lowest or any offer
received for the Works.

Signature: Date:
SP

Name: Authorised to sign on behalf of (organization

name):
Capacity:

ACCEPTANCE
The Employer has by signing below, accepted the Contractor's offer and agrees that in
consideration for the execution of the Works by the Contractor, the Employer shall pay the
Contractor in accordance with the Contract. This Agreement comes into effect on the date
when the Contractor receives one original of this document signed by the Employer.

Signature: Date:

Name: Authorised to sign on behalf of (organization

name):
Capacity:

i
 APPENDIX
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

This Appendix forms part of the Agreement.

[ Note: with the exception of the items for which the Employer's requirements have
been inserted, the Contractor shall complete the following information before
submitting his offer. ]

Item Sub-Clause Data

EN
Documents forming the Contract
listed in the order of priority . . . 1.1.1

Document (delete if not applicable) Document Identification

(a) The Agreement . . . . . . . .

(b) Particular Conditions . . . .
IM
(c) General Conditions . . . . .
(d) The Specification . . . . . .
(e) The Drawings . . . . . . . . .
(f) The Contractor's tendered
design
EC

(g) The bill of quantities . . . . .

(h) ...................
(i) ...................

Time for Completion . . . . . . . . . 1.1.9 . . . . days

Law of the Contract . . . . . . . . . 1.4 ..... Law of the Country*

SP

Language ................ 1.5 .....

Provision of Site . . . . . . . . . . . . 2.1 ..... On the Commencement Date*

Authorised person .......... 3.1 .....

Name and address of Employer's

representative (if known) . . . . . . . . 3.2 .....

Performance security (if any):

Amount ................ 4.4 .....

Form .................. 4.4 ..... (details)

* Employer to amend as appropriate

ii
 Item Sub-Clause Data
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Requirements for Contractor's

design (if any) . . . . . . . . . . . . . . 5.1 ..... Specification Clause No’s

Programme:

Time for submission . . . . . . . . 7.2 . . . . . . Within 14 days* of the Commence-

ment Date.

Form of programme . . . . . . . . 7.2 . . . . . .

EN
Amount payable due to failure to
complete . . . . . . . . . . . . . . . . . 7.4 . . . . . . per day up
to a maximum of 10%* of sum
stated in the Agreement

Period for notifying defects . . . . 9.1 & 11.5 365 days* calculated from the
IM
date stated in the notice under
Sub-Clause 8.2
Variation procedure

Daywork rates . . . . . . . . . . . . 10.2 . . . . .

EC

(details)
Valuation of the Works*

Lump sum Price . . . . . . . . . . . 11.1 . . . . . (details)

Lump sum price with schedules

of rates . . . . . . . . . . . . . . . . . 11.1 . . . . . (details)
SP

Lump sum price with bill of

quantities . . . . . . . . . . . . . . . . 11.1 . . . . . (details)

Remeasurement with tender bill

of quantities . . . . . . . . . . . . . . 11.1 . . . . . (details)

Cost reimbursable . . . . . . . . . 11.1 . . . . . (details)

Percentage of value of Materials

and Plant . . . . . . . . . . . . . . . . . 11.2 . . . . . Materials 80%*

Plant 90%*

* Employer to amend as appropriate

iii
 Item Sub-Clause Data
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Percentage of retention . . . . . . . 11.3 . . . . . 5%

Currency of payment . . . . . . . . . 11.7 . . . . .

Rate of interest . . . . . . . . . . . . . 11.8 . . . . . % per annum

Insurances . . . . . . . . . . . . . . . . 14.1

Type of cover* Amount of cover* Exclusions*

EN
The Works, Materials, Plant The sum stated in the
and fees Agreement plus 15%

Contractor’s Equipment Full replacement cost

Third Party injury to persons

and damage to property
IM
Workers

Other cover*
EC

Arbitration

Rules . . . . . . . . . . . . . . . . . . . 15.3 . . . . . UNCITRAL Arbitration Rules*

(details)

Appointing authority . . . . . . . . 15.3 . . . . . President of FIDIC or his nominee*

(details)
SP

Place of Arbitration . . . . . . . . . 15.3 . . . . . The Country*

*Employer to amend as appropriate

iv
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

SHORT FORM of Contract

EN
GENERAL CONDITIONS

First Edition 1999

ISBN 2-88432-024-5
IM
EC
SP

FEDERATION INTERNATIONALE DES INGENIEURS-CONSEILS

INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS
INTERNATIONALE VEREINIGUNG BERATENDER INGENIEURE
FEDERACION INTERNACIONAL DE INGENIEROS CONSULTORES
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

EN
CONTENTS

General Conditions
IM
1 GENERAL PROVISIONS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1

1.1 Definitions
The Contract
Persons
EC

Dates, Times and Periods

Money and Payments
Other Definitions
1.2 Interpretation
1.3 Priority of Documents
1.4 Law
1.5 Communications
1.6 Statutory Obligations
SP

2 THE EMPLOYER . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2

2.1 Provision of Site

2.2 Permits and Licences
2.3 Employer's Instructions
2.4 Approvals

3 EMPLOYER’S REPRESENTATIVES . . . . . . . . . . . . . . . . . . . . . . . . . . 3

3.1 Authorised Person

3.2 Employer's Representative

4 THE CONTRACTOR . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3

4.1 General Obligations

4.2 Contractor's Representative
4.3 Subcontracting
4.4 Performance Security
a
 5 DESIGN BY CONTRACTOR . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3

5.1 Contractor's Design

5.2 Responsibility for Design

6 EMPLOYER’S LIABILITIES . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

6.1 Employer's Liabilities

7 TIME FOR COMPLETION . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5

7.1 Execution of the Works

7.2 Programme
7.3 Extension of Time
7.4 Late Completion

EN
8 TAKING-OVER . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5

8.1 Completion
8.2 Taking-Over Notice

9 REMEDYING EFFECTS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5

9.1 Remedying Defects

IM
9.2 Uncovering and Testing

10 VARIATIONS AND CLAIMS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 6

10.1 Right to Vary

EC

10.2 Valuation of Variations

10.3 Early Warning
10.4 Right to Claim
10.5 Variation and Claim Procedure

11 CONTRACT PRICE AND PAYMENT . . . . . . . . . . . . . . . . . . . . . . . . . . 7

11.1 Valuation of the Works

SP

11.2 Monthly Statements

11.3 Interim Payments
11.4 Payment of First Half of Retention
11.5 Payment of Second Half of Retention
11.6 Final Payment
11.7 Currency
11.8 Delayed Payment

12 DEFAULT . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8

12.1 Default by Contractor

12.2 Default by Employer
12.3 Insolvency
12.4 Payment upon Termination

13 RISK AND RESPONSIBILITY . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9

13.1 Contractor's Care of the Works

13.2 Force Majeure
b
 14 INSURANCE . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9

14.1 Extent of Cover

14.2 Arrangements
14.3 Failure to Insure

15 RESOLUTION OF DISPUTES . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 10
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

15.1 Adjudication
15.2 Notice of Dissatisfaction
15.3 Arbitration

INDEX . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 11

EN
IM
EC
SP

c
 General Conditions

1
General Provisions
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

1.1
Definitions In the Contract as defined below, the words and expressions defined shall have the
following meanings assigned to them, except where the context requires otherwise:

The Contract 1.1.1 "Contract" means the Agreement and the other documents listed in the
Appendix.

EN
1.1.2 "Specification" means the document as listed in the Appendix, including
Employer's requirements in respect of design to be carried out by the
Contractor, if any, and any Variation to such document.

1.1.3 "Drawings" means the Employer's drawings of the Works as listed in the
Appendix, and any Variation to such drawings.

Persons 1.1.4 "Employer" means the person named in the Agreement and the legal
IM
successors in title to this person, but not (except with the consent of the
Contractor) any assignee.

1.1.5 "Contractor" means the person named in the Agreement and the legal
successors in title to this person, but not (except with the consent of the
EC

Employer) any assignee.

1.1.6 "Party" means either the Employer or the Contractor.

Dates, Times and 1.1.7 "Commencement Date" means the date 14 days after the date the
Periods Agreement comes into effect or any other date agreed between the Parties.

1.1.8 "day" means a calendar day.

SP

1.1.9 "Time for Completion" means the time for completing the Works as stated
in the Appendix (or as extended under Sub-Clause 7.3), calculated from the
Commencement Date.

Money and Payments 1.1.10 "Cost" means all expenditure properly incurred (or to be incurred ) by the
Contractor, whether on or off the Site, including overheads and similar
charges, but does not include profit.

Other Definitions 1.1.11 "Contractor's Equipment" means all apparatus, machinery, vehicles,
facilities and other things required for the execution of the Works but does
not include Materials or Plant.

1.1.12 "Country" means the country in which the Site is located.

1.1.13 "Employer's Liabilities" means those matters listed in Sub-Clause 6.1.

1.1.14 "Force Majeure" means an exceptional event or circumstance: which is

beyond a Party's control; which such Party could not reasonably have
General Conditions 1
 provided against before entering into the Contract; which, having arisen,
such Party could not reasonably have avoided or overcome; and, which is
not substantially attributable to the other Party.

1.1.15 "Materials" means things of all kinds (other than Plant) intended to form or
forming part of the permanent work.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

1.1.16 "Plant" means the machinery and apparatus intended to form or forming
part of the permanent work.

1.1.17 "Site" means the places provided by the Employer where the Works are to
be executed, and any other places specified in the Contract as forming part
of the Site.

1.1.18 "Variation" means a change to the Specification and /or Drawings (if any)
which is instructed by the Employer under Sub-Clause 10.1.

EN
1.1.19 "Works" means all the work and design (if any) to be performed by the
Contractor including temporary work and any Variation

1.2
Interpretation Words importing persons or parties shall include firms and organisations. Words
importing singular or one gender shall include plural or the other gender where the
context requires.
IM
1.3
Priority of Documents The documents forming the Contract are to be taken as mutually explanatory of one
another. If an ambiguity or discrepancy is found in the documents, the Employer shall
issue any necessary instructions to the Contractor, and the priority of the documents
EC

shall be in accordance with the order as listed in the Appendix.

1.4
Law The law of the Contract is stated in the Appendix.

1.5
Communications Wherever provision is made for the giving or issue of any notice, instruction, or other
communication by any person, unless otherwise specified such communication shall
SP

be written in the language stated in the Appendix and shall not be unreasonably
withheld or delayed.

1.6
Statutory Obligations The Contractor shall comply with the laws of the countries where activities are
performed. The Contractor shall give all notices and pay all fees and other charges in
respect of the Works.

2.1
2
The Employer

Provision of Site The Employer shall provide the Site and right of access thereto at the times stated in
the Appendix.

2.2
Permits and Licences The Employer shall, if requested by the Contractor, assist him in applying for permits,
licences or approvals which are required for the Works.
2 Short Form of Contract
 2.3 The Contractor shall comply with all instructions given by the Employer in respect of
Employer’s Instructions the Works including the suspension of all or part of the Works.

2.4
Approvals No approval or consent or absence of comment by the Employer or the Employer's
representative shall affect the Contractor's obligations.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

3.1
3
Employer’s Representatives

Authorised Person One of the Employer's personnel shall have authority to act for him. This authorised
person shall be as stated in the Appendix, or as otherwise notified by the Employer to
the Contractor.

3.2

EN
Employer’s The Employer may also appoint a firm or individual to carry out certain duties. The
Representative appointee may be named in the Appendix, or notified by the Employer to the
Contractor from time to time. The Employer shall notify the Contractor of the delegated
duties and authority of this Employer's representative.

4
IM
The Contractor
4.1
General Obligations The Contractor shall carry out the Works properly and in accordance with the
Contract. The Contractor shall provide all supervision, labour, Materials, Plant and
EC

Contractor's Equipment which may be required. All Materials and Plant on Site shall
be deemed to be the property of the Employer.

4.2
Contractor’s The Contractor shall submit to the Employer for consent the name and particulars of
Representative the person authorised to receive instructions on behalf of the Contractor.

4.3
SP

Subcontracting The Contractor shall not subcontract the whole of the Works. The Contractor shall not
subcontract any part of the Works without the consent of the Employer.

4.4
Performance Security If stated in the Appendix, the Contractor shall deliver to the Employer within 14 days
of the Commencement Date a performance security in a form and from a third party
approved by the Employer.

5.1
5
Design by Contractor

Contractor’s Design The Contractor shall carry out design to the extent specified, as referred to in the
Appendix. The Contractor shall promptly submit to the Employer all designs
prepared by him. Within 14 days of receipt the Employer shall notify any comments
or, if the design submitted is not in accordance with the Contract, shall reject it
stating the reasons. The Contractor shall not construct any element of the
permanent work designed by him within 14 days after the design has been
General Conditions 3
 submitted to the Employer or where the design for that element has been rejected.
Design that has been rejected shall be promptly amended and resubmitted. The
Contractor shall resubmit all designs commented on taking these comments into
account as necessary.

5.2
Responsibility for The Contractor shall remain responsible for his tendered design and the design under
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Design this Clause, both of which shall be fit for the intended purposes defined in the Contract
and he shall also remain responsible for any infringement of any patent or copyright in
respect of the same. The Employer shall be responsible for the Specification and
Drawings.

6
Employer’s Liabilities

EN
6.1
Employer’s Liabilities In this Contract, Employer's Liabilities mean :

a) war, hostilities (whether war be declared or not), invasion, act of foreign

enemies, within the Country,
b) rebellion, terrorism, revolution, insurrection, military or usurped power, or civil
war, within the Country,
c) riot, commotion or disorder by persons other than the Contractor's personnel
IM
and other employees, affecting the Site and/or the Works,
d) ionising radiations, or contamination by radio-activity from any nuclear fuel, or
from any nuclear waste from the combustion of nuclear fuel, radio-active
toxic explosive, or other hazardous properties of any explosive nuclear
assembly or nuclear component of such an assembly, except to the extent to
EC

which the Contractor may be responsible for the use of any radio-active
material,
e) pressure waves caused by aircraft or other aerial devices travelling at sonic or
supersonic speeds,
f) use or occupation by the Employer of any part of the Works, except as may be
specified in the Contract,
g) design of any part of the Works by the Employer's personnel or by others for
whom the Employer is responsible, and
SP

h) any operation of the forces of nature affecting the Site and/or the Works, which
was unforeseeable or against which an experienced contractor could not
reasonably have been expected to take precautions.
i) Force Majeure,
j) a suspension under Sub-Clause 2.3 unless it is attributable to the Contractor's
failure,
k) any failure of the Employer,
l) physical obstructions or physical conditions other than climatic conditions,
encountered on the Site during the performance of the Works, which
obstructions or conditions were not reasonably foreseeable by an experienced
contractor and which the Contractor immediately notified to the Employer,
m) any delay or disruption caused by any Variation,
n) any change to the law of the Contract after the date of the Contractor's offer
as stated in the Agreement,
o) losses arising out of the Employer's right to have the permanent work executed
on, over, under, in or through any land, and to occupy this land for the
permanent work, and
p) damage which is an unavoidable result of the Contractor's obligations to
execute the Works and to remedy any defects.
4 Short Form of Contract
 7.1
7
Time for Completion

Execution of the Works The Contractor shall commence the Works on the Commencement Date and shall
proceed expeditiously and without delay and shall complete the Works within the Time
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

for Completion.

7.2
Programme Within the time stated in the Appendix, the Contractor shall submit to the Employer a
programme for the Works in the form stated in the Appendix.

7.3
Extension of Time Subject to Sub-Clause 10.3, the Contractor shall be entitled to an extension to
the Time for Completion if he is or will be delayed by any of the Employer's

EN
Liabilities.

On receipt of an application from the Contractor, the Employer shall consider all
supporting details provided by the Contractor and shall extend the Time for
Completion as appropriate.

7.4
Late Completion If the Contractor fails to complete the Works within the Time for Completion, the
IM
Contractor's only liability to the Employer for such failure shall be to pay the
amount stated in the Appendix for each day for which he fails to complete the
Works.

8
EC

Taking-Over
8.1
Completion The Contractor may notify the Employer when he considers that the Works are
complete.

8.2
SP

Taking-Over Notice The Employer shall notify the Contractor when he considers that the Contractor has
completed the Works stating the date accordingly. Alternatively, the Employer may
notify the Contractor that the Works, although not fully complete, are ready for taking
over, stating the date accordingly.

The Employer shall take over the Works upon the issue of this notice. The Contractor
shall promptly complete any outstanding work and, subject to Clause 9, clear the
Site.

9.1
9
Remedying Defects

Remedying Defects The Employer may at any time prior to the expiry of the period stated in the Appendix,
notify the Contractor of any defects or outstanding work. The Contractor shall remedy
at no cost to the Employer any defects due to the Contractor's design, Materials,
Plant or workmanship not being in accordance with the Contract.
General Conditions 5
 The cost of remedying defects attributable to any other cause shall be valued as a
Variation. Failure to remedy any defects or complete outstanding work within a
reasonable time of the Employer's notice shall entitle the Employer to carry out all
necessary work at the Contractor's cost.

9.2
Uncovering and Testing The Employer may give instruction as to the uncovering and/or testing of any work.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Unless as a result of any uncovering and/or testing it is established that the

Contractor's design, Materials, Plant or workmanship are not in accordance with the
Contract, the Contractor shall be paid for such uncovering and/or testing as a
Variation in accordance with Sub-Clause 10.2.

10
Variations and Claims

EN
10.1
Right to Vary The Employer may instruct Variations.

10.2
Valuation of Variations Variations shall be valued as follows:

a) at a lump sum price agreed between the Parties, or

b) where appropriate, at rates in the Contract, or
IM
c) in the absence of appropriate rates, the rates in the Contract shall be used as
the basis for valuation, or failing which
d) at appropriate new rates, as may be agreed or which the Employer considers
appropriate, or
e) if the Employer so instructs, at daywork rates set out in the Appendix for which
EC

the Contractor shall keep records of hours of labour and Contractor's

Equipment, and of Materials used.

10.3
Early Warning A Party shall notify the other as soon as he is aware of any circumstance which may
delay or disrupt the Works, or which may give rise to a claim for additional payment.
The Contractor shall take all reasonable steps to minimise these effects.
SP

The Contractor's entitlement to extension to the Time for Completion or additional

payment shall be limited to the time and payment which would have been due if he
had given prompt notice and had taken all reasonable steps.

10.4
Right to Claim If the Contractor incurs Cost as a result of any of the Employer's Liabilities, the
Contractor shall be entitled to the amount of such Cost. If as a result of any of the
Employer's Liabilities, it is necessary to change the Works, this shall be dealt with as
a Variation.

10.5
Variation and Claim The Contractor shall submit to the Employer an itemised make-up of the value of
Procedure Variations and claims within 28 days of the instruction or of the event giving rise to the
claim. The Employer shall check and if possible agree the value. In the absence of
agreement, the Employer shall determine the value.

6 Short Form of Contract

 11.1
11
Contract Price and Payment

Valuation of the Works The Works shall be valued as provided for in the Appendix, subject to Clause 10.

11.2
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Monthly Statements The Contractor shall be entitled to be paid at monthly intervals:

a) the value of the Works executed,

b) the percentage stated in the Appendix of the value of Materials and Plant
delivered to the Site at a reasonable time,

subject to any additions or deductions which may be due.

EN
The Contractor shall submit each month to the Employer a statement showing the
amounts to which he considers himself entitled.

11.3
Interim Payments Within 28 days of delivery of each statement, the Employer shall pay to the Contractor
the amount shown in the Contractor's statement less retention at the rate stated in
the Appendix, and less any amount for which the Employer has specified his reasons
for disagreement. The Employer shall not be bound by any sum previously considered
IM
by him to be due to the Contractor.

The Employer may withhold interim payments until he receives the performance
security under Sub-Clause 4.4 (if any).

11.4
EC

Payment of First Half of One half of the retention shall be paid by the Employer to the Contractor within 14
Retention days after issuing the notice under Sub-Clause 8.2.

11.5
Payment of Second Half The remainder of the retention shall be paid by the Employer to the Contractor within
of Retention 14 days after either the expiry of the period stated in the Appendix, or the remedying
of notified defects or the completion of outstanding work, all as referred to in Sub-
SP

Clause 9.1, whichever is the later.

11.6
Final Payment Within 42 days of the latest of the events listed in Sub-Clause 11.5 above, the
Contractor shall submit a final account to the Employer together with any
documentation reasonably required to enable the Employer to ascertain the final
contract value.

Within 28 days after the submission of this final account, the Employer shall pay to the
Contractor any amount due. If the Employer disagrees with any part of the
Contractor's final account, he shall specify his reasons for disagreement when making
payment.

11.7
Currency Payment shall be in the currency stated in the Appendix.

11.8
Delayed Payment The Contractor shall be entitled to interest at the rate stated in the Appendix for each
day the Employer fails to pay beyond the prescribed payment period.
General Conditions 7
 12.1
12
Default

Default by Contractor If the Contractor abandons the Works, refuses or fails to comply with a valid
instruction of the Employer or fails to proceed expeditiously and without delay, or is,
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

despite a written complaint, in breach of the Contract, the Employer may give notice
referring to this Sub-Clause and stating the default.

If the Contractor has not taken all practicable steps to remedy the default within 14
days after the Contractor's receipt of the Employer's notice, the Employer may by a
second notice given within a further 21 days, terminate the Contract. The Contractor
shall then demobilise from the Site leaving behind Materials and Plant and any
Contractor's Equipment which the Employer instructs in the second notice is to be
used until the completion of the Works.

EN
12.2
Default by Employer If the Employer fails to pay in accordance with the Contract, or is, despite a written
complaint, in breach of the Contract, the Contractor may give notice referring to this
Sub-Clause and stating the default. If the default is not remedied within 7 days after
the Employer's receipt of this notice, the Contractor may suspend the execution of all
or parts of the Works.
IM
If the default is not remedied within 28 days after the Employer's receipt of the
Contractor's notice, the Contractor may by a second notice given within a further
21 days, terminate the Contract. The Contractor shall then demobilise from the
Site.

12.3
EC

Insolvency If a Party is declared insolvent under any applicable law, the other Party may by notice
terminate the Contract immediately. The Contractor shall then demobilise from the Site
leaving behind, in the case of the Contractor's insolvency, any Contractor's
Equipment which the Employer instructs in the notice is to be used until the
completion of the Works.

12.4
SP

Payment upon After termination, the Contractor shall be entitled to payment of the unpaid balance of
Termination the value of the Works executed and of the Materials and Plant reasonably delivered
to the Site, adjusted by the following:

a) any sums to which the Contractor is entitled under Sub-Clause 10.4,

b) any sums to which the Employer is entitled,
c) if the Employer has terminated under Sub-Clause 12.1 or 12.3, the Employer
shall be entitled to a sum equivalent to 20% of the value of those parts of the
Works not executed at the date of the termination,
d) if the Contractor has terminated under Sub-Clause 12.2 or 12.3, the Contractor
shall be entitled to the Cost of his suspension and demobilisation together with
a sum equivalent to 10% of the value of those parts of the Works not executed
at the date of termination.

The net balance due shall be paid or repaid within 28 days of the notice of
termination.

8 Short Form of Contract

 13.1
13
Risk and Responsibility

Contractor’s Care of the The Contractor shall take full responsibility for the care of the Works from the
Works Commencement Date until the date of the Employer's notice under Sub-Clause 8.2.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Responsibility shall then pass to the Employer. If any loss or damage happens to the
Works during the above period, the Contractor shall rectify such loss or damage so
that the Works conform with the Contract.

Unless the loss or damage happens as a result of an Employer's Liability, the

Contractor shall indemnify the Employer, the Employer's contractors, agents and
employees against all loss or damage happening to the Works and against all claims
or expense arising out of the Works caused by a breach of the Contract, by
negligence or by other default of the Contractor, his agents or employees.

EN
13.2
Force Majeure If a Party is or will be prevented from performing any of its obligations by Force
Majeure, the Party affected shall notify the other Party immediately. If necessary, the
Contractor shall suspend the execution of the Works and, to the extent agreed with
the Employer, demobilise the Contractor's Equipment.

If the event continues for a period of 84 days, either Party may then give notice of
IM
termination which shall take effect 28 days after the giving of the notice.

After termination, the Contractor shall be entitled to payment of the unpaid balance of
the value of the Works executed and of the Materials and Plant reasonably delivered
to the Site, adjusted by the following:
EC

a) any sums to which the Contractor is entitled under Sub-Clause 10.4,

b) the Cost of his suspension and demobilisation,
c) any sums to which the Employer is entitled.

The net balance due shall be paid or repaid within 28 days of the notice of
termination.
SP

14.1
14
Insurance

Extent of Cover The Contractor shall, prior to commencing the Works, effect and thereafter maintain
insurances in the joint names of the Parties:

a) for loss and damage to the Works, Materials, Plant and the Contractor's
Equipment,
b) for liability of both Parties for loss, damage, death or injury to third parties or
their property arising out of the Contractor's performance of the Contract,
including the Contractor's liability for damage to the Employer's property other
than the Works, and
c) for liability of both Parties and of any Employer's representative for death or
injury to the Contractor's personnel except to the extent that liability arises from
the negligence of the Employer, any Employer's representative or their
employees.
General Conditions 9
 14.2 All insurances shall conform with any requirements detailed in the Appendix. The
Arrangements policies shall be issued by insurers and in terms approved by the Employer. The
Contractor shall provide the Employer with evidence that any required policy is in force
and that the premiums have been paid.

All payments received from insurers relating to loss or damage to the Works shall be
held jointly by the Parties and used for the repair of the loss or damage or as
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

compensation for loss or damage that is not to be repaired.

14.3
Failure to Insure If the Contractor fails to effect or keep in force any of the insurances referred to in the
previous Sub-Clauses, or fails to provide satisfactory evidence, policies or receipts,
the Employer may, without prejudice to any other right or remedy, effect insurance for
the cover relevant to such default and pay the premiums due and recover the same
as a deduction from any other monies due to the Contractor.

15
EN
Resolution of Disputes
15.1
Adjudication Unless settled amicably, any dispute or difference which arises between the
Contractor and the Employer out of or in connection with the Contract, including any
valuation or other decision of the Employer, shall be referred by either Party to
IM
adjudication in accordance with the attached Rules for Adjudication ("the Rules"). The
adjudicator shall be any person agreed by the Parties. In the event of disagreement,
the adjudicator shall be appointed in accordance with the Rules.

15.2
EC

Notice of Dissatisfaction If a Party is dissatisfied with the decision of the adjudicator or if no decision is given
within the time set out in the Rules, the Party may give notice of dissatisfaction
referring to this Sub-Clause within 28 days of receipt of the decision or the expiry of
the time for the decision. If no notice of dissatisfaction is given within the specified
time, the decision shall be final and binding on the Parties. If notice of dissatisfaction
is given within the specified time, the decision shall be binding on the Parties who shall
give effect to it without delay unless and until the decision of the adjudicator is revised
by an arbitrator.
SP

15.3
Arbitration A dispute which has been the subject of a notice of dissatisfaction shall be finally
settled by a single arbitrator under the rules specified in the Appendix. In the absence
of agreement, the arbitrator shall be designated by the appointing authority specified
in the Appendix. Any hearing shall be held at the place specified in the Appendix and
in the language referred to in Sub-Clause 1.5.

10 Short Form of Contract

 INDEX OF SUB-CLAUSES
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Sub-Clause Page

Adjudication 15.1 10
Approvals 2.4 3
Arbitration 15.3 10
Arrangements, Insurance 14.2 10
Authorised person 3.1 3

Communications 1.5 2

EN
Completion 8.1 5
Contractor's Care of the Works 13.1 9
Contractor's Design 5.1 3
Contractor's Representative 4.2 3
Currency 11.7 7

Default by Contractor 12.1 8

Default by Employer 12.2 8
IM
Definitions 1.1 1
Delayed Payment 11.8 7

Early Warning, Claims 10.3 6

Employer's Instructions 2.3 3
EC

Employer's Representative 3.2 3

Employer's Liabilities 6.1 4
Execution of the Works 7.1 5
Extension of Time 7.3 5
Extent of Cover, Insurance 14.1 9

Failure to Insure 14.3 10

Final Payment 11.6 7
SP

Force Majeure 13.2 9

General Obligations, Contractor 4.1 3

Insolvency 12.3 8
Interim Payments 11.3 7
Interpretation 1.2 2

Late Completion 7.4 5

Law 1.4 2

Monthly Statements 11.2 7

Notice of Dissatisfaction 15.2 10

Payment upon Termination 12.4 8

Performance Security 4.4 3
Permits and Licences 2.2 2
Priority of Documents 1.3 2
General Conditions 11
 Programme 7.2 5
Provision of Site 2.1 2

Remedying Defects 9.1 5

Responsibility for Design 5.2 4
Retention, First Half 11.4 7
Retention, Second Half 11.5 7
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Right to Claim 10.4 6

Right to Vary 10.1 6

Statutory Obligations 1.6 2

Subcontracting 4.3 3

Taking-Over Notice 8.2 5

Uncovering and Testing 9.2 6

EN
Valuation of the Works 11.1 7
Valuation of Variations 10.2 6
Variation and Claim Procedure 10.5 6
IM
EC
SP

12 Short Form of Contract

 Particular Conditions
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Note It is intended that the Short Form of Contract will work satisfactorily without any
Particular Conditions. However, if the requirement of the project makes it desirable to
amend any Clause or to add provisions to the Contract, the amendments and
additions should be set out on pages headed Particular Conditions. Care should be
taken with the drafting of such Clauses especially in view of the high priority given to
the Particular Conditions by Sub-Clause 1.3.

EN
IM
EC
SP

13
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

14
SP
EC
IM
EN
 Rules for Adjudication
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

referred to in Sub-Clause 15.1

General 1 Any reference in the Conditions of Contract to the Rules for Adjudication shall
be deemed to be a reference to these Rules.

2 Definitions in the Contract shall apply in these Rules.

EN
Appointment of 3 The Parties shall jointly ensure the appointment of the Adjudicator. The
Adjudicator Adjudicator shall be a suitably qualified person.

4 If for any reason the appointment of the Adjudicator is not agreed at the latest
within 14 days of the reference of a dispute in accordance with these Rules,
then either Party may apply, with a copy of the application to the other Party, to
IM
any appointing authority named in the Contract or, if none, to the President of
FIDIC or his nominee, to appoint an Adjudicator, and such appointment shall be
final and conclusive.

5 The Adjudicator's appointment may be terminated by mutual agreement of the

EC

Parties. The Adjudicator's appointment shall expire when the Works have been
completed or when any disputes referred to the Adjudicator shall have been
withdrawn or decided, whichever is the later.

Terms of Appointment 6 The Adjudicator is to be, and is to remain throughout his appointment, impartial
and independent of the Parties and shall immediately disclose in writing to the
Parties anything of which he becomes aware which could affect his impartiality
SP

or independence.

7 The Adjudicator shall not give advice to the Parties or their representatives
concerning the conduct of the project of which the Works form part other than
in accordance with these Rules.

8 The Adjudicator shall not be called as a witness by the Parties to give evidence
concerning any dispute in connection with, or arising out of, the Contract.

9 The Adjudicator shall treat the details of the Contract and all activities and
hearings of the Adjudicator as confidential and shall not disclose the same
without the prior written consent of the Parties. The Adjudicator shall not,
without the consent of the Parties, assign or delegate any of his work under
these Rules or engage legal or technical assistance.

10 The Adjudicator may resign by giving 28 days' notice to the Parties. In the event
of resignation, death or incapacity, termination or a failure or refusal to perform
the duties of Adjudicator under these Rules, the Parties shall agree upon a
replacement Adjudicator within 14 days or Rule 4 shall apply.
Rules for Adjudication 15
 11 The Adjudicator shall in no circumstances be liable for any claims for anything
done or omitted in the discharge of the Adjudicator's duties unless the act or
omission is shown to have been in bad faith.

12 If the Adjudicator shall knowingly breach any of the provisions of Rule 6 or act
in bad faith, he shall not be entitled to any fees or expenses hereunder and shall
reimburse each of the Parties for any fees and expenses properly paid to him
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

if, as a consequence of such breach any proceedings or decisions of the

Adjudicator are rendered void or ineffective.

Payment 13 The Adjudicator shall be paid the fees and expenses set out in the Adjudicator's
Agreement.

14 The retainer fee, if applicable, shall be payment in full for:

EN
(a) being available, on 28 days' notice, for all hearings and Site visits;
(b) all office overhead expenses such as secretarial services, photocopying
and office supplies incurred in connection with his duties;
(c) all services performed hereunder except those performed during the
days referred to in Rule 15.

15 The daily fee shall be payable for each working day preparing for or attending
Site visits or hearings or preparing decisions including any associated travelling
IM
time.

16 The retainer and daily fees shall remain fixed for the period of tenure of the
Adjudicator.
EC

17 All payments to the Adjudicator shall be made by the Contractor who will be
entitled to be reimbursed half by the Employer. The Contractor shall pay
invoices addressed to him within 28 days of receipt. The Adjudicator's invoices
for any monthly retainer shall be submitted quarterly in advance and invoices
for daily fees and expenses shall be submitted following the conclusion of a Site
visit or hearing. All invoices shall contain a brief description of the activities
performed during the relevant period. The Adjudicator may suspend work if any
invoice remains unpaid at the expiry of the period for payment, provided that 7
SP

days prior notice has been given to both Parties.

18 If the Contractor fails to pay an invoice addressed to it, the Employer shall be
entitled to pay the sum due to the Adjudicator and recover the sum paid from
the Contractor.

Procedure for Obtaining 19 A dispute between the Parties may be referred in writing by either Party to the
Adjudicator's Decision Adjudicator for his decision, with a copy to the other Party. If the Adjudicator
has not been agreed or appointed, the dispute shall be referred in writing to the
other Party, together with a proposal for the appointment of an Adjudicator. A
reference shall identify the dispute and refer to these Rules.

20 The Adjudicator may decide to visit the Site. The Adjudicator may decide to
conduct a hearing in which event he shall decide on the date, place and
duration for the hearing. The Adjudicator may request that written statements
from the Parties be presented to him prior to, at or after the hearing. The Parties
shall promptly provide the Adjudicator with sufficient copies of any
documentation and information relevant to the Contract that he may request.
16 Short Form of Contract
 21 The Adjudicator shall act as an impartial expert, not as an arbitrator, and shall
have full authority to conduct any hearing as he thinks fit, not being bound by
any rules or procedures other than those set out herein. Without limiting the
foregoing, the Adjudicator shall have power to:

(a) decide upon the Adjudicator's own jurisdiction, and as to the scope of
any dispute referred to him,
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

(b) make use of his own specialist knowledge, if any,

(c) adopt an inquisitorial procedure,
(d) decide upon the payment of interest in accordance with the Contract,
(e) open up, review and revise any opinion, instruction, determination,
certificate or valuation, related to the dispute,
(f) refuse admission to hearings to any persons other than the Employer,
the Contractor and their respective representatives, and to proceed in
the absence of any Party who the Adjudicator is satisfied received notice
of the hearing.

EN
22 All communications between either of the Parties and the Adjudicator and all
hearings shall be in the language of the Adjudicator's Agreement. All such
communications shall be copied to the other Party.

23 No later than the fifty-sixth day after the day on which the Adjudicator received
a reference or, if later, the day on which the Adjudicator's Agreement came into
effect, the Adjudicator shall give written notice of his decision to the Parties.
IM
Such decision shall include reasons and state that it is given under these Rules.
EC
SP

Rules for Adjudication 17

 Adjudicator’s Agreement
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Identification of Project:

(the "Project")

Name and address of the Employer:

EN
(the “Employer”)

Name and address of Contractor:

IM
(the "Contractor")

Name and address of Adjudicator:

EC

(the "Adjudicator")

Whereas the Employer and the Contractor have entered into a contract ("the
Contract") for the execution of the Project and wish to appoint the Adjudicator to act
as adjudicator in accordance with the Rules for Adjudication ["the Rules"].
SP

The Employer, Contractor and Adjudicator agree as follows:

1. The Rules and the dispute provisions of the Contract shall form part of this
Agreement.

2. The Adjudicator shall be paid:

A retainer fee of per calendar month

(where applicable)

A daily fee of

Expenses (including the cost of telephone calls, courier charges, faxes and
telexes incurred in connection with his duties; all reasonable and necessary
travel expenses, hotel accommodation and subsistence and other direct travel
expenses).

Receipts will be required for all expenses.

18
 3. The Adjudicator agrees to act as adjudicator in accordance with the Rules and
has disclosed to the Parties any previous or existing relationship with the
Parties or others concerned with the Project.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

4. This Agreement shall be governed by the law of

5. The language of this Agreement shall be

SIGNED BY

EN
for and on behalf of the Employer in the presence of

Witness
Name
Address
Date
IM
SIGNED BY

for and on behalf of the Contractor in the presence of

EC

Witness
Name
Address
Date
SP

SIGNED BY

for and on behalf of the Adjudicator in the presence of

Witness
Name
Address
Date

19
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

20
SP
EC
IM
EN
 Notes for Guidance
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

(not forming part of the Contract)

General The objective of this Contract is to express in clear and simple terms traditional
procurement concepts. The Contract is intended to be suitable for works of simple
content and short duration. If it is required that the Contractor should undertake
design, this is also provided for.

EN
There are no Particular Conditions, although these Notes contain alternative wording
for consideration in particular circumstances. All necessary additional information is
intended to be provided in the Appendix.

A single document is proposed for the form of tender and the agreement. This reflects
the simple projects envisaged.
IM
One result of the simple form of Contract is that there is an increased burden on the
Employer to set out in the Specification and Drawings the full scope of works,
including the extent of any design to be done by the Contractor.

There is no Engineer or Employer's Representative in the formal sense used in some

EC

other FIDIC Conditions. The Employer takes all necessary actions. However, the
Employer must nominate his authorised spokesman and, if he wishes to engage a
consultant to administer the Contract, may appoint a representative with specific
delegated duties and authority. The Contractor also nominates a representative.

The Conditions contain no overall limit on the Contractor's liability. If such a limit is
required, a Clause should be inserted in the Particular Conditions.
SP

Agreement The printed form envisages a simple procedure of offer and acceptance. In order to
avoid the traps and uncertainties that surround "letters of acceptance" and "letters of
intent", it was thought preferable to promote a clear and unambiguous practice.

It is intended that the Employer will write in the Employer's name in the Agreement
and fill in the Appendix where appropriate and send two copies to tenderers together
with the Specification, Drawings etc forming the tender package. In respect of both
copies, the Contractor is to complete, sign and date the Offer section and complete
any remaining spaces in the Appendix. Having decided which tender to accept, the
Employer signs the Acceptance section of both copies and returns one copy to the
Contractor. The Contract comes into effect upon receipt by the Contractor of his copy.

If post-tender negotiations are permitted and changes in specification or price are

agreed, then the form can still be used after the Parties have made and initialled the
appropriate changes to their respective documents. The Contractor thus makes a
revised offer in response to the Employer's revised tender documents and the revised
offer is accepted by the Employer signing and returning the Acceptance form. If the
changes are extensive, a new form of Agreement should be completed by the Parties.
Notes for Guidance 21
 As the Contract comes into effect upon receipt of the signed Acceptance by the
Contractor, the Employer should take steps to establish when receipt occurs, for
example by requiring the Contractor to collect and sign for the Agreement.

When the applicable law imposes any form of tax such as VAT on the Works, the
Employer should make clear whether tenderers should include such taxes in their
prices. Similarly, if payment is to be made in whole or in part in a currency other than
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

the currency of the Country, the Employer should make this clear to tenderers. See
Sub-Clause 11.7.

Appendix Any Notes for Guidance on the completion of the Appendix are to be found in the
Notes to the Clauses concerned. The Employer should complete the Appendix as
indicated prior to inviting tenders. Tenderers may be asked to insert a Time for
Completion at 1.1.9 if none is specified. Where tenderers are required to submit
design with their tenders, the documents containing the tendered design should be

EN
identified by the tenderer against item 1.1.1(f) of the Appendix.

A number of suggestions have been made in the Appendix, such as the time for
submission of the Contractor's programme under Sub-Clause 7.2 and the amount of
retention under Sub-Clause 11.3. If these suggestions are adopted by the Employer,
no action is required. Otherwise, they should be deleted and replaced.
IM
General Provisions 1.1 Definitions. The definitions in these Conditions are not all the same as
those to be found in other FIDIC Contracts. This is as a result of the need
for simplicity in Conditions of this sort. Significantly different definitions
include Commencement Date, Site, Variation and Works.
EC

1.1.1 "Contract". The list of documents serves two purposes: firstly, to identify
which documents form part of the Contract; and secondly, to provide an
order of priority in the event of conflict between them.

Document identification is necessary to avoid any possible doubt, for example

because specifications have been subject to revisions. A complete list of
Drawings is always desirable and could be attached on a separate sheet.
SP

There is no need for Particular Conditions but if amendments to these

Conditions are required, they should be inserted on the sheet headed
Particular Conditions and given priority over the General Conditions. If none,
delete the reference.

The Specification should set out in clear terms any design that the
Contractor is required to undertake, including the extent to which any
design proposals are to be submitted with the tender. If none, the reference
to the Contractor's tendered design should be deleted.

If there is no bill of quantities, delete the reference.

If there are additional documents which are required to form part of the
Contract, such as schedules of information provided by the Contractor,
these should be added by the Employer. Consideration should be given in
each case to the required priority.

If a letter of acceptance is used, it should be given high priority, with or in

place of the Agreement, for example.
22 Short Form of Contract
 1.1.7 "Commencement Date". The starting date for the Contract is 14 days after
the date when the Contractor receives the Agreement signed by the
Employer, unless the Parties agree otherwise.

1.1.14 "Force Majeure" may include, but is not limited to, exceptional events or
circumstances of the kind listed below, so long as all of the four conditions
stated in the definition have been satisfied:
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

a) war, hostilities (whether war be declared or not), invasion, act of

foreign enemies,
b) rebellion, terrorism, revolution, insurrection, military or usurped
power, or civil war,
c) riot, commotion, disorder, strike or lockout by persons other than the
Contractor's personnel and other employees,
d) munitions of war, explosive materials, ionising radiation or
contamination by radioactivity, except as may be attributable to the

EN
Contractor's use of such munitions, explosives, radiation or radio-
activity, and
e) natural catastrophes such as earthquake, hurricane, typhoon or
volcanic activity.

1.1.19 “Works”. The term "Works" is intended to cover all the obligations of the
Contractor, including any design and the remedying of defects.
IM
1.5 Communications. The problem of languages is addressed by requiring the
important communications such as notices and instructions to be in the
language stated in the Appendix. Otherwise there is no "Ruling Language".
Any arbitration will be conducted in the specified language.
EC

1.6 Changes to the law after the date of the Contractor's offer are at the
Employer's risk and any delay or additional cost are recoverable by the
Contractor. If the law of the Contract is not the law of the Country, then Sub-
Clause 6.1 should be changed in the Particular Conditions.

The Employer 2.1 Unless the Parties have agreed otherwise, the Site must be handed over by
the Employer to the Contractor on the Commencement Date. This is 14
SP

days after the Contract has come into effect, which occurs when the signed
Agreement has been returned by the Employer to the Contractor (see also
Sub-Clause 1.1.7 above).

2.2 If for any reason, permits etc may also be required from places other than
the Country, this Sub-Clause could be limited by the addition at the end of
the words:

"... in the Country but not elsewhere."

2.4 The term "approval" is only used in the Conditions in relation to the
performance security at Sub-Clause 4.4 and insurances at Sub-Clause
14.1. It is important that risks such as those of poor workmanship or
Contractor's design are not transferred to the Employer unintentionally. The
Sub-Clause is intended to prevent argument.

Employer's 3 Two principles guided the drafting of this Clause. Firstly, the Contractor
Representatives should know who in an Employer organisation is authorised to speak and
Notes for Guidance 23
 act for the Employer at any given time. This is achieved by Sub-Clause 3.1:
the authorised individual should be named in the Appendix.

Secondly, those Employers who require professional assistance should not

be discouraged from doing so and their consultant should have clearly
established delegated powers. This is the object of Sub-Clause 3.2. Once
appointed, the Employer's representative acts for and in the interests of the
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Employer. There is no dual role or duty to be impartial. If an impartial

Employer's Representative is required with a role similar to the traditional
Engineer, then the following words could be used in the Particular
Conditions:

"Replace the final sentence of Sub-Clause 3.2 with the following: "The
Employer's Representative shall exercise in a fair and impartial manner
the powers of the Employer under or in connection with the following
Sub-Clauses: 1.3, 2.3, 4.2, 4.3, 5.1, 7.3, 8.2, 9.1, 9.2, 10.1, 10.2, 10.5,

EN
11.1 to 11.6, 11.8, 12.1, 13.2 and 14.1."

To the extent that the Employer has delegated powers to an Employer's

representative, he should be careful not to exercise such powers himself in
order to avoid the risk of conflicting instructions, decisions etc.

The Contractor 4.1 Most contracts do not specify the exact standard required for each element
IM
of the Works, so some benchmark standard is needed with which the
Contractor is to comply. If a more specific set of standards could be referred
to for a particular project, then an amendment in the Particular Conditions
would be desirable.
EC

4.4 Performance Security. Suggested forms of performance bond (surety

bond) or bank guarantee have not been provided. If it is felt that the scale
of project warrants security by means of a bond, then local commercial
practice should dictate the form. Example forms are included with FIDIC's
Conditions of Contract for Construction. The amount and a reference to
the desired form of any required security should be set out in the
Appendix.
SP

Design by Contractor 5.1 As with all design-build contracts it is essential that the Employer's
requirements are set out clearly and precisely. The Appendix should indicate
to tenderers the Sub-Clause(s) in the Specification that set out the design
requirement. Where the Employer procures any part of the design, the
responsibility for design will be shared as this Contract makes the
Contractor responsible only for design prepared by him. The extent of the
Contractor's design obligation should therefore be clearly stated if disputes
are to be avoided. The Conditions avoid the confusing concept of approval
of design. Designs are submitted and may be returned with comments or
rejected. The Employer need not react at all.

5.2 The Contractor's responsibility for his design remains, as is made clear here
and in Sub-Clause 2.4. In the event of conflict between the Specification
and Drawings and the Contractor's tendered design, the order of priority in
the Appendix makes it clear that the Employer's documents prevail. This
means that if the Employer prefers the Contractor's tendered solution, the
Specification and Drawings should be amended before the Contract is
signed by the Parties.
24 Short Form of Contract
 The Contractor will have an absolute obligation to ensure that the parts of
the Works designed by him are fit for their purpose, provided that the
intended purposes are defined in the Contract. The Employer must
therefore make clear in the parts of the Specification that impose design
obligations, the intended purposes of the part of the Works to be designed
by the Contractor. This should be done even where this seems obvious in
order to avoid argument about whether an intended purpose is defined or
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

not.

If a party wishes to protect the intellectual property in his design, provision

must be made in the Particular Conditions.

Employer's Liabilities 6.1 This Sub-Clause gathers together in one place the grounds for extension of
time under Sub-Clause 7.3 and the grounds for claims under Sub-Clause
10.4. There is no time or claim for bad weather although this could be

EN
adjusted in the Particular Conditions if so required.

Time for Completion 7.2 The Appendix should stipulate any particular requirements as to the form
and level of detail of programme to be submitted. Where Contractor's
design is required, the Appendix could stipulate that the programme should
show the dates on which it is intended to prepare and submit drawings etc.
IM
7.3 The test for entitlement to an extension of time is whether it is appropriate.
This means that if an event under Sub-Clause 6.1 caused critical delay to
the Works and it is fair and reasonable to grant an extension of time, the
Employer should do so. An extension of time should not be granted to the
extent that any failure by the Contractor to give an early warning notice
EC

under Sub-Clause 10.3 contributed to the delay.

7.4 There is a maximum amount which the Contractor is liable to pay for late
completion specified in the Appendix. 10% of the sum stated in the
Agreement is suggested.

Taking-Over 8.2 In line with normal practice, it is not envisaged that the Works need be
SP

100% complete before the Employer may take over. Once the Works are
ready to be used for their intended purpose, the notice should be given.
There is no provision for taking-over of only parts of the Works but if this is
required, provision should be made in the Particular Conditions.

If any tests are required to be completed prior to taking-over, these should

be specified in the Specification. The definition of Works is broad enough to
include any such tests.

Remedying Defects 9.1 There is no defined Defects Liability Period but during the period - normally
12 months - from the date of taking-over, the Employer may notify the
Contractor of defects. The Contractor must remedy such defects within a
reasonable time. If he fails to do so, the Employer may employ others for
that purpose at the Contractor's cost. The Employer may also notify defects
at any time prior to taking-over.

The liability of the Contractor for defects will not normally end with the expiry
of the period stated in the Appendix. Although he is then no longer obliged
Notes for Guidance 25
 to return to Site to remedy defects, the defect represents a breach of
contract for which the Contractor is liable in damages. This liability remains
for as long as the law of the Contract stipulates, often 3, 6 or 10 years from
the date of the breach. If this long-term liability is to be reduced or
eliminated, a Clause in the Particular Conditions is required.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Variations and Claims 10.1 Variation is defined to include any change to the Specification or Drawings
included in the Contract. If the Employer requires a change to part of the
Works designed by the Contractor either as part of his tender or after the
Contract was awarded, then this is to be done by way of an addition to the
Specification or Drawings which by Sub-Clause 5.2 will prevail over
Contractor's design.

10.2 This Sub-Clause sets out alternative procedures for the valuation of
Variations, to be applied in the order of priority given. It applies equally to

EN
omissions as to additional works.

a) A lump sum should be the first method to be considered as it can

encompass the true cost of a Variation and avoid subsequent
dispute over the indirect effect. The Employer can invite the
Contractor to submit an itemised make-up (Sub-Clause 10.5) before
instructing the Variation so that an agreed lump sum can form part
of the instruction.
IM
b) Alternatively, a more traditional approach can be taken by valuing the
Variation at rates in the bill of quantities and any schedules, or
c) using these rates as a basis, or
d) using new rates.
e) Daywork rates are normally used when the Variation is of an
EC

indeterminate nature or is out of sequence with the remaining Works.

To ensure reasonable daywork rates, provision should be made for
these to be priced competitively in the tender documents.

10.3 This Sub-Clause and Sub-Clause 10.5 require the Contractor to notify the
Employer of events promptly and to detail any claim within 28 days. If the
effects of the event are increased or if the ability of the Employer to verify any
claim is affected by the failure to notify, then the Employer is protected.
SP

Contract Price and 11.1 Normally only one of the options in the Appendix should be used to indicate
Payment how the sum in the offer is be calculated and presented. The following
explains what is intended:

Lump sum price A lump sum offer without any supporting details.
This would be used for very minor works where
Variations are not anticipated and the Works will
be completed in a short period requiring only one
payment to the Contractor.

Lump sum price with A lump sum offer supported by schedules of

schedule of rates rates prepared by the tenderer. This would be a
larger contract where Variations and stage
payments would be required. If the Employer
does not have the resources to prepare his own
bill of quantities then this alternative would be
suitable.
26 Short Form of Contract
 Lump sum price with A lump sum offer based on bill of quantities
bill of quantities prepared by the Employer. This would be the
same as last but where the Employer has the
resources to prepare his own bill of quantities. A
better contract would result with an Employer’s
bill of quantities.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

Remeasurement with A sum subject to remeasurement at the rates

bill of quantities offered by the tenderer in the bill of quantities
prepared by the Employer. This would be the
same as last but would suit a contract where
many changes are envisaged to the Works after
the Contract has been awarded.

Cost reimbursable An estimate prepared by the tenderer which will

be replaced by the actual cost of the Works

EN
calculated in accordance with the terms set by
the Employer. This would suit a project where the
extent of work cannot be ascertained before the
Contract is placed. An example of this would be
an emergency reconstruction of a building
damaged by fire.

However, if for some special reason, more than one option is selected, for
IM
example there is a remeasureable element in a lump sum Contract, then the
details should be carefully defined.

The Foreword indicates that this Short Form of Contract is intended for
works of short duration. In the event of a contract for works of long duration,
EC

a new clause could be inserted at Sub-Clause 11.1 to adjust for the rise and
fall in the cost of labour, materials and other imports to the Works. Such a
clause could be adapted from the other FIDIC Conditions of Contract.

11.2 If the Contract is for a lump sum, consideration should be given as to how
the work is to be valued for the purposes of interim payments. In completing
the Appendix for Sub-Clause 11.1, the Employer may request tenderers to
submit a cash flow forecast linked to a stage payment proposal for
SP

agreement. This would be reviewed in the event of an extension of time

made in accordance with Sub-Clause 7.3.

Alternatively, interim payment can be based on valuation of the Works which

would also be appropriate for remeasurement and cost reimbursable
Contracts. Payment could also be based on the achievement of milestones
or a schedule of activities to which values are assigned.

If local law or practice so dictates, an invoice may also be required, in which

case it could be submitted with the statement.

11.3 No provision is made for advance payments. If such a payment is to be

made, there should be provision in the Particular Conditions and for any
security to be provided by the Contractor. An example form of advance
payment guarantee is to be found in FIDIC's Conditions of Contract for
Construction.

11.4 The deduction of retention is sometimes replaced by the provision of

security by the Contractor to the Employer. Alternatively, the entire retention
Notes for Guidance 27
 sum deducted is released after taking-over upon the provision by the
Contractor of security. In either event, suitable text would be required in the
Particular Conditions. An example form of retention guarantee is to be found
in FIDIC's Conditions of Contract for Construction.

11.5 The release of the second part of the retention will serve as confirmation that
all notified defects have been remedied.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

11.7 It is assumed that payments will be in a single currency. If this is not the
case, the proportions of different currencies should be stated in the
Appendix and provision made in the Specification or the Particular
Conditions as to how payment is to be made.

Default 12.1 The Employer may terminate the Contract if the defaulting Contractor does
not respond to a formal notice by taking all practicable steps to put right his

EN
default. This recognises that not all defaults are capable of correction in 14
days. If termination takes place, the Employer may take over and use the
Contractor's Equipment to complete the Works. Care should be taken,
however, if the equipment on Site is hired: no specific provision is made to
cover this situation and the Employer is unlikely to be able to retain such
equipment.

12.2 This provision provides the Contractor's main remedy for non-payment. 7
IM
days after the Employer's receipt of a default notice, which must refer to
Sub-Clause 12.2, the Contractor may suspend all or part of his work. 21
days later the option to terminate arises if the Employer persists with non-
payment or other default. The Contractor must use his right to terminate
within 21 days or lose it. This is to prevent a party abusing a right to
EC

terminate in his dealings with the other party for the remainder of the project.

If Contractor's Equipment is essential for the safety or stability of the Works,

the Employer will be obliged to agree terms with the Contractor for the
retention of such equipment. Local law will often protect the Employer from
the immediate and reckless removal of essential items.

12.3 The right of the Employer to retain the Contractor's Equipment may clash
SP

with the right of a liquidator or receiver to realise the assets of an insolvent

Contractor. Reference to the applicable law would be necessary.

12.4 This Sub-Clause enables the financial aspects of the Contract to be resolved
quickly and without the necessity to await the completion of the Works by
others. By specifying the damages payable to the innocent party for the
defaults leading to the termination, much delay, complication and scope for
dispute are avoided. The Employer's costs in obtaining a replacement
contractor will generally be higher than the Contractor's loss of profit.

Risk and Responsibility 13.1 Although the Contractor is responsible for the Works prior to taking-over, he
is protected by the obligation to insure the Works under Clause 14 and by
his ability to recover under Clause 6 his Cost if one of the Employer's
Liabilities occurs.

13.2 To qualify as Force Majeure, events must prevent performance of an

obligation. See also the definition at Sub-Clause 1.1.14. Notice must be
given at once.
28 Short Form of Contract
 Insurance 14.1 The Employer should set out his precise requirements in the Appendix. Third
Party, public liability insurance would normally be mandatory. As smaller
contracts are likely to fall within tenderers' standing Contractors' All Risk
(CAR) insurance policies, tenderers should generally be asked to submit
details of their insurance cover with their tenders.

Any requirements for insurance after the date of the Employer's notice
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

under Sub-Clause 8.2, or arising from taking-over parts of the Works,

should be covered by Particular Conditions. See also Clause 13.

If the Employer wishes to take out the insurances instead of the Contractor,
the following should be used as a Particular Condition in place of Sub-
Clause 14.1:

"Replace the text of Sub-Clause 14.1 with the following: "The Employer
shall, prior to the Commencement Date, effect insurance in the joint

EN
names of the Parties of the types, in the amounts and with the exclusions
stipulated in the Appendix. The Employer shall provide the Contractor
with evidence that any required policy is in force and that the premiums
have been paid."

Sub-Clauses 14.2 and 14.3 should be deleted if the Employer takes out the
insurances.
IM
It should be noted that in the event of the Employer's failure to insure, the
Contractor may give notice under Sub-Clause 12.2.

Resolution of Disputes 15.1 There are advantages in appointing an adjudicator from the outset even
EC

though the adjudicator may not be required to take any action or earn any
fee unless and until a dispute is referred to him. Delays will inevitably occur
if the parties initiate the procedure to appoint an adjudicator only when a
dispute has arisen. It is therefore recommended that the Employer propose
a person to act as adjudicator either at tender stage or shortly after the
Agreement is signed and that the matter is discussed and agreed as soon
as possible.
SP

Care should be taken about whether an adjudicator should be local or from

a neutral country. Although the adjudicator should be impartial, the costs of
employing someone from a third country could be disproportionate if it is
necessary for the adjudicator to visit or if a hearing became necessary.
However, in view of the costs involved in arbitration, even of minor disputes,
any extra cost of a truly impartial adjudicator is a recommended investment.

It is intended that all decisions made by the Employer or his representative

should be capable of being reviewed by an adjudicator and, if required, by
an arbitrator.

15.3 Arbitration may not be commenced unless the dispute has first been the
subject of an adjudication. The Rules of arbitration should be stipulated in
the Appendix. The UNCITRAL Rules are recommended. However, if
administered arbitration is required, that is arbitration overseen and
administered by an arbitral institution, the ICC Rules could be specified. The
ICC Court of Arbitration and its Secretariat in Paris appoints and replaces
arbitrators, checks the form of terms of reference and awards and generally
monitors progress and the performance of arbitrators. Where alternative
Notes for Guidance 29
 arbitration rules are chosen that include a procedure for the appointment of
an arbitrator, the authority designated in the Appendix to make the
appointment should be changed to reflect this. For example, if ICC Rules are
chosen, then the appointing authority should normally be changed to "ICC
Court of Arbitration". The place of arbitration is significant as the arbitration
law of the place of arbitration will apply in such matters as the ability of a
party to appeal.
Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

EN
IM
EC
SP

30 Short Form of Contract

Licensed copy: UWE, UNIVERSITY OF THE WEST OF ENGLAND, 13/12/2021, Uncontrolled Copy, ®FIDIC

SP Notes

EC
IM
EN

31