施工设计服务合同 Construction Design Contract
施工设计服务合同 Construction Design Contract
施工设计服务合同 Construction Design Contract
施工设计服务合同
Construction Design
Contract
合同编号: CTCE-ETH-JMCDHT-001
Contract Number: CTCE-ETH-JMCDHT-001
承包人(以下简称甲方):中铁四局埃塞俄比亚分公司 (TIN:0016148356)
Contractor: China Tiesiju Civil Engineering Group CO.LTD Ethiopia Branch
(hereinafter referred to as the "Party A")
设计服务单位(以下简称乙方):SMART Consulting Engineers PLC,
Organization of construction design: SMART Consulting Engineers PLC, ( hereinafter referred
to as the "Party B")
签约地点:JIMMA City,Ethiopia,Place of Signing: JIMMA City, Ethiopia
签约时间: 2021 年 6 月 15 日,Date of Contract: 15/6/2021
依照埃塞俄比亚有关法律、行政法规,遵循平等、自愿、公平、诚实信用、共担风险的原则,甲方愿意
将 季马至奇达道路升级改造项目施工设计服务给乙方, 双方就设计服务协商达成一致,订立本合同。
In accordance with Ethiopian relevant laws, Administrative laws and regulations,
Party A is willing to subcontract construction design of Jimma-Chida Road Upgrading
Project to Party B. Both of the parties agree to sign the subcontract on the basis of
equality, voluntariness, justice, sincerity and joint adventure。
本合同签订之前,乙方已熟悉施工的技术规范和要求,乙方不得以“不懂技术和规范” 等作为
借口提出合同之外的任何要求。本合同签订之前,乙方已熟悉项目要求的技术规范及设计要求情况,
乙方不得以“不熟悉地方条件” 等作为借口提出合同之外的任何要求。
本合同在双方签字并盖章之后生效。
Before signing the Contract, Party B has studied and been familiar with the
relevant technical standards and requirements of the construction. No any additional
requirements beyond the Contract should be raised with the excuses such as unfamiliar
with technical standards and requirements etc. Before signing the Contract, Party B
has studied and been familiar with the conditions and situations. No any additional
requirements beyond the Contract should be raised with the excuses such as unfamiliar
with the constructions conditions and situations etc..
The Contract shall take effect with the stamp and signature of both Parties.
第一条 工程概况
Clause 1 Project Profile
1、工程名称:埃塞俄比亚季马至奇达道路升级改造项目 ;
1、Project Name: Jimma-Chida Road Upgrading Project .
2、服务内容:道路部分图纸(平纵面设计、挡土墙、平交口设计),结构物部分图纸(圆管涵设
计细化),结构物部分图纸(箱涵图纸细化),结构物部分图纸(桥梁图纸细化),附属工程图
纸(各种类型水沟、旧桥修复、人行道、路缘石等),交通工程图纸(标志、标线、安全设施等),
转盘图纸设计。
2、Content of Subcontract: Road drawing (flat and vertical design, retaning wall
drawing, intersection drawing ),Structure drawing (detailed drawings of pipe
culvert),Structure drawing( detailed box culvert),Structure drawing( detailed
drawing of bridges),drawings of ancillary works(all kinds of earth
ditchs,renovation of old bridges ,walkway,curb),Traffic construction
甲 共 7页 第 乙
方: 1 页 方:
施工设计服务合同
甲 共 7页 第 乙
方: 2页 方:
4、合同中的总价包含:业主、监理工程师要求临时停工等所有因素可能引起的一切风险,若合同
中未提及的工作,应视为包含于合同价格。
4 、 Total Amount of the Contract shall include all risks, such as the requirement of
temporary construction shutdown by Employer or Engineer. If there is some work not
mentioned in contract, it should be supposed to be included in the total amount of the
Contract.
5、本合同单价为不含税,结算必须提供合法有效的增值税发票。如因乙方因发票问题导致甲方出
现税务风险,由此造成的损失需由乙方承担。
5、The unit price of this contract does not include tax, and the settlement must
provide a legal and valid VAT invoice. If Party B causes tax risks to Party A due to
invoice problems, Party B shall bear the losses caused thereby.
6、支付币种为埃塞俄比亚比尔。
6、Payment currency: Ethiopian Birr.
第四条 计量、结算与支付
Clause 4 Measurement、Settlement and Payment
1、计量与结算
1、measurement and settlement
(1)工程数量:详见附件一《设计服务量及费用清单》。附件一中所列设计服务数量为暂定数量,
不作为最终结算的依据,结算时按实际完成并经业主及监理批复的施工设计图为准。
(1) work quantity: For the details, please refer to Appendix 1 "Bill of Quantities
and Expenses". The work quantity listed in the Appendix 1 is temporary, which is not used
for the reference of final settlement. The actual completed work quantity that is
qualified , which is approved and accepted by Party A will be used as a reference for
settlement.
(2)按章节 series 中的设计服务比例进行计量。
(2)calculated by the rate of design service according to series
(3)本合同实行按 月 计量(每月 25 日),甲方组织有关人员进行核实, 经甲、乙双方签字确
认后,方可进行下步结算程序。
(3)This contract is measured by month (every month on the 25th ). Party A arrange
relevant personnel to conduct on-site verification about the work, with the signature and
consent of both Parties, settlement procedure will carry on afterwards.
(4)末次结算完成后,甲、乙双方应及时对服务合同进行封闭,签订末次清算协议。
( 4 ) After the settlement is completed, both of the Parties should seal the
subcontract in time and sign the settlement clearing agreement.
2、支付
2、payment
(1)甲方支付前,乙方应提交符合甲方要求的与结算费用相一致的合法发票,如果因乙方发票问题
导致甲方出现税务风险,由此造成的损失需由乙方承担。乙方未出具增值税专用发票的,甲方不予支
付。
( 2 ) Before Party A pays, Party B shall submit a legal invoice that meets the
requirements of Party A and consistent with the settlement fee. If Party A has a tax risk
due to Party B’s invoice problem, Party B shall bear the loss caused thereby. If Party B
fails to issue a special VAT invoice, Party A will not pay.
3、不予支付
3、withhold payment
出现下列情况甲方将对乙方该项工作不支付处理:
Payment shall be withheld by Party A under the situation listed as below:
(1)该项工作因服务单位出现严重设计问题,需要返工重做;
(1)This work exists serious quality problem, which needs to be reworked.
(2)该项设计服务工作未得到业主或监理的验收以及批准;
(2)This work is not accepted and approved by the employer and supervisor.
(3)合同期内规定工程未完成前,乙方违反合同私自撤场;
(3)Party B evacuate the construction site without the permission of Party A before
completing the work during the period specified in the contract.
第五条 质量要求
Clouse 5 quality requirements
1、乙方必须按照技术规范、甲方提供的承包合同要求精心设计,确保设计质量。
1 、 Party B shall elaborately arrange the construction in accordance with the
drawings, the technical specification and technical disclosure supplied by Party A,
第六条 相关规范
Clause 6 Relevant Specifications
本合同未提到的任何技术要求,以下列出的文件顺序作为参照:
Any technology, materials, plan, quality not mentioned in this contract shall refer to
the document order listed as below:
1、甲方与埃塞公路局签定的相关文件;
1、Relevant documents that Party A signed with Ethiopian Roads Authority(hereinafter
called
ERA)
2、按合同要求的埃塞俄比亚公路局公布的标准技术规范。
2 、 The standard technical specifications published by ERA stipulated in this
contract.
第七条 双方权利义务
Clause 7 Rights and Obligations of Both Parties
1. 承包商义务:
1.the obligation of Party A
a.向设计咨询服务单位付款。
a.to pay Party B
b. 在项目现场提供这样的工作空间(办公室、办公家具和房屋)和服务所需的相关文件。
b. to provide working facilities(office,furniture, house,etc.)and documents needed
at service.
c. 向分包商提供与根据本协议提供服务相关的所有合理支持、信息、记录和其他材料,使其能够
履行本协议规定的义务。
c.to provide subcontractor with all reasonable support,information,record and other
things in order to assist subcontractor to fulfill the obligations stipulated in this
contract.
d. 及时对设计公司提出的问题予以回答;
d. to make timely reply to the questions raised by Party B
e.承包商应尽快告知设计公司他对于后者提交的任何规划、计划、报告、建议或问题的决定,以
避免设计公司服务的延误或中断;
e. Party A shall give prompt notice to Party B with regard to any program, scheme
,report, suggestions or decisions submitted by the latter lest delay or interruption of
Party B are caused.
2 设计公司有义务:
Party B is obligated to :
a) 履行设计公司本身应承担的责任和本协议中规定的义务;
To take the responsibility of its own and fulfill the obligation stipulated in
this contract;
b) 利用为本协议实施所必需的、充足的资源,并将施工设计图向甲方提供电子版及 3 份纸质版的
图纸;
To make full use of resources necessary for fulfilling this agreement, and provide
Party A with working drawing both in soft copy version and 3 pieces of hard copy version
c) 指定一名合格的负责人,对承包商提出的问题予以答疑并参加与业主的设计评审会议直到获取
业主的批准;
To assign someone qualified to take charge of making replies to questions
raised by contractors and to attend evaluation meeting of design with contractor until
the design is approved by the employer.
d) 提供这类服务中一般正常要求的所有咨询和技术服务,为适当履行服务而需要在现场和办公室
提供服务;
To offer service of consultancy and technique required in such kind of
service and offer service on site or at office with a view to fully fulfill obligation.
e) 对由于设计公司责任需要进行文件和图纸的变更的情况,设计公司不会要求额外费用。
To ask no extra expense at the event of documents and drawings are required to
change resulting from Party B
f) 保护承包商提交的文件和材料。
To keep an eye on the documents submitted by Contractor.
g) 设计公司在设计文件中描述的材料和设备,应当注明规格、型号、性能
Specification, type, performance of materials and equipment described in the
drawings by Party B shall be indicated.
h) 不得在未经承包商允许的情况下向任何第三方扩散或转让承包商提交的图纸等技术资料。如发
生以上情况并给承包商造成经济损失,承包商有权向设计公司索赔。
Party B shall not disseminate or transfer technical data submitted by contractor
to any third party without permission. If Party A’s dissemination and transfer give
rise to economic losses of contractors, the latter have the right to make a claim to
Party A.
i) 保证交付的设计资料及文件不侵犯任何第三方的知识产权或其它任何权利,否则应承担由此给
承包商带来损失的赔偿责任。
To guarantee that the design data and document violate no any third party’s
intelligence property or other rights, otherwise Party B shall bear the losses of
contractor.
j) 在遵守本承包合同的范围内,尽可能优化相关的设计和细节。
不得质押主承包商的信用证,或不得代表主承包商承担除先前书面同意承担的费用以外的任何费
用。
To optimize the design and other details as possible as Party B can.
Party B shall not pledge contractor’s letter of credit and shall not represent
general contractor to bear the expenses except what has been agreed to undertake in
written form before.
第八条 合同解除
Clause 8 Termination of Contract
1、甲乙双方协商一致,可以解除合同;
1 、 this contract can be terminated with the consent of both parties.
2、因不可抗力致使合同无法履行,可以解除合同;
2、this contract can be terminated under the situation where the contract can not be
performed because of the force majeure.
3、 本合同其他条款约定的合同解除条款。
3、items of contract termination specified in other items of this contract
4、如果设计进度严重延迟,并且在发出书面警告后 7 天内没有采取改善措施, 甲方可以发出终
止函。
4、If construction progress is seriously delayed and there is not a turn to take for
the better within 7 days after issuing the written warning.Party A can issue a
termination letter.
第九条 争议解决
Clause 9 Dispute Resolution
执行本合同时的任何争议均应友好协商解决 ,当事各方未协商解决办法,可以将其争议提交具有
法律管辖权的法院。
Any disputes arisen in the course of implementing this contract shall be resolved
by negotiation. If no agreement is reached eventually, the dispute shall be handle by
court with jurisdiction.
第十条 附则
Clause 10 Supplementary
1、合同签订前乙方必须提供其营业执照、税务登记证、资质等级、经法定代表人授权的委托书等
资料原件由甲方进行审核。甲方审核通过后,乙方应将以上证件复印件加盖公章交由甲方,并作为本
合同附件之一。
1 、 Party B shall provide original documents such as business license, tax
registration certificate , qualification certificate 、 safe production certificate 、 power
of attorney issued by the legal representative for Party A to check before signing the
contract. Once passing the check, Party B shall submit the copies of these documents
with public stamp of his company mentioned above to Party A as one of the appendixes of
this contract.
2、 本合同一式 3 份,甲方执 2 份,乙方执 1 份。
2、this contract has 3 originals, two for Party A, one for Party B.
工程承包人:(公章) 设计服务单位:(公章)
住 所: 住 所:
Address: Address:
法定代表人: 法定代表人:
委托代理人: 委托代理人:
Agent: Agent:
见 证 人: 见 证 人:
Witness : Witness :