Engineering and Construction Subcontract

Revising the programme 32

32.1 The Subcontractor shows on each revised programme
. the actual progress achieved on each operation and its effect upon the
timing of the remaining work,
. the effects of implemented compensation events,
. how the Subcontractor plans to deal with any delays and to correct
notified Defects and
. any other changes which the Subcontractor proposes to make to the
Accepted Programme.
32.2 The Subcontractor submits a revised programme to the Contractor for
acceptance
. within the period for reply after the Contractor has instructed him to,
. when the Subcontractor chooses to and, in any case,
. at no longer interval than the interval stated in the Subcontract Data
clauses

from the subcontract starting date until Completion of the whole of the
core

subcontract works.

Access to and use of 33

the Site 33.1 The Contractor allows access to and use of each part of the Site to the
Subcontractor which is necessary for the work included in this subcontract.
option clauses

Access and use is allowed on or before the later of its subcontract access
date and the date for access shown on the Accepted Programme.
main

Instructions to stop or not 34

to start work 34.1 The Contractor may instruct the Subcontractor to stop or not to start any work
and may later instruct him that he may re-start or start it.
option clauses

Take over 35
secondary

35.1 The Contractor need not take over the subcontract works before the Sub-
contract Completion Date if it is stated in the Subcontract Data that he is not
willing to do so. Otherwise the Contractor takes over the subcontract works not
later than two weeks after Completion.
35.2 The Employer or the Contractor may use any part of the subcontract works
before Completion has been certified. If he does so, the Contractor takes over
components

the part of the subcontract works when the Employer or the Contractor begins
to use it except if the use is
cost

. for a reason stated in the Subcontract Works Information or

. to suit the Subcontractor’s method of working.
35.3 The Contractor certifies the date upon which he takes over any part of the
subcontract works and its extent within two weeks of the date.
subcontract

Acceleration 36
data

36.1 The Contractor may instruct the Subcontractor to submit a quotation for an
acceleration to achieve Completion before the Subcontract Completion Date.
The Contractor states changes to the Key Dates to be included in the
quotation. A quotation for an acceleration comprises proposed changes to the
Prices and a revised programme showing the earlier Subcontract Completion
Date and the changed Key Dates. The Subcontractor submits details of his
assessment with each quotation.
36.2 The Subcontractor submits a quotation or gives his reasons for not doing so
within the period for reply.

10 # copyright nec 2005 www.neccontract.com

SUBCONTRACT DATA

Part one – Data provided by the Contractor

Completion of the data in full, according to the Options chosen, is essential to

create a complete subcontract.

Statements given in all

subcontracts

clauses
core
1 General . The conditions of contract are the core clauses and the clauses for main
Option . . . . . , dispute resolution Option . . . . . and secondary Options . . . . .
of the NEC3 Engineering and Construction Subcontract June 2005 (with
amendments June 2006).
. The works in the main contract are

option clauses
..............................................................

main
. The subcontract works are
..............................................................
. The Contractor is

option clauses
Name . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

secondary
Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
..............................................................
. The Employer in the main contract is
Name . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

components
..............................................................

cost
. The Project Manager in the main contract is
Name . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

subcontract
..............................................................

data
. The Supervisor in the main contract is
Name . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
..............................................................
. The Adjudicator in this subcontract is
Name . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
..............................................................

www.neccontract.com # copyright nec 2005 59

 Engineering and Construction Subcontract

Optional statements If the tribunal is arbitration

. The arbitration procedure is . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. The place where the arbitration is to be held is
..............................................................
. The person or organisation who will choose an arbitrator
. if the Parties cannot agree a choice or
. if the arbitration procedure does not state who selects an arbitrator is
..............................................................

If the Contractor has decided the subcontract completion date for the whole of
the subcontract works
. The subcontract completion date for the whole of the subcontract works is
clauses
core

..............................................................

If the Contractor is not willing to take over the subcontract works before the
Subcontract Completion Date
option clauses

. The Contractor is not willing to take over the subcontract works before the
Subcontract Completion Date.
main

If no programme is identified in part two of the Subcontract Data

. The Subcontractor is to submit a first programme for acceptance within
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . weeks of the Subcontract Date.
option clauses
secondary

If the Contractor has identified work which is to meet a stated condition by a

key date
. The key dates and conditions to be met are
condition to be met key date
1 ......................... ...........................
components

2 ......................... ...........................
cost

3 ......................... ...........................

If the period in which payments are made is not four weeks and Y(UK)2 is not
used
. The period within which payments are made is . . . . . . . . . . . . . . . . . . . . . . . .
subcontract

If Y(UK)2 is used and the final date for payment is not 21 days after the date
data

when payment is due

. The period for payment is . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

62 # copyright nec 2005 www.neccontract.com