Panipat Thermal Power Station
Panipat Thermal Power Station
Panipat Thermal Power Station
TENDER DOCUMENT
FOR
(February, 2018)
TELEPHONE NO.0180-2566859
FAX NO. 0180-2566858
INDEX
e-tenders in two parts are invited on behalf of Chief Engineer, PTPS, HPGCL, Panipat from
reputed and experienced contractors/ firms for the work as under:-
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
Information Regarding Online Payment of Tender Document, e-Service & EMD Fee
1. The Bidders can download the tender documents from the Portal:
https://haryanaeprocurement.gov.in.
2. The Bidders shall have to pay for the Tender documents, EMD Fees & e-Service Fee online by
using the service of secure electronic payment gateway. The secure electronic payments
gateway is an online interface between contractors and online payment authorization networks.
The Payment for Tender Document Fee and e-Service Fee can be made by eligible bidders /
contractors online directly through Debit Cards & Internet Banking Accounts and the Payment
for EMD can be made online directly through RTGS / NEFT. Payment by any other mode
would not be accepted.
3. It is advised that the bidder make the payment for EMD via RTGS / NEFT to the beneficiary
account number as mentioned in the challan atleast T+2 day (Transaction + Two day) two day
in advance to the last day for validation on account / transaction period.
Note: - If the tenders are cancelled or recalled on any grounds, the tender document fees & e-
service fee will not be refunded to the agency.
Note: - Those agencies who are exempted from EMD, should submit proof of related
documents at least 10 days before end date of “Downloading of Tender Documents & Bid
Preparation” stage to publisher of the tender i.e. Executive Engineer of the concerned
Division.
Post registration, bidder shall proceed for bidding by using both his digital certificates (one each
for encryption and signing). Bidder shall proceed to select the tender he is interested in. On the
respective Department‟s page in the e-tendering portal, the Bidder would have following options
to make payment for tender document & EMD:
a) Debit Card
b) Net Banking
c) RTGS/NEFT
A) Net banking:
The procedure for paying through Net banking will be as follows.
(i) Bidder selects Net banking option in e-Procurement portal.
(ii) The e-Procurement portal displays the amount to be paid by bidder.
(iii) Bidder clicks on “Continue” button
(iv) The e-Procurement portal takes the bidder to Net banking payment gateway screen
displaying list of Banks
(v) Bidder chooses his / her Bank
(vi) The Net banking gateway redirects Bidder to the Net banking page of the selected Bank
(vii) Bidder enters his account credentials and confirms payment
viii) The Bank verifies the credentials and confirms with “successful” or “failure” message to
the Net banking gateway which is confirmed back to e-Procurement portal.
ix) The page is automatically routed back to e-Procurement portal
x) The status of the payment is displayed as “successful” in e-Procurement portal. The e-
Procurement portal also generates a receipt for all successful transactions. The bidder can
take a print out of the same.
xi) The e-Procurement portal allows Bidder to process another payment attempt in case
payments are not successful for previous attempt.
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
These conditions will over-rule the conditions stated in the tender documents, wherever relevant
and applicable.
2.1. The Bids submitted online should be encrypted and signed electronically with a Digital
Certificate to establish the identity of the bidder bidding online. These Digital Certificates are
issued by an Approved Certifying Authority, by the Controller of Certifying Authorities,
Government of India.
2.2. A Digital Certificate is issued upon receipt of mandatory identity (i.e. Applicant‟s PAN Card)
and Address proofs and verification form duly attested by the Bank Manager / Post Master /
Gazetted Officer. Only upon the receipt of the required documents, a digital certificate can be
issued. For more details please visit the website – https://haryanaeprocurement.gov.in.
2.3. The bidders may obtain Class-II or III digital signature certificate from any Certifying Authority
or Sub-certifying Authority authorized by the Controller of Certifying Authorities or may obtain
information and application format and documents required for the issue of digital certificate
from:
2.4. Bid for a particular tender must be submitted online using the digital certificate (Encryption &
Signing), which is used to encrypt the data and sign the hash during the stage of bid
preparation & hash submission. In case, during the process of a particular tender, the user
loses his digital certificate (due to virus attack, hardware problem, operating system or any
other problem) he will not be able to submit the bid online. Hence, the users are advised to
keep a backup of the certificate and also keep the copies at safe place under proper
security (for its use in case of emergencies).
2.5. In case of online tendering, if the digital certificate issued to the authorized user of a firm is
used for signing and submitting a bid, it will be considered equivalent to a no-objection
certificate / power of attorney / lawful authorization to that User. The firm has to authorize a
specific individual through an authorization certificate signed by all partners to use the digital
certificate as per Indian Information Technology Act 2000. Unless the certificates are revoked,
it will be assumed to represent adequate authority of the user to bid on behalf of the firm in
the department tenders as per Information Technology Act 2000. The digital signature of this
authorized user will be binding on the firm.
2.6. In case of any change in the authorization, it shall be the responsibility of management /
partners of the firm to inform the certifying authority about the change and to obtain the digital
signatures of the new person / user on behalf of the firm / company. The procedure for
application of a digital certificate however will remain the same for the new user.
2.8. Before submitting tenders the instructions may be read carefully regarding submission of
tender. If any bidder finds discrepancies or omissions in the tender documents or is in doubt
as to the true meaning of any part, he shall clarify same from tender issuing office in writing
before the due date of submission of the bid. No arguments on this account whatsoever shall
be entertained after the last date & time of submission of tenders.
5. Online Viewing of Detailed Notice Inviting Tenders:- The bidders can view the detailed
NIT and the time schedule (Key Dates) for all the tenders floated through the single portal e-
Procurement system on the Home Page at https://haryanaeprocurement.gov.in.
6. Download of Tender Documents: - The tender documents can be downloaded from the e-
Procurement portal https://haryanaeprocurement.gov.in.
7. Key Dates: - The date and time shall be binding on all bidders. The tenderers can submit
their quotations (Online) as per the dates mentioned in the key dates:
Key Dates:-
Start date and Expiry date and
Sr. No. Department Stage Tenderer‟s Stage
time time
Tender Authorization & 29.03.2018 at 30.04.2018 at
1 ---
Publishing 17:00 Hrs. 13:00 Hrs.
Downloading of
Tender 29.03.2018 at 30.04.2018 at
2 ------
Documents & Bid 17:00 Hrs. 13:00 Hrs.
Preparation
30.04.2018
3 Technical Opening (Part-I) - ---
at 15:00 Hrs.
Short listing of Technical
Will be intimated to the firms on
4 bids & Opening of
their e-mail
Financial Bid (Part-II)
8. Bid Preparation (Technical & Financial) Online Payment of Tender Document Fee,
eService fee, EMD fees and Submission of Bid Seal (Hash) of online Bids:-
8.1. The bidders shall have to pay for the Tender document fee, EMD fees & eService Fee (Rs.
1000/-) online by using the service of secure electronic payment gateway. The secure
electronic payments gateway is an online interface between contractors and online payment
authorization networks. The Payment for Tender Document Fee and eService Fee can be
made by eligible bidders/ contractors online directly through Debit Cards & Internet Banking
Accounts and the Payment for EMD can be made online directly through RTGS / NEFT.
8.2. The bidders shall upload their technical offer containing documents, qualifying criteria,
technical specification, schedule of deliveries, and all other terms and conditions except the
8.3. Submission of bids will be preceded by submission of the digitally signed & sealed bid (Hash)
as stated in the time schedule (Key Dates) of the Tender.
9. Tender Closing:-
a) If bidder fails to complete the Online Bid Submission stage on the stipulated date and time,
his/hers bid will be considered as bid not submitted, and hence not appear during tender
opening stage.
b) From the starting date of tender downloading to final date of submission of bid, the bidder can
rework on his bid number of times he wants. If bidder submits the revised bid including price
bid, original bid will automatically deleted and this revised bid will become original bid. No
revised bid will be submitted after Part-I (Technical Bid) is opened.
c) Complete bid will only be submitted after realization of tender document‟s fee and EMD.
d) Bidders participating in online tenders shall check the validity of his/her Digital Signature
Certificate before participating in the online Tenders at the portal
http://haryanaeprocurement.gov.in.
e) For help manual please refer to the „Home Page‟ of the e-Procurement website at
https://haryanaeprocurement.gov.in, and click on the available link „How to..?‟ to download the
file.
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
All tenderers must carefully observe the following instructions and offers/tenders not strictly
in accordance with these instructions will be liable to rejection:-
a) The bidder should be Empanelled Accredited Auditor Firm and should be in the list
maintained by M/s BEE. The bidder must have successfully executed Energy Audit Work for
210MW or 250MW or above capacity Thermal Power Stations (TPS) as per the latest
version of ASME codes e.g. ASME PTC :6 2004 for Steam Turbine, ASME PTC :4
2008 for Steam Generators, ASME PTC : 12.2 for Surface Condenser, ASME
PTC:19.2,19.3,19.5 for pressure, temperature & flow measurement etc. The
standards and guidelines to be followed are attached in Annexure-IV (B).
The bidder must have experience of having successfully executed Energy Audit Work
Order(s) in HPGCL / NTPC / any SEBs / any PSUs / any Corporations / Central Govt. / State
Govt. / Semi Govt. or in any Thermal as per annexure IV of NIT and have average annual
turnover and other eligibility conditions mentioned below.
b) Experience for Execution of Work Order- The bidder must have successfully executed
Work Orders(s) for same or similar item (s) / Works (s) during last 5 years ending 31.03.2017
in 210 MW units or above capacity power plants and having minimum order value as under:
c) Turnover- Bidders must have average annual turnover in last 3 consecutive financial years
i.e. FY2016-17, FY 2015-16 and FY2014-15, shall not be less than Rs. 60 Lac
Note:
1) Other income shall not be considered for arriving at annual turnover.
2) In case where audited results for the last preceding financial year are not available for
determining the average annual turnover, certification of financial statements from a
practicing chartered accountant shall be considered acceptable.
3) The bidder shall submit certified copies for the same duly audited by Chartered
Accountant.
4) The Work Order value and turnover value referred above is exclusive of all taxes
and duties.
d) The bidder should possess GST Number and copy of the same to be attached with e-NIT.
Notes:
a) The tender documents of only those bidders shall be considered who fulfill the eligibility
criteria / qualifying documents and submit documentary evidences duly attested in support of
the same along with copy of performance certificate / repeat order from the same
organization, if any.
b) The bidders should have testing facilities at its works or the testing will be carried out at any
Govt. approved NABL test laboratory.
c) The bidder should ensure that the instruments required at Sr. No. 13 of Annexure-IV
(A) etc., possess the desired accuracy as stipulated under ASME PTC for process
a) Even though the bidders meet the above Qualifying Criteria they are subject to be
disqualified, if they have made misleading or false representations in the forms, statements
and attachments submitted in the proof of the qualification requirements.
b) The Bidders shall supply partnership deed in case of partnership firm / Memorandum of
Association and Article of Association in case of a company.
c) Not withstanding anything stated above Haryana Power Generation Corporation Ltd. reserves
the right to assess the tenderer‟s capacity to perform the contract should the circumstances
warrant such assessment in the overall interest of the Haryana Power Generation Corporation
Ltd. In this regard the decision of corporation will be final.
3. Opening of Tender:-
a) The tenders will be opened in the office of Executive Engineer/Efficiency Division, PTPS,
Panipat in the presence of authorized representative of the tenderers, if they so desire, at the
time and date set for opening of tenders or in case any extension was given thereto on the
extended tender opening date and time. Tenderer‟s authorized representatives (up to two
persons) may attend the opening.
b) The Price Bid (Part-II of the tender) shall be opened after Part-I of the tenders have been
scrutinized and evaluated. The tenderers whose Part-I have been approved, will be allowed to
participate in opening of Price Bid (Part-II). The due date and time for opening of Price Bid
(Part-II) shall be informed later on.
4. Any information regarding tender can be had from the office of Executive Engineer/ Efficiency,
PTPS, Panipat ([email protected]) on any working day prior to last date of submission of
tenders. The payment of Tender Document Fee and e-service Fee can be made online
directly through Debit Cards & Internet Banking Accounts. The payment of Earnest Money
can be made by eligible bidders / contractors online directly through RTGS / NEFT. Cost of
tender and EMD in any other form shall not be accepted.
5. Before submitting tenders, the instructions may be read carefully regarding submission of
tender. If any bidder finds discrepancies or omissions in the tender documents or is in doubt
as to the true meaning of any part, he shall clarify same from tender issuing office in writing
before the due date of submission of the bid.
6. Unless exempted specifically, tenders not accompanied with the prescribed EMD, cost of
tender & e-Service fee shall be rejected. EMD / Cost of Tender shall be in the prescribed
mode of payment as asked in the NIT otherwise the tender shall be liable to be rejected.
7. The validity of the tender / offer shall be for 120 days from the date of opening of the price bid.
8. The rate negotiations could be held up to L3 bidder, if the difference between the L1 quoted
rates and those quoted by L2 and L3 is within 5% of the L1 quoted rates. In case where the
L1 bidder refuses to further reduce his offered price and the L2 or L3 bidders come forward to
offer a price which is better than the price offered by L1 bidder, the bidder whose price is
9. Before tendering, the tenderer shall carefully study all the clauses and specifications of the
tender documents. If tenderers have any doubt for the meaning of any portion of the tender
specifications or find discrepancies or omissions in the drawings or the tender documents
issued are incomplete or needs clarification aspects, scope of work etc., he shall at once
contact the authority inviting the tender for clarifications before submission of tender. No
arguments on this account whatsoever shall be entertained after the last date & time of
submission of tenders.
10. Inspection of site of work- Before tendering, the tenderer is advised to inspect the site of
work & the environment and make acquaint with actual work and other prevalent conditions,
facilities available, position of material and labour. No claim on this account, whatsoever, shall
be entertained afterwards.
11. A certificate to the effect may be submitted that the tenderer is not black listed from any
Public Sector undertakings of Central Govt. / State Govt. / SEBs / Corporations / any other
reputed Thermal / Hydel Plant etc.
12. The bidder can revise his price bid any number of times but only before last date of
submission of bid. All previous quotes are deleted & only the latest price quoted is visible to
the purchasing authority on date of opening of price bid.
13. Tenders through Fax / E-mail / telegraphic tenders shall not be considered. Incomplete,
obscure or irregular tender is liable for rejection. If the tenderer deliberately gives wrong
information in his tender, HPGCL reserves the right to reject such tender at any stage.
14. If the tenderer deliberately gives wrong information in his tender, HPGCL reserves the right to
reject such tender at any stage.
15. The work as a whole will be allotted in a single part to the bidder who is overall lowest
in the merit order considering all items of work.
16. In case due dates of sale / receipt /opening of tender happens to be holiday in PTPS/HPGCL,
the needful will be done on next working day.
17. The committee nominated by HPGCL shall evaluate all the bids received against NIT on the
parameter indicated under heading qualifying requirement. The decision of the committee
shall be final.
18. No deviation shall be allowed. However, in case of deviation of taxes etc., the same be
loaded for comparison purpose.
19. Selection preference of the tendered work may be allowed as per policy of the State
Government to the Industrial Units located in Haryana on the lowest valid rates if tenderer so
claim with requisite documentary evidence.
20. The bidders / contractors shall observe the highest standards of ethics during the submission
of tender, procurement and execution of the contract. In case of evidence of cartel formation
by the bidder(s) EMD is liable to be forfeited.
21. The bidder shall bear all costs including bank charges if any, associated with the preparation
and submission of his bid and the purchaser will in no case be responsible or liable for those
costs, regardless of the conduct or outcome of the bidding process.
23. The tenderer shall quote the prices in English language and international numerals. The rates
shall be in whole rupees and shall be entered in figures as well as in words. For the purpose
of tender, the metric system of units shall be used.
24. All rates shall be quoted on the proper form i.e. price bid supplied as part of the tender
documents on e-tender portal by the Department.
25. On acceptance of the tenders, the name of the authorized representative(s) of the tenders, who
would be responsible for taking instructions from the Engineer-in-Charge and shall be
communicated to the Engineer-in-Charge immediately after the allotment / start of work.
26. The Haryana Power Generation Corporation Limited does not bind itself to accept the lowest
tender and reserves to itself the right to accept the whole or any part of the tender and the tendered
shall be bound to perform the same at the rate quoted in this tender.
27. Eligibility of the black listed firms to participate in NIT- The firms who have been blacklisted
by HPGCL or any other Centre or State Power Utility/ Board or Corporation/ or any other
Thermal/Hydro Electricity project shall not be eligible to bid against the NIT of HPGCL, However;
a) In case the blacklisting of the firm is for a specific plant and not for the organization as a
whole then such blacklisting will not tantamount to ineligibility of the bidder.
b) Blacklisting of the firm by any unit of the HPGCL shall be considered as ineligibility of the firm
at any other project of HPGCL.
c) In case any firm was blacklisted for a limited period in past by any organization and presently
such blacklisting has removed by such organization then it will not tantamount to ineligibility
of the bidder.
d) Firm has to certify itself for its eligibility with supporting documents to participate in the NIT
stating that it has not been blacklisted by any organization presently, however in case at a
later stage such certification found wrong then it will lead to misrepresentation of the facts
and the firm shall be treated as blacklisted on this ground and action shall be taken as per
HPGCL regulation 36 and 37.”
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
c. X-Ratio i,e. heat capacity of air passing through the air heater to
the heat capacity of gas passing through the air heater.
d. Air side and gas side pressure loss across the air heater.
Raw Water System and Waste Water treatment system (DM Plant)
Capacity utilization and power consumption of all major drives.
Performance evaluation of pumps
If any other test than specified on the system other than the specified
as above is required to establish the baseline performance of the unit
11 prior to carrying out Energy Efficient R&M and LE Works of the Unit, it
will be carried out by the Consultant.
Note: -Energy audit should be carried out as per the guidelines given on website
“www.cea.nic.in”.
The activities mentioned in the scope of work as per Annexure-IV, IV (A) & IV (B).
However, it is not possible to list out all the minor activity in detail. So, all such
minor / any other left out activity essential for mandatory energy audit test shall
deemed to be included in the scope of work and energy audit test should be
carried out as taken into account the guidelines given on website
“www.bee.nic.in”.
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
18. Appendix A to PTC 6 The Test Code for Steam Turbines ASME PTC : 6A 2000
19. Cooling Technology Institute Acceptance Test Code for ATC-105
testing mechanical draught & natural draught cooling
towers
20. Flue Gas & Exhaust Gas Analysis ASME PTC : 19.10 1981
21. Reciprocating Internal-Combustion Engines ASME PTC : 17 1973
22. General Instructions ASME PTC : 1 2004
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
1. Contract Agreement: - The contractor shall execute a contract agreement with HPGCL on a
Non Judicial Stamp Paper of appropriate value within 15 days of receipt of work order as per
Annexure-VIII. Also acceptance certificate as per Annexure-IX is to be submitted.
2. Rate / Contract Price: - Rate shall be quoted by the bidder, strictly as per rate quoting sheet
and the agreed contract price shall remain firm during the currency of the contract. Any
statutory taxes/levies, if to be charged extra, should be clearly indicated by tenderer in their
offer separately, failing which it will be presumed that the quoted prices are inclusive of all
such statutory taxes/levies.
a) Every tenderer, while submitting his tender, shall deposit the earnest money online.
b) The EMD furnished by successful tenderer on whom the work order is placed shall be
converted into security deposits as a guarantee for faithful and satisfactory execution of work
order.
c) The EMD of the unqualified bidders will be returned without any interest, as promptly as
possible, within 30 days after declaration of qualification result and that of unsuccessful
bidder within 15 days of the execution of the contract with the selected bidder.
d) The successful bidder shall deposit the security equal to 10% of the total value of the work
order However, the EMD already deposited by the bidder shall be converted into the security
deposit and the balance amount shall be deducted from the bill.
e) The security deposit of the contractor shall be retained by HPGCL for faithful execution of the
contract.
f) Security deposit shall be released only after successful completion of the entire work as per
scope IV, IV(A) & IV(B) and completion certificate of Engineer In-charge.
g) No interest shall be paid on EMD / Security Deposit for the period it remains deposited with
HPGCL.
h) The earnest money/security deposit shall be forfeited in part or in full under the following
circumstances:-
i. If the tenderer withdraws his tender at any stage during the currency of validity period.
ii. If the work order has been issued but the contractor refuses to comply with it irrespective
of the fact that HPGCL sustains any loss on account of such default or not.
iii. In the event of a breach of contract in any manner.
iv. In case of evidence of cartel formation by the bidder(s).
v. If the contractor fails or neglects to observe or perform any of his obligations under the
contract, it shall be lawful for the HPGCL to forfeit either in whole or in part, in its absolute
discretion, the EMD/security deposit furnished by the contractor.
vi. The forfeiture of EMD/security deposit shall be without prejudice to the right of HPGCL to
recover any further amount or any liquidated and/or other damages as admissible under
the law, under payments or over payments made to the contractor under this contract or
any other contract as well as to take such administrative action against the contractor as
blacklisting etc.
Note: The above terms are subject statutory & mandatory deductions.
5. Mode of Payment: - Payment shall be released by the Sr. Accounts Officer, PTPS-II, PTPS,
Panipat through RTGS/NEFT. For payment through RTGS/NEFT, the contractor will intimate
the complete bank details viz. Name of Bank/Branch, Account Number, Type of Account,
IFSC Code etc, to Sr. Accounts Officer, O&M-II, PTPS, Panipat. Bank charges, if any, shall
have to be borne by the contractor.
6. Completion Period: - The duration of completion of the assignment shall be 10 days for
each unit (Unit 5 to 8) and 40 days for all the 4 units from the date of intimation from
Engineer in Charge after issuing of work order/LOI. The work shall be started immediately
from the date of notice, which shall be given to the contractor by Engineer in Charge. The
quantity of work may be decreased to any extent depending upon the plant / front available.
The payment shall not be made for the work not done. The duration of completion of the
assignment shall not be more than 40 days for all the 4 Units.
In case HPGCL remain unable to view site/Front to carry out the Energy Audit Test
in time to contractor, then the contractor will allow to extension schedule time to
completion of Energy Audit Test. This extension will be granted with approval of
Chief Engineer/PTPS.
It will be the discretion of HPGCL to decide the priority of unit for energy audit test.
HPGCL may skip/cancel the audit of any unit without assigning any reason.
8. Penalty for delay: - If the firm does not engage certified Energy Auditor/sufficient
skilled staff or the quality of work is not up to the satisfaction of Engineer-in-charge
or there is delay in attending of jobs, the penalty @ 1% of the contract value per day
for part thereof up to maximum of 10% of total contract value will be imposed .
However, the firm may compensate the delay at any unit with early completion of work of
other unit and the penalty will be applicable only on the basis of delay in total scheduled time
of 40 days provided for all the 4 units to the firm from the date of issue of intimation to the
date of submission of final Audit Report of all the Units.
9. Risk and Cost: -If the contractor is unable to execute the work, any loss incurred by
HPGCL in this respect will be to the contractor‟s account. HPGCL may also terminate
the contract after giving a 07 days‟ notice, if in its opinion; the work under the contract is
not being done to its satisfaction. HPGCL also has the right to get the job done from a
third party at the risk and cost of the first contractor till the expiry of the period of
contract and debit the cost plus 15% of the cost to the first contractor‟s account.
To recover damages as per penalty clause mentioned as above, if the said delay is not
covered under the Force Majeure reasons
12. Force Majeure:- The delay in the completion of the work may be treated as force majeure to
the contractor only if:-
a. The delay is resulted from any causes arising out of compliance with regulations, orders or
instructions of the Central or State Governments, acts of God, acts of Civil & Military
authority, fires, floods, strikes, lock-outs, freight embargoes, war-risk riots and civil
commotion. And
b. The contractor‟s request for extension of the completion period along with all necessary
evidence comes, before the expiry of the schedule date(s) of completion.
13. Statutory Deductions: - Statutory deduction on account of Income Tax, Works Tax &
Sales Tax etc. including surcharge shall be made at source from the bills of the contractor at
the prevailing rates.
a) This office reserves the right to claim adequate compensation from the contractor on
account of any damage caused to the equipment handed over to him for execution of the
work, due to careless handling or negligence on the part of the contractor.
14. Idle labour charges: - No idle labour charges will be admissible in the event of any
stoppage caused in the work resulting in contractor‟s labour being rendered idle due
to any cause.
15. Over run charges: - No over run charges shall be paid in the event of the completion
period being extended for any reasons.
16. Watch and ward: - The watch and ward of T&P & other material will be the
responsibility of the contractor.
17. Facilities to be arranged by contractor:- The contractor shall make his own
arrangement for providing all facilities like boarding, furniture and transportation etc.
for his supervisors/staff engaged by him for the job.
18. Factory act/ Minimum wages act/ Insurance act/ EPF act etc:- Strict adherence of
various applicable labour laws like the Factories Act, Minimum Wages Act, ESI Act,
Payment of Wages Act, the Workman‟s Compensation Act, EPF Act, Contractor
labour (Regulation & Abolition) Act, 1970 and all other statutory requirements as
amended from time to time to the entire satisfaction of Central/State Govt.
Authorities, shall be the responsibility of the Contractor and he shall have to make
20. Safety rules: - A Firm shall have to comply with all the provisions of safety rules. The
Chief Safety Officer may impose penalty of Rs.200/- per day per head if the workers
of contractor are found to be working carelessly without proper protective
equipments in unsafe conditions. Against violation of any other clause, a penalty of
Rs 500 /- per violation (minimum) shall be levied. In case of repeated violation of
serious nature resulting in various serious accident or direct loss to the corporation
/threatens to cause severe consequences, higher penalty rates may be imposed
including suspension/ termination of the contract. If any action is initiated by Chief
inspector of factories, Chandigarh or any other authority against occupier/factory
manager or any other authority of HPGCL in case of any fatal/non fatal accident or
any other violation of factory act, 1948, Pb. Hr. factory rules, 1952 or any other
industrial or labour act, the contractor shall be liable for the same and also to deposit
the amount of fine/penalty if any. In case of default action as deem fit shall be
initiated against the contractor.
A safety clearance certificate from the chief safety officer shall be obtained by the
contractor and has to be attached along with the bill. This office reserves the right to
claim adequate compensation from the contractor on account of any damage caused
to the plant & equipment handed over to him for execution of the work, due to
careless handling or negligence on the part of the contractor
21. Arbitration: - All the matters, questions, disputes, differences and/or claims arising out
of and/or concerning and/or in connection and/or relating to this Contract whether or
not obligations of either or both Parties under this contract be subsisting at the time of
such dispute and whether or not this contract has been terminated or purported to be
terminated or completed, shall be referred to the Sole Arbitrator to be nominated by
Managing Director/HPGCL and the disputes will be dealt in accordance with provision
of the Arbitrator and Conciliation (Amendment) Ordinance, 2015. The award of the
Arbitrator shall be final and binding on the parties to this contract.
22. Laws Governing Contracts: - All contracts shall be governed by the laws of India for the
time being in force. Irrespective of the place of delivery, place of performance or place of
payment under a contract, the contract shall be deemed to have been made at the place
from which the acceptance of tender has been issued.
23. Jurisdiction of Courts: - The contract shall be deemed to have entered into at Hisar and all
cause of actions in relation to the contract shall, therefore, be deemed to have arisen within
24. Set Off:- Any sum of money due and payable to the supplier under the contract (including
security-deposit returnable to the supplier) may be appropriated by the HPGCL and set-off
against any claim of the Corporation for the payment of a sum of money arising out of under
that or any other contract entered into by the contractor with the HPGCL.
25. Subletting and Assignment: - The contractor shall not, sublet, transfer or assign the
contract or any part there of or interest therein or advantage thereof in any part thereof in
any manner whatsoever without prior consent of the HPGCL.
26. All material issued to the contractor by the HPGCL or brought by the contractor for its
bonafide use at work shall be stored and preserved by the contractor in his custody as to
avoid it against any loss/damage/shrinkage or deterioration in any form. Any loss suffered
by the HPGCL on this account shall be compensated by the firm at panel rates to be
determined by the HPGCL. The rates so determined shall be final and binding on the firm.
27. This office reserves the right to claim adequate compensation from the contractor on
account of any damage caused to the plant & equipment handed over to him for execution
of the work, due to careless handling or negligence on the part of the contractor.
28. The recovery in respect of any spares which get damaged due to negligence on the part of
the contractor will be done at the rates as mentioned in the price catalogue of BHEL or any
other Source, plus 10% supervision charges.
29. During the course of this work, the contractor shall keep a competent authorized
representative and its assistants so that the progress of the work is not hampered. The
representative shall represent the contractor in his absence and all directions given to him
shall be binding as given to the contractor. In no case, the authorized representative can
refuse to receive the instructions.
30. HPGCL reserves the right to cancel the work order at any time without assigning any
reasons and will not be responsible and will not pay for any expenses or losses that may be
incurred by the contractor towards preparation/mobilization for execution of the job against
work order.
Note:-
1. Unless agreed otherwise the above terms and conditions of the contract will form the part of
the work order after finalizing the proposal. The word tenderer where ever used above shall
be read as contractor. The non applicability / modification in the aforesaid clauses if agreed
shall be mentioned / attached in / with the work order specifically.
2. Any other term not defined in instructions to the bidder or above terms and conditions
should be interpreted as defined in HPGCL Purchase Regulation “2015”.
3. The term “Bid” and “tender” and their derivatives (“Bidder / Tenderer” “Bidding / Tendering”)
are synonymous. Singular also means plural.
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
Executive Engineer/Efficiency,
For Chief Engineer/PTPS,
HPGCL, Panipat
(Rs.) ______________________ )
Note:-
The Bidders are required to quote the rates strictly as per the Rate Quoting Sheet after
carefully going through the complete tender documents
(Rs.) ______________________ )
Note:-
The Bidders are required to quote the rates strictly as per the Rate Quoting Sheet after
carefully going through the complete tender documents
(Rs.) ______________________ )
Note:-
The Bidders are required to quote the rates strictly as per the Rate Quoting Sheet after
carefully going through the complete tender documents
(Rs.) ______________________ )
Note:-
The Bidders are required to quote the rates strictly as per the Rate Quoting Sheet after
carefully going through the complete tender documents
Rs. In words
(________________________________________________________________)
Note: - Evaluation of Bids shall be made on the basis of overall quoted prices for
energy audit of all the four (5to 8) units.
The Bidders are required to quote the rates strictly as per the Rate Quoting Sheet
after carefully going through the complete tender documents
CONTRACT AGREEMENT
This contract agreement entered in to this ______ day of the month of ________, 2018 between
Haryana Power Generation Corporation Ltd., a body corporate constituted under the Indian
Company Act, 1956 herein after called Corporation which terms shall include all its heirs and
successors on the one hand and M/s _______________________________________________.
The contractor which terms shall include all its heirs and successors on the other hand.
The contractor will comply with all the provisions of the relevant labour laws/Acts and the rules
/regulations framed there under. In the event of PTPS, Panipat being obliged to pay the
compensation, the contractor will indemnify the Corporation. The labour regulation shall be treated
as part of the contract. Any break of labour laws/regulation shall be treated as breach of the
contract.
Here PTPS, Panipat and the contractor have agreed to execute an agreement.
Now this deed witness and parties hereto hereby mutually agree as above.
In witness thereof, the contractor & HPGCL hereto set their hands as under.
Witness Witness
Acceptance Certificate
I__________________________________Designation__________________________________
______________________________________________________________________________
hereby accept all the terms and conditions given in the above tender document.
9. Past Experience:-
Name of Organization Period Reference of Order Value contract
Contract wise
Bidder Response
Sr. No. Technical Specification
(Yes or No)
1 Tender cost with e-service fees @ Rs. 2,180/- YES / NO
Earnest Money Deposited @ Rs. 25800/-
2 YES / NO
Or documentary proof of EMD exemption documents
3 Acceptance of all terms & conditions of tender (Annexure-X) YES / NO
4 Documentary proof of EmAEA Firm and enlisted with M/s BEE List YES / NO
Copy of successfully executed work orders for same or similar item
during last 5 years ending 31.01.2018 in 210 MW units or above
capacity power plants and having minimum order value as under:
5 Single order of the value not less than Rs. 20,00,000/- OR YES / NO
Two orders of the value not less than Rs. 12,00,000/- each
OR
Three orders of the value not less than Rs. 8,00,000/- each
6 Documentary Proof for annual turnover certificates as per NIT. YES / NO
7 Documentary Proof for GST registration number. YES / NO
8 Documentary Proof for permanent account (PAN) number. YES / NO
Authority letter in the name of the Authorized Person who has signed
9 the Tender Document / Price Bid on behalf of the Contractor / YES / NO
Company.
The certificate to the effect that the tenderer is not black listed from
10 any Public Sector Undertakings of Central Govt. / State Govt. / State YES / NO
Electricity Boards / Corporations.
11 Statement of bidders duly filled (Annexure-X) YES / NO