MUNICIPAL CORPORATION OF GREATER MUMBAI

e-TENDER

(Percentage Rate)

Name of “Civil & Structural Repairs to KMJ Phule Hospital,

work: Kannamwarnagar, Vikhroli(East) in S ward.

http://portal.mcgm.gov.in

Prepared by: -sd-

SE (HIC)ES

Checked by: -sd-

SE (HIC)ES

-sd- -sd-

AE(HIC)S&T EE (HIC) ES
Wards

Ch.E.(BM)’s office,

3 rd floor, Engineering Hub Building,

Dr.E.Moses Road, Worli Naka, Worli,

Mumbai 400 018

 INDEX

SECTION DESCRIPTION PG-NO

1 E-TENDER NOTICE 5

2 ELIGIBILITY CRITERIA 11

3 DISCLAIMER 17

4 INTRODUCTION 20

5 E-TENDER ONLINE SUBMISSION PROCESS 23

6 INSTRUCTIONS TO APPLICANTS 27

7 SCOPE OF WORK 49

8 BILL OF QUANTITIES 51

9 SPECIAL DIRECTIONS TO THE TENDERER 88

10 GENERAL CONDITIONS OF CONTRACT 93

11 SPECIFICATIONS & SELECTION OF MATERIAL 159

12 FRAUD AND CORRUPT PRACTICES 162

13 LIST OF APPROVED BANKS 167

14 APPENDIX 171

15 FORM OF TENDER 172

16 AGREEMENT FORM 177

17 ANNEXURE A 180

18 ANNEXURE B 182

19 ANNEXURE C 185

20 ANNEXURE D 187

21 BANKERS GUARANTEE 188

22 PROFORMAS 190

3
 SECTION 1

E-TENDER NOTICE

5
 MUNICIPAL CORPORATION OF GREATER MUMBAI
HEALTH INFRASTRUCTURE CELL

Ch.E /BM/24435 / HIC /II / Date:- 15-04-2017

e-TENDER NOTICE

Sub: “Civil & Structural Repairs to KMJ Phule Hospital,

Kannamwarnagar, Vikhroli(East) in S ward.’’

The Municipal Corporation of Greater Mumbai (MCGM) invites

e-tender to appoint Contractor for the aforementioned work from contractors
of repute, multidisciplinary engineering organizations i.e. eminent firm,
Proprietary/Partnership Firms/ Private Limited Companies/ Public Limited
Companies/Companies registered under the Indian companies’ act 2013,
the contractors registered with the Municipal Corporation of Greater
Mumbai, (MCGM) in Class ‘A’ and category C-1 as per old registration
and class ‘III’ as per new registration and from the contractors/firms
equivalent and superior classes registered in Central or State
Government/Semi Govt. Organization/Central or State Public Sector
Undertakings, excluding those who are demoted/blacklisted in MCGM,
P.W.D, other Government/ Semi Govt organizations in India. The
contractors who are not registered with MCGM will have to apply for
registering their firm within three months time period from the award of
contract, otherwise their Bid Security i.e. E.M.D (Earnest Money Deposit)
will be forfeited/recovered and an amount equal to Registration Fee of
respective class will be recovered as penalty.
Joint Venture or Consortium will not be allowed for this tender.

Bidding Process will comprise of THREE stages.

The application form can be downloaded from MCGM's portal

(http://portal.mcgm.gov.in) on payment of Rs.13,400/- + 6.0% VAT. The
applicants not registered with MCGM are mandated to get registered(Vendor
Registration) with MCGM for e-tendering process & obtain login credentials
to participate in the online bidding process.Note:- Tender cost shall be
deposited in G.L. Code no. 150110300 & the 6.0% VAT on e-tender cost
shall be deposited in G.L. Code no 350300508.

7
i) To download the application form, for those applicants not having vendor
registration, need to apply first for vendor registration at the office of
Account Officer (FAR), 3rd floor, Municipal Headquarter.
ii) Followed by SRM login ID and password to be obtained from Central
Purchase Department (CPD), Office at Byculla, Bakariadda, Mumbai
iii) For e-Tendering registration, enrolment for digital signature certificates
and user manual, please refer to respective links provided in ‘Tenders’
tab. Vendors can get digital signature from any one of the Certifying
Authorities (CA's) licensed by controller of certifying authorities namely,
Safes crypt, IDRBT, National informatics centre, TCS, CUSTOMS, MTNL,
GNFC and e- Mudhra CA.

Name and Contract Estimated Cost E.M.D. in Cost of

location of work period of Project Rs. e-Tender
in Rs.
Civil & Structural Rs. Rs.13,400/-
16 Civil cost =
Repairs to KMJ Rs 1,45,74,540/- 1,87,000/- + 6.0% VAT
Months
Phule Hospital,
(Inclusive Electrical cost=
Kannamwarnagar, Rs 41,18,780/-
of
Vikhroli(East) in S
monsoon) Total cost =
ward Rs 1,86,93,320/-

In terms of the 3 stage system of e-tendering, a Bidder will be

required to deposit, along with its Bid, an Earnest Money Deposit of Rs.
1,87,000/- (Rupees One lakh eighty seven thousand only) (the "EMD"),
refundable in accordance to the relevant clause of bid document, from the
Bid Due Date, except in the case of the selected Bidder whose Bid
Security/EMD shall be retained. The Bidders will have to provide Earnest
Money Deposit through the payment gateways while submitting the bids.
The Bid shall be summarily rejected if it is not accompanied by the Earnest
Money Deposit. The e-tender is available on MCGM portal
(http://portal.mcgm.gov.in) as mentioned in the Header Data of the tender.

As per THREE Packet systems, the document for Packet A& B is

to be uploaded by the bidder in vendors’ document online in Packet A, B.

8
Packet A,B& C shall be opened on dates as mentioned in header data. All
the responsive and eligible bidders if they so wish can be present at the time
of opening of bids, in the office of Dy.Chief Engineer (Health
Infrastructure Cell). The Packet C shall be opened if bids submission in
Packet A& B satisfies/includes all the requirements and same are found
acceptable to the Authority.

The Municipal Commissioner reserves the right to reject all or

any of the e- tender(s) without assigning any reasons at any stage.

The dates and time for submission and opening the bids are as
shown in the Header Data. If there are any changes in the dates the same
will be displayed on the MCGM Portal. (http://portal.mcgm.gov.in) .

The Applicants interested for the above referred works may

contact the Dy.Chief Engineer (Health Infrastructure Cell)at the following
address on any working day during office hours.

Dy.Chief Engineer (Health Infrastructure Cell)’s office,

3 rd floor, Engineering Hub Building,
Dr.E.Moses Road, Worli Naka, Worli,
Mumbai 400 018.

The applicants may wish to visit the site under reference located at
“Civil & Structural Repairs to KMJ Phule Hospital,
Kannamwarnagar, Vikhroli(East) in S ward.’’ and can collect the
information of the present status from the department who have
invited the bids.

The MCGM reserves the rights to accept any of the application

or reject any or all the application received for above works, without
assigning any reasons thereof. The information regarding above subject
matter is available on Website of MCGM.
(http://portal.mcgm.gov.in/tenders).

-Sd-

Exe.Engineer (HIC)ES

9
 HEADER DATA

Tender Document Number 7100098484

Name of Organization Municipal Corporation of Greater Mumbai
Subject “Civil & Structural Repairs to KMJ Phule
Hospital, Kannamwarnagar, Vikhroli(East) in
S ward.’’

Cost of Tender Rs.13,400/- ( + 6.0% VAT)

Cost of E-Tender (Estimated Cost) Rs. 1,86,93,320/-

Bid Security Deposit/Earnest Rs. 1,87,000/-
Money Deposit
Date of issue and sale of tender 15/ 04 /2017 from 11:00 AM
Pre-Bid Meeting ……………...at 11:00Hrs in conference room
of Ch.Eng.(---------------)

Last date & time for sale of tender 24/ 04 /2017 up to 12:00 Hours
&Receipt of Bid Security Deposit
Submission of Packet A,B & C 24 / 04 /2017 up to 16:00 Hours
(Online)
Opening of Packet – A 26 / 04/2017 after 16:01 Hours
Opening of Packet – B 26 / 04 /2017 after 16:05 Hours

Opening of Packet – C 16 / 05 /2017 after 15:00 Hours

Address for communication Office of the:-
Dy.Chief Engineer (HIC), 3rd floor,
Engineering Hub Building, Dr.E.Moses
Road, Worli Naka, Worli, Mumbai-018
Venue for opening of bid On line in Dy.Ch. Engg. (HIC)’s office.

This tender document is not transferable.

The MCGM reserves the rights to accept any of the application or reject any
or all the application received for above subject without assigning any
reason thereof.
Due to any unforeseen circumstances if any of the date mentioned in the
header data is declared as public holiday, in that case all the dates* will get
shifted by one day or next working day.

-sd- -
Exe.Engineer (HIC)ES

10
 SECTION 2
ELIGIBILITY CRITERIA

11
 POST QUALIFICATION

A. Technical Capacity

(1) The tenderer(s) in their own name should have satisfactorily

executed the work of similar nature in MCGM /Semi Govt. /Govt. &
Public Sector Organizations in during last seven (7) years ending
last day of month previous to the one in which bids are invited as a
prime Contractor (or as a nominated sub-Contractor, where the
subcontract had involved similar nature of work as described in the
scope of works in this bid document, provided further that all other
qualification criteria are satisfied)

a) Three similar completed works each of value not less than the
value equal to 20% of estimated cost put to tender
Or
b) Two similar completed works each of value not less than the
value equal to 25% of estimated cost put to tender.
Or
c) One similar completed work of value equal and or not less than
the 40% of estimated cost put to tender

The value of executed works shall be brought to current costing level

by enhancing the actual value of work at compound rate of 10 % per
annum; calculated from the date of completion to last date of receipt
of applications for tenders.

(2) Similar Experience: For assessing the technical capacity,similar

work shall mean, the completed or on-going works in:
(a) Building Construction/Repairs/Retrofitting/Structural
Repairs.
(b) Mechanical & Electrical works.
(c) For assessing the technical capacity of Regular, Routine
and maintenance works; Similar work shall mean, the completed
or ongoing works in Building construction OR Building
Maintenance such as repairs/retrofitting/structural repairs OR

12
 construction/repairs of Asphalt/concrete roads OR
laying/rehabilitation of sewer lines along with allied components
OR laying/rehabilitation of water pipe lines in Cast
iron/M.S.pipes/HDPE/MDPE pipes OR
repairs/maintenance/construction of culverts over nullah.

B. Financial Capacity

Achieved an average annual financial turnover as certified by ‘Chartered

Accountant’ (in all classes of civil engineering construction works only)
equal to 30% of the estimated cost of work in last three (3) financial
years immediately preceding the Financial Year in which bids are invited.
The value of executed works shall be brought to current costing level by
enhancing the actual value of work at compound rate of 10 % per
annum; calculated from the date of completion to last date of receipt of
applications for tenders.

C. Bid Capacity:
The bid capacity of the prospective bidders will be calculated as under
Assessed Available Bid Capacity = (A* N* 2 - B)
Where,
A= Maximum value of Civil Engineering works executed in any one
year (year means Financial year) during the last five years
(updated to the price level of the Financial year in which bids are
received at a rate of 10% per year) taking into account the
completed as well as works in progress.
N= Number of years prescribed for completion of the
Project/Works,including monsoon period, for which these bids
are being invited. (E.g. 16 months = 16/12 year) For every
intervening monsoon 1.33 shall be added to N.
B= Value of existing commitments (only allotted works) on the last
date of submission of bids as per bidding document and on-going
works to be completed during the period of completion of the
Project/Works for which these bids are being invited.

Note: The statement showing the value of existing commitments and on-
going works as well as the stipulated period of completion
13
 remaining for each of the works listed should be attached along
with certificates duly signed by the Engineer-in Charge, not below
the rank of an Executive Engineer or equivalent.

Even though the bidders meet the above qualifying criteria, they are
subject to be disqualified if they have:

- made misleading or false representation in the forms, statements

and attachments submitted in proof of the qualification
requirements; and/or
- Record for poor performance such as abandoning the works, not
properly completing the contract, inordinate delays in completion,
litigation history, or financial failures etc
Equipment Capabilities as required for this work:

The successful bidder will make the arrangements of the required

equipment on the day of commencement or with respect to the progress
of the work in phases, as per the instructions of site in charge. The
successful bidder will ensure commitment in this respect on an
undertaking on Rs.500 stamp paper to be submitted along with the Bid
in Packet B. However, this condition in no way shall dilute the respective
condition in Registration Rules of MCGM. The list of minimum
equipments (which can be owned/hired/assured access) required for
execution of subject work is as follows:

Sr.
Equipment Owned Requirements
No.
1 Mortar mixer 1 Nos.
2 Sand washing machine 1 No.
3 Vibrators (Needle) with all sizes needle 2 Nos.
4 Concrete mixer ( Non tilting ) 1 No.
5 Site Chowky for work 1 No.
6 Excavator Nil.
7 Compressive Testing Machine (New Works) Nil.

Note:

14
 1. Bidders shall submit the undertaking for equipment capability and
other undertakings as such on a single Rs.500/- stamp paper.

Technical Personnel

The contractor shall employ personnel, as mentioned below (including

but not limited to) for successful completion of the subject tender work:

Technical Personnel (During Construction Period)

Min. nos.
Sr.
Post Qualification to be
No.
deployed
Principal
At least B.E. (Civil) with min. 5 years
1 Technical 1
experience
Representative
Project/ Site At least B.E. (Civil) with min. 2 years
2 Engineer/Billi experience or D.C.E. with min. 5 years 1
ng Engineer experience.
At least B.E. (Electrical) with min.2
Electrical
3 years experience or D.E.E. with 1
Engineer
minimum 5 years experience.
At least B.E. (Civil) with min. 3 years
Quality experience or D.C.E. with min. 5 years
4 Nil
Engineer experience and min. 2 years experience
in Q.C.
Supervisory Having grade III & above license from
5 1
staff MCGM

The failure in providing experienced technical and /professional ability

personnel, and even ignoring the instruction of the Engineer-in-charge in
this regards, will subject to recovery of penalty as mentioned below:

Technical Personnel (During Construction Period)

Sr. Rate of
Qualification Min. Experience(years)
No. Recovery
1 Project Manager 10 years Rs.30000/-p.m.
2 Graduate Engineer 5years Rs.25000/-p.m.
3 Graduate Engineer 2years Rs.15000/-p.m.
4 Diploma Engineer 5 years Rs.15000/-p.m.

Setting of Site Laboratories:

15
 Contractors shall set up a laboratory at site before commencement of
work at their cost for performing various tests and at least the following
machines and equipments shall be provided therein –

1. Set of Sieves as per I.R.C. /I.S.

2. Compressive Testing Machine(For new works)
3. Oven, Electrically Operated
4. Weighing Balance (20 kg capacity)
5. 3 m straight edge
6. Sieve shaker
7. First Aid Box
8. Measuring Jar (for silt content)
9. Other Machines/apparatus as may be directed by the Engineer
10. VernierCaliber
11. Level / Theodolite
12.Slump Cone
All the test records shall be maintained in the site office and made
available as and when required. The laboratory must be established
within 15 days from the date of receipt of the orders from Engineer In
charge. On failure to do so, a penalty of Rs 1000/- per day shall be
imposed.
The contractor shall install testing equipment at site. The contractor
shall ensure and certify the calibration of the equipment so installed and
shall maintain the same in working order throughout the period of
construction. The contractor shall also provide necessary technically
qualified experienced trained staff for carrying out such tests for using
such equipment. The tests shall be carried out under the supervision of
the Engineer-in-charge. The calibration shall be checked every twelve
months as directed by Engineer-in-charge.
-sd-
Exe.Engineer (HIC)ES

16
 SECTION 3

DISCLAIMER

17
 DISCLAIMER
The information contained in this e-tender document or provided to
Applicant(s), whether verbally or in documentary or any other form, by or on
behalf of the Municipal Corporation of Greater Mumbai (MCGM), hereafter
also referred as “The Authority “, or any of its employees or advisors, is
provided to Applicant(s) on the terms and conditions set out in this e-tender
and such other terms and conditions subject to which such information is
provided.

This e-tender includes statements, which reflect various assumptions

and assessments arrived at by the Municipal Corporation of Greater
Mumbai (MCGM) in relation to the Project. Such assumptions, assessments
and statements do not purport to contain all the information that each
Applicant may require. This e-tender may not be appropriate for all persons,
and it is not possible for the Municipal Corporation of Greater Mumbai
(MCGM), its employees or advisors to consider the investment objectives,
financial situation and particular needs of each party who reads or uses this
e-tender. The assumptions, assessments, statements and information
contained in this e-tender may not be complete, accurate, adequate or
correct. Each Applicant should therefore, conduct its own investigations and
analysis and should check the accuracy, adequacy, correctness, reliability
and completeness of the assumptions, assessments, statements and
information contained in this e-tender and obtain independent advice from
appropriate sources.

Information provided in this e-tender to the Applicant(s) is on a wide

range of matters, some of which may depend upon interpretation of law. The
information given is not intended to be an exhaustive account of statutory
requirements and should not be regarded as a complete or authoritative
statement of law. The Municipal Corporation of Greater Mumbai (MCGM)
accepts no responsibility for the accuracy or otherwise for any interpretation
or opinion on law expressed here.

The Municipal Corporation of Greater Mumbai(MCGM), its employees

and advisors make no representation or warranty and shall have no liability
to any person, including any Applicant or Bidder, under any law, statute,
rules or regulations or tort, principles of restitution or unjust enrichment or
otherwise for any loss, damages, cost or expense which may arise from or be
incurred or suffered on account of anything contained in this e-tender or

18
otherwise, including the accuracy, adequacy, correctness, completeness or
reliability of the e-tender and any assessment, assumption, statement or
information contained therein or deemed to form part of this e-tender or
arising in any way with pre-qualification of Applicants for participation in
the Bidding Process.The Municipal Corporation of Greater Mumbai (MCGM)
also accepts no liability of any nature whether resulting from negligence or
otherwise howsoever caused arising from reliance of any Applicantupon the
statements contained in this e-tender.

The Municipal Corporation of Greater Mumbai (MCGM) may, in its

absolute discretion but without being under any obligation to do so, update,
amend or supplement the information, assessment or assumptions
contained in this e-tender.

The issue of this e-tender does not imply that the Municipal
Corporation of Greater Mumbai (MCGM) is bound to select and short-list
pre-qualified Applications for Bid Stage or to appoint the selected Bidder or
Concessionaire, as the case may be, for the Project and the Municipal
Corporation of Greater Mumbai (MCGM) reserves the right to reject all or
any of the Applications or Bids without assigning any reasons whatsoever.

The Applicant shall bear all its costs associated with or relating to the
preparation and submission of its Application including but not limited to
preparation, copying, postage, delivery fees, expenses associated with any
demonstrations or presentations which may be required by The Municipal
Corporation of Greater Mumbai (MCGM) or any other costs incurred in
connection with or relating to its Application. All such costs and expenses
will remain with the Applicant and the Municipal Corporation of Greater
Mumbai(MCGM) shall not be liable in any manner whatsoever for the same
or for any other costs or other expenses incurred by an Applicant in
preparation or submission of the Application, regardless of the conduct or
outcome of the Bidding Process.

19
 SECTION 4

INTRODUCTION

20
 INTRODUCTION
1. Background:

The Municipal Corporation of Greater Mumbai covers an area of

437.71sq.kms.with a population of 1.24 Crores as per census of 2011. The
metropolis accounts major portion of India’s international trade and
government’s revenue, from being one of the foremost centers of education,
science and technological research and advancement.

The Mumbai Metropolis has historic tradition of strong civic activism

dedicated to the cause of a better life for all its citizens. And it’s the
Municipal Corporation of Greater Mumbai (MCGM), hereafter called the
“corporation”, the primary agency responsible for urban governance in
Greater Mumbai.

MCGM (The Authority) is one of the largest local self-governments in

the Asian Continent. In observance of historic traditions of strong civic
activism, with the change in time and living conditions to match with the
urbanization, MCGM has mainly focused in providing almost all kinds of
engineering services viz, Hydraulics, storm water drain, sewerage, water
supply projects, roads, bridges, solid waste management, and environmental
services. Beside this, the MCGM is also providing dedicated services in
various segments such as Health, Primary Education as well as the
construction and maintenance of Public Markets and Slaughter Houses.

MCGM is an organization having different departments, right from

engineering depts. to health depts. Moreover we have other dept. like
education, market, fire brigade dept., Octroi and other such departments
where quite a good number of staff members are working.

Scope of Work:

MCGM is primarily an organization, which in the interest of citizens

and with the speed of urbanization deals with the variety of the
infrastructure services and delivered to the public by different departments
like Water Supply Projects, Sewerage Projects, Hydraulics, Storm Water
Drain/Roads and bridges and Building Construction etc.

21
Name of work:- Civil & Structural Repairs to KMJ Phule Hospital,
Kannamwarnagar, Vikhroli(East) in S ward.

Civil Work:-

1. Waterproofing of terrace & toilet blocks.

2. Structural repairs such as Column jacketing & Polymer
treatment to slab & beam.
3. Internal/External plastering wherever damaged.
4. Repairs to toilet blocks.
5. False ceiling to CMO room & ICU entry (ground floor).
6. Internal/External painting.
7. Plumbing work.

Electrical Work:-

The electrical estimate is prepared in which removing & refixing of existing

panels, switchgears, pumps, CCTV cameras, Solar Water Heating system,
some part of cabling work is considered. In Medical Gas System, dismantling
of existing system and SITC of new system is considered. The existing panels
in Medical gas room is in working condition so it is not taken in the scope of
work. ICU , Operation theatres , extension bldg. (Laboratary) and few rooms
which are good in condition is not considered for rewiring work. As HVAC
system is under CSMC, it is not considered in this work. Removing and
refixing of HVAC system and window / split A/Cs are to be carried out in
OTs and concerned rooms.

22
 SECTION 5

E-TENDERING ONLINE
SUBMISSION PROCESS

23
 E-TENDERING ONLINE SUBMISSION PROCESS

The terminology of e-Tendering is solely depending upon policies in

existence, guidelines and methodology adopted since decades. The SRM is
only change in process of accepting and evaluation of tenders in addition to
manual. The SAP module to be used in this E-tendering is known as
Supplier Relationship Module (SRM).SRM is designed and introduced by
ABM Knowledge ware Ltd. who will assist MCGM in throughout the
tendering process for successful implementation.
NOTE: This tendering process is covered under Information Technology ACT
& Cyber Laws as applicable
(1) In e-tendering process some of the terms and its definitions are to be
read as under wherever it reflects in online tendering process.
Start Date read as “Sale Date”
End Date read as “Submission Date”
Supplier read as “Contractor/bidder”
Vendor read as “Contractor/bidder”
Vendor Quotation read as “Contractors Bid/Offer”
Purchaser read as “Department/MCGM”

I. Before entering in to online tendering process, the contractors should

complete the registration process so as to get User ID for E-tendering
links. For this, the contractors can access through Supplier registration
via MCGM Portal.

There are two methods for this registration :( II and III)

II. Transfer from R3 (registered contractors with MCGM) to SRM

a. Contractors already registered with MCGM will approach to Vendor
Transfer cell.
b. Submit his details such as (name, vendor code, address, registered
Email ID, pan card etc.) to Vendor transfer cell.
c. MCGM authority for Vendor Transfer, transfers the Vendor to SRM
application from R3 system to SRM system.
d. Transferred Vendor receives User ID creation link on his supplied mail
Id.
e. Vendor creates his User ID and Password for e-tendering applications
by accessing link sent to his mail ID.
24
III. Online Self Registration (Temporary registration for applicant not
registered with MCGM)

a. Vendor fills up Self Registration form via accessing MCGM portal.

b. Vendor Transfer cell (same as mentioned above) accesses Supplier
Registration system and accepts the Vendor request.
c. Accepted Vendor receives User ID creation email with Link on his
supplied mail Id.
d. Vendor creates his User ID and Password for e-tendering application.

IV. CONTRACTORS BIDDING: Applicant will Quote and Upload Tender

Documents
1. Access e-tender link of SRM Portal
2. Log in with User ID and Password
3. Selects desired Bid Invitation (he wants to bid)
4. To download tender documents contractors will have to pay online
Tender fee. The same can be done by accessing Pay Tender Fees
option. By this one will be able to pay Tender fee through Payment
Gateway-If transaction successful, Contractors can register his
interest to participate. Without Registration one cannot quote for the
Bid/Tender.
5. Applicant will download Tender Documents from Information from
purchaser tab by accessing Purchaser document folder through
collaboration ‘C’ folder link.
6. Applicant will upload Packet A related and Packet B related
Documents in Packet A and Packet B folder respectively by accessing
these folders through “My Notes” Tab and collaboration folder link.
7. All the documents uploaded have to be digitally signed and saved.
Contractors can procure there digital signature from any certified
CA’s in India.
8. Bid security deposit/EMD and ASD, if applicable, should be paid
online as mentioned in tender.
9. For commercial details (in Packet C) contractors will fill data in Item
Data tab in Service Line Item via details and quotes his “Percentage
Variation” (i.e.% quoted) figure.(If entered ‘0’ it will be treated as at
par. By default the value is zero only.
10. Applicants to check the bid, digitally signs & save and submit his
Bid Invitation.

25
 11. Applicants can also save his uploaded documents/commercial
information without submitting the BID for future editing through
‘HOLD’ option.
12. Please note that “Hold” action do not submit the Bid.
13. Applicants will receive confirmation once the Bid is submitted.
14. Bid creator (MCGM) starts Bid Opening for Packet A after reaching
End Date and Time and Bid Evaluation process starts.

As per Three Packet system, the document for Packet A& B are to be
uploaded by the tenderer in 'Vendor's document' online in Packet A & B.
Before purchasing/ downloading the tender copy, tenderer may refer to
post- Qualification criteria mentioned in e-Tender Notice.

The tenderer shall pay the EMD/Bid Security through payment gateways
before submission of Bid and shall upload the screenshot of receipt of
payment in Packet ‘A’ instead of paying the EMD at any of the CFC centers
in MCGM Ward Offices.

The e-tender is available on MCGM portal, http://portal.mcgm.gov.in, as

mentioned in the Header Data of the tender. The tenders duly filled in
should be uploaded and submitted online on or before the end date of
submission. The Packet ‘A’, Packet ‘B’ & Packet ‘C’ of the tenderer will be
opened as per the time-table shown in the Header Data in the office of
Dy.Ch Engineer (Health Infrastructure Cell)

The Municipal Commissioner reserves the right to reject all or any of the e-
Tender(s) without assigning any reason at any stage. The dates and time for
submission and opening the tenders are as shown in the Header Data. If
there are any changes in the dates the same will be displayed on the MCGM
Portal (http://portal.mcgm.gov.in).

Due to any unforeseen circumstances if any of the date mentioned in the

header data is declared as public holiday, in that case all the dates* will get
shifted by one day or next working day.

26
 SECTION 6

INSTRUCTIONS TO BIDDERS

27
 INSTRUCTIONS TO BIDDERS

Scope of Application

The Authority wishes to receive Applications for Qualification in order to

SELECT experienced and capable Applicants for the Bid Stage.

A. TIME PERIOD OF THE PROJECT

Entire project should be completed and delivered within 16 months of

time from the date of award of contract that includes Monsoon.

The time allowed for carrying out the work as entered in the Tender shall
be strictly observed by the Contractor and shall be reckoned from the
date on which the Letter of Acceptance is given to the Contractor. The
work shall throughout the stipulated period of the Contract be proceeded
with all due diligence as time being deemed to be the essence of the
contract on the part of the Contractor. On failing to do so, the Contractor
shall pay as compensation an amount which shall be governed as per
Clause - 8(e) of Standard General Conditions of Contract
The Contractor should complete the work as per phase given below :

¼ of the work in .. ¼ of the time

½ of the work in .. ½ of the time
¾ of the work in .. ¾ of the time
Full of the work in .. Full of the time
Full work will be completed in 16 months Including monsoon.
However deviations if any from above phasing will be got duly approved
by the engineer in charge.
The programme for completion of work shall be a part of the Contract
Document in the form of Bar Chart / GANTT Chart. The Contractor is
supposed to carry out the work and keep the progress as per Bar
Chart/GANTT Chart. The Contractor shall complete the work as per the
Schedule given in the Contract and the programme submitted by the
Contractor.

28
 B. Contract Execution

All required documents for execution of the contract shall be submitted

within 30 days from the date of issue of letter of acceptance. If the
documents are not submitted within the stipulated time a penalty of Rs
5000/- per day will be applicable to the contractor. All contract
documents need to be duly affixed with stamp duty properly signed along
with evidence/proof of payment of security/contract deposit/ within 30
days from the date of letter of acceptance received by him

C. If the amount of the Contract Deposit to be paid above is not paid

within 30 days from the date of issue of Letter of Acceptance, the
Tender / Contractor already accepted shall be considered as
cancelled and legal steps be taken against the contractor for
recovery of the amounts.

D. The amount of Security Deposit retained by the MCGM shall be

released after expiry of period up to which the contractor has
agreed to maintain the work in good order is over. In the event of
the contractor failing or neglecting to complete the rectification
work within the period up to which the contractor has agreed to
maintain the work in good order, the amount of security deposit
retained by MCGM shall be adjusted to-wards the excess cost
incurred by the Department on rectification work.

E. Action when whole of security deposit is forfeited:

In any case in which under any Clause of this contract, the contractor
shall have rendered himself liable to pay compensation amounting to the
whole of this security deposit whether paid in one sum or deducted by
installments or in the case of abandonment of the work owning to serious
illness or death of the contractor or any other cause, the Engineer on
behalf of the Municipal Commissioner shall have power to adopt any of
the following process, as he may deem best suited to the interest of
MCGM -
(a) To rescind the contract (for which recession notice in writing to the
contractor under the head of Executive Engineer shall be conclusive
evidence) and in that case, the security deposit of the contract shall
stand forfeited and be absolutely at the disposal of MCGM.
(b) To carry out the work or any part of the work departmentally
debiting the contractor with the cost of the work, expenditure
29
 incurred on tools and plant, and charges on additional supervisory
staff including the cost of work-charged establishment employed for
getting the un-executed part of the work completed and crediting
him with the value of the work done departmentally in all respects in
the same manner and at the same rates as if it had beencarried out
by the contractor under the terms of his contract. The certificate of
the Executive Engineer as to the costs and other allied expenses so
incurred and as to the value of the work so done departmentally
shall be final and conclusive against the contractor.
(C) To order that the work of the contractor be measured up and to take
such part thereof as shall be un-executed out of his hands, and to
give it to another contractor to complete, in which case all expenses
incurred on advertisement for fixing a new contracting agency,
additional supervisory staff including the cost of work charged
establishment and the cost of the work executed by the new contract
agency will be debited to the contractor and the value of the work
done or executed through the new contractor shall be credited to the
contractor in all respects and in the same manner and at the same
rates as if it had been carried out by the contractor under the terms
of his contract. The certificate of the Executive Engineer as to all the
cost of the work and other expenses incurred as aforesaid for or in
getting the un-executed work done by the new contractor and as to
the value of the work so done shall be final and conclusive against
the contractor.
In case the contract shall be rescinded under Clause (a) above, the
contractor shall not be entitled to recover or be paid any sum for any
work therefore actually performed by him under this contract unless
and until the Executive Engineer shall have certified in writing the
performance of such work and the amount payable to him in respect
thereof and he shall only be entitled to be paid the amount so
certified. In the event of either of the courses referred to in Clause (b)
or (c) being adopted and the cost of the work executed
departmentally or through a new contractor and other allied
expenses exceeding the value of such work credited to the
contractors amount of excess shall be deducted from any money due
to the contractor, by MCGM under the contract or otherwise,
howsoever, or from his security deposit or the sale proceeds thereof
provided, however, the contractor shall have no claim against MCGM
even if the certified value of the work done departmentally or
through a new contractor exceeds the certified cost of such work and
allied expenses, provided always that whichever of the three courses
30
 mentioned in clauses (a), (b) or (c) is adopted by the Executive
Engineer, the contractor shall have no claim to compensation for any
loss sustained by him by reason of his having purchase or procured
any materials or entered in to any engagements or made any
advance on account of or with a view to the execution of the work or
the performance of the contract.

F. Contract may be rescinded and security deposit forfeited for

bribing a public officer or if contractor becomes insolvent:

If the contractor assigns or sublets his contracts or attempt so to do, or

become insolvent or commence any proceeding to get himself adjudicated
and insolvent or make any composition with his creditors, or attempt so
to do or if bribe, gratuity, gift, loan, perquisite, reward or advantage,
pecuniary or otherwise, shall either directly or indirectly be given
promised or offered by the contractor or any of his servants or agents
through any public officer, or person in the employ of MCGM/Govt. in
any way relating to his office or employment, or if any such officer or
person shall become in any way directly or indirectly interested in the
contract the Engineer In-charge may thereupon, by notice in writing
rescind the contract and the Security Deposit of the Contractor shall
thereupon stand forfeited and be absolutely at the disposal of MCGM and
the same consequences shall ensure as if the contract had been
rescinded under above clause J hereof; and in addition the contractor
shall not be entitled to recover or be paid for any work therefore actually
performed under the contract.

G. Instruction to tenderer during execution of Electrical /

Mechanical work.
The Electrical / Mechanical work shall be got carried out by the civil
contractors through the contractors registered with M.C.G.M. in
Electrical Category of class ‘A’ & above as per new registration rules
2015. Information about the registered contractors shall be obtained
from the office of the Ch.E.(M&E)/ E.E.(Monitoring & Registration
Cell). Attested scanned copy of the valid registration certificate in
Electrical Category shall be uploaded with the tender alongwith the
undertaking from the registered Electrical Contractor stating his
willingness to carry out the tender work.

31
 The name of electrical contractor shall be specified at the time of
quoting & separate subcontractor status should be accorded to them in
the contract.

Submission of Tenders
PACKET – A

The Packet ‘A’ shall contain scanned certified copies of the following
documents
Scrutiny of this packet will be done strictly with reference to only the
scanned copies of Documents uploaded online in packet ‘A’

a) Valid Registration Certificate.

b) Valid Bank Solvency Certificate of Minimum Solvency amount as
governed by Registration Rules in force for respective Class of
Contractor for Civil and M&E works.(Rs. 75,00,000/- for this tender)
c) A document in support of Registration under Maharashtra ‘VAT’ Act
2002. Sales Tax Registration Certificate in Maharashtra (or equivalent
requirement under VAT). Those not registered in Maharashtra shall
submit an undertaking to the effect that if they are successful tenderer,
they shall submit Sales Tax Registration Certificate in Maharashtra
within 15 days of issue of work order, failing which payment for the
work executed will not be released.
d) Certified copies of valid 'PAN' documents and photographs of the
individuals, owners, Karta of Hindu undivided Family, firms, private
limited companies, registered co-operative societies, partners of
partnership firms and at least two Directors, if number of Directors are
more than two in case of Private Limited Companies, as the case may
be. However, in case of Public Limited companies, Semi Government
Undertakings, Government Undertakings, no 'PAN' documents will be
insisted.
e) Latest Partnership Deed in case of Partnership firm duly registered with
Chief Accountant (Treasury) of MCGM.
The bidders shall categorically provide their Email-ID in packet ‘A’.

NOTE:

32
  If the tenderer(s) withdraw tender offer during the tender validity
period, his entire E.M.D shall be forfeited.
 If it is found that the Bidder has not submitted required documents in
Packet “A” then, the shortfalls will be communicated to the Bidder
through e-mail only and compliance required to be made within a time
period of three working days otherwise they will be treated as non-
responsive.

PACKET – B

The Packet ‘B’ shall contain scanned certified copies of the following
documents –

a) The list of similar type of works as stated in para ‘A’ of Post

qualification successfully completed during the last five years in
prescribed proforma, in the role of prime contractor. Information
furnished in the prescribed proforma (Proforma – I) shall be supported
by the certificate duly self-attested. Documents stating that it has
successfully completed during the last five years at least one contract
of similar works as stated in para ‘A’ of Post qualification.

b) Annual financial turnover for preceding three financial years as

certified by Chartered Accountant preceding the Financial Year in
which bids are invited. Copies of Applicants duly audited balance
sheet and profit and loss account for the preceding three
financial years preceding the Financial Year in which bids are
invited. (Proforma – II)

c) Documents stating that, it has access to or has available liquid assets,

unencumbered assets, lines of credit and other financial means
(independent of any contractual advance payment) sufficient to meet
the construction cash flow requirements for the subject contract in
the event of stoppage, start-up, or other delay in paymentof the
minimum 15% of the cost of the work tendered for, net of the
tenderer's commitment of other contracts (Certificate from Bankers /
C.A./Financial Institution shall be accepted as a evidence).

d) The bidder shall give undertaking on Rs 500/-stamp paper that it is

33
 his/their sole responsibility to arrange the required machineries either
owned/on lease or hire basis, at site before start of the work.

The successful bidder shall make the arrangements of the required

equipment on the day of commencement or with respect to the
progress of the work in phases, as per the instructions of site in
charge. The successful bidder and, to that effect he will ensure
commitment on an undertaking on Rs.500 stamp paper to be
submitted along with the Bid in Packet B. However, this condition in
no way shall dilute the respective condition in Registration Rules of
MCGM.

e) Details of works in hand (Proforma VI-A & VI-B) (original), along with
copies of work orders & attested copies of percentage of works
completed or part thereof.

f) Statement showing assessed available Bid Capacity.

g) The undertaking of Rs.500/- stamp paper as per the proforma

annexed in ‘Annexure B & C’

Note: Bidders shall submit the undertaking for equipment capability

and other undertakings as such on a single Rs.500/- stamp paper.

i) The tenderers shall upload work plan as per the following outline:

1. GANTT chart/ PERT/ CPM chart showing the completion of work

within prescribed time period, considering major activities.
2. Organizational set up envisaged by the contractors.
3. Plant & equipment proposed to be deployed for this work.
4. Site Offices and Laboratories proposed to be set up.
5. A note on how the whole work will be carried out (work plan
including methodology).
6. Quality management plan.
7. All the activities included in the Scope of Work shall be covered in
the work plan.
Note:

i. The Electrical / Mechanical work shall be got carried out by the civil

34
 contractors through the contractors registered with MCGM. in
Electrical Category. Information about the registered contractors shall
be obtained from the office of the Ch.E. (M&E)/ E.E. (Monitoring &
Registration Cell). Attested scanned copy of the valid registration
certificate in Electrical Category shall be uploaded with the tender
along with the undertaking from the registered Electrical Contractor
stating his willingness to carry out the tender work.

ii. The successful bidder shall submit valid registration certificate under
E.S.I.C., Act 1948, if the tenderer has more than 10 employees
/persons on his establishment (in case of production by use of energy)
and 20 employees/persons on his establishment (in case of
production without use of energy) to MCGM as and when demanded.
In case of less employees/persons mentioned above then the
successful bidder has to submit an undertaking to that effect on Rs.
200 stamp paper as per circular u/no. CA/FRD/I/65 of 30.03.2013.

iii. The successful bidder shall submit valid registration certificate under
E.P.F. & M.P., Act 1952, if tenderer has more than 20
employees/persons on his establishment, to MCGM as and when
demanded. In case if the successful bidder has less
employees/persons mentioned above then the successful bidder has
to submit an undertaking to that effect on Rs. 200 stamp paper as per
circular u/no. CA/FRD/I/44 of 04.01.2013.

Note:

If it is found that the Bidder has not submitted required documents in

Packet “B” then, the shortfalls will be communicated to the Bidder through
e-mail only and compliance required to be made within a time period of
three working days otherwise they will be treated as non-responsive.

PACKET – C

a. Online tender filled in either percentage plus or minus (above or

below), or at par. (There is no separate provision to quote % in
physical form, this is a part in Header Data of online Tendering). For
Packet ‘C’ tenderer(s) will fill data in ‘Item Data Tab’ in Service Line
Item via Details and quotes his percentage variation figures. (If
35
 entered ‘0’ it will be treated as ‘at par’. By default the value is zero
only).

Note: In case of rebate/premium of 15% and above as quoted by the

tenderer, the rate analysis of major items shall be submitted by L1
and L2 bidder after demand notification by e-mail to bidders by
Dy.Ch.Eng. The format for rate analysis is annexed at Annexure D.

BID SECURITY OR EMD

 The Bidder shall furnish, as part of the Bid, Bid Security/EMD, in the
amount specified in the Bid Data Sheet. This bid security shall be in
favour of the authority mentioned in the Bid Data Sheet and shall be
valid till the validity of the bid.

 The tenderers shall pay the EMD online instead paying the EMD at
any of the CFC centres in MCGM Ward Offices.

 Any bid not accompanied by an acceptable Bid Security and not

secured as indicated in sub-clause mentioned above, shall be rejected
by the Employer as non-responsive.

 The Bid Security of the successful Bidder will be discharged when the
Bidder has signed the Agreement and furnished the required Security
Deposits.

 The Bid Security/ EMD of L-3 and bidder shall be refunded

immediately after opening of financial bid but, the EMD/ASD
submitted by the L-2 bidder will be returned after obtaining Standing
Committee Resolution.

 The Bid Security may be forfeited:

a) If the Bidder withdraws the Bid after bid opening (opening of

technical qualification part of the bid during the period of Bid
validity;
b) In the case of a successful Bidder, if the Bidder fails within the
specified time limit to:
36
 i. sign the Agreement; and/or
ii. Furnish the required Security Deposits.

1. The cases wherein if the shortfalls are not complied by a

contractor, will be informed to Registration and Monitoring Cell.
Such non-submission of documents will be considered as
‘Intentional Avoidance’ and if three or more cases in 12 months
are re-ported, shall be viewed seriously and disciplinary action
against the defaulters such as banning/de-registration, etc.
shall be taken by the registration cell with due approval of the
concerned AMC.

2. No rejections and forfeiture shall be done in case of curable

defects. For non-curable defects the 10% of EMD shall be
forfeited and bid will be liable for rejection.
Note:
i) Curable Defect shall mean shortfalls in submission such
as:

a. Non-submission of following documents,

i. Valid Registration Certificate

ii. Valid Bank Solvency
iii. Sales Tax Registration Certificate (VAT)
iv. Certified Copies of PAN documents and photographs of
individuals, owners, etc
v. Partnership Deed and any other documents
vi. Undertakings as mentioned in the tender document.

b. Wrong calculation of Bid Capacity,

c. No proper submission of experience certificates and other

documents, etc.

ii) Non-curable Defect shall mean

a. In-adequate submission of EMD/ASD amount.
b. In-adequacy of technical and financial capacity with respect
to
Eligibility criteria as stipulated in the tender.

37
 BID VALIDITY

 Bids shall remain valid for a period of not less than one eighty (180)
days after the deadline date for bid submission specified in Bid Data
Sheet. A bid valid for a shorter period shall be rejected by the
Employer as non-responsive.

 In exceptional circumstances, prior to expiry of the original time limit,

the Employer may request that the bidders may extend the period of
validity for a specified additional period. The request and the bidders’
responses shall be made in writing or by cable. A bidder may refuse
the request without forfeiting his Bid Security. A bidder agreeing to
the re-quest will not be required or permitted to modify his bid, but
will be required to extend the validity of his bid security for a period of
the extension.

DEFECT LIABILITY PERIOD

 The Contractor is expected to carry out the construction work in

Workmen like manner so as to meet the requirement and specification
for the project. It is expected that the Workmanship and materials will
be reasonably fit for the purpose for which they are required.

 Defects or defective work is where standard and quality of

workmanship and materials as specified in the contract is deficient.
Defect is defined as a failure of the completed project to satisfy the
express or implied quality or quantity obligations of the construction
contract. Defective construction works are as the works which fail
short of complying with the express descriptions or requirements of
the contract, especially any drawings or specifications with any
implied terms and conditions as to its quality, workmanship,
durability, aesthetic, performance or design. Defects in construction
projects are attributable to various reasons.

 Some of the defects are structural defects results in cracks or collapse

of faulty defective plumbing, inadequate or faulty drainage system,
inadequate or faulty ventilation, cooling or heating systems,

38
 inadequate fire systems etc. The defects could be various on accounts
of different reasons for variety of the projects.

 The Engineering In charge/Project Officer shall issue the practical

completion certificate for the project. During the Defect Liability Period
which commences on completion of the work, the Engineering In
charge shall inform or the contractor is expected to be informed of any
defective works by the Employer’s representative of the defects and
make good at contractor’s cost with an intention of giving opportunity
to the contractor of making good the defects appeared during that
period. It is the contractor’s obligation under the contract to rectify
the defects that appear during Defect Liability Period and the
contractor shall within a reasonable time after receipt of such
instructions comply with the same at his own cost. The Engineering In
charge/Project Officer shall issue a certificate to that effect and
completion of making good defects shall be deemed for all the purpose
of this contract to have taken place on the day named in such defect
liability certificate.

 If defective work or workmanship or design have been knowingly

covered-up or conceived so as to constitute fraud, commencement of
the Defect Liability Period may be delayed. The decided period may be
delayed until discover actually occurs on at least the defect could
have been discovered with reasonable diligence, whichever is earlier.

 The General DLP shall be as below:

Sr. No. Description of work Defect Liability Period

1 General works 3 years
2 Structural works 5 years
3 Waterproofing works 5 years

 Also, in case of defect, the Engineer shall give notice to the Contractor
of any Defects before the end of the Defects Liability Period, which
begins at. The Defects Liability Period shall be extended for as long as
Defects remain to be corrected. Every time notice of Defect/Defects is

39
 given, the Contractor shall correct the notified Defect/Defects within
the duration of time specified by the Engineer’s notice. The Engineer
may issue notice to the Contractor to carry out removal of defects or
deficiencies, if any, noticed in his inspection, or brought to his notice.
The Contractor shall remove the defects and deficiencies within the
period specified in the notice and submit to the Engineer a compliance
report.

 It is the Completion Stage when the contractor has completed all of

the works and fixed all of the defects that were on the list of issue by
Engineer-in-charge. When this happens, the engineer must issue a
‘Certificate of Completion’. On the issue of ‘Certificate of Completion’,
the ‘Defect Liability Period ‘starts. The contractor also must issue a
‘Certificate statement’ as an acknowledgment to the engineer not later
than 14 days after the ‘Certificate of Completion’ has been issued.
During the ‘Defect Liability Period’, the contractor has to obey all
written instructions from the engineer to carryout repairs and fix any
defects which appear in the Permanent Works. If the contractor does
not ,due to his own faults finish the repair works or fix the defects by
the end of ‘Defect Liability Period’, the ‘Defect Liability Period’ will
continue until all works instructed by engineer is done.

40
 SECURITY DEPOSIT AND PERFOMANCE GUARANTEE

A. Security Deposit

The security deposit shall mean and comprise of

I) Contract Deposit and

II) Retention Money.

I) Contract Deposit – The successful tender, here after referred to as the

contractor shall pay an amount equal to two (2) percent of the contract
sum shall be paid within thirty days from the date of issue of letter of
acceptance.

II) Retention Money – The contractor shall pay the retention money an
amount equal to five (5) percent of the Contract Sum which will be
recovered from the contractors every bill i.e. interim / running / final bill.

B. Additional Security Deposit

The additional security deposit will be applicable when a rebate of more

than of 12 % at the rate of with no maximum limit. The ASD is calculated
as follows:
Additional security deposit = (X/100) x office estimated cost,
Where X=percentage rebate quoted above 12%
The ASD shall be paid online in the ASD tab for bidders in e-tendering
system before submission of the bid.

C. Performance Guarantee

The successful tender, here after referred to as the contractor shall pay in
the form of “Performance Guarantee” at different rates for different slabs
as stated below:

41
 Offer PG applicable %
For premium, at par and PG= 0.92% x contract sum applicable for
rebate 0 to 12% rebate of 12%
For rebate of 12.01% P.G. = {0.92% x contract sum applicable
for rebate of 12%} +(X) x contract sum
Where,
X= percentage rebate quoted more than
12%

Note: Contract sum shall mean amount after application of rebate/premium

as quoted by the contractor with contingencies only and excluding
price variation.

The PG shall be paid in one the following forms.

I) Cash (In case guarantee amount is less than Rs.10,000/-

II) Demand Draft (In case guarantee amount is less than

Rs.1,00,000/-)

III) Government securities

IV) Fixed Deposit Receipts (FDR) of a Schedule Bank.

V) An electronically issued irrevocable bank guarantee bond of

anySchedule bank or f in the prescribed form given in Annexure.

Performance Guarantee is applicable over and above the clause of

Security Deposit. Performance Guarantee will have to be paid & shall
be valid till the defect liability period or finalization of final bill
whichever is later.

This deposit will be allowed in the form of I to V as mentioned above

and shall be paid within 15 days after receipt of Letter of Acceptance.

Note: Following exceptions shall be adopted for ‘Demolition Tenders’:

• Irrespective of the offer (Rebate/ at par/ premium), ASD shall be

differed and only PG of 10% of contract sum be taken from the
successful bidder on award of contract only.

42
 • MCGM departments shall ensure to incorporate specific condition
regarding above in bid document and e-tender notice.

D. Refund of Security Deposit

I. Refund of Contract Deposit

The Contract Deposit shall be released within 30 days after

completion of 3rd year of DLP (in case of 5 years DLP) and after issue
of ‘Defect Liability Certificate’ (in case of 1 or 2 or 3 years DLP)
subject to no recoveries are pending against the said work, provided
that the Engineer is satisfied that there is no demand outstanding
against the Contractor. No claim shall be made against the Balance
Contract Deposit after the issue of Defects Liability Certificate.

II. Refund of Retention Money

One-half (50%)of the Retention Money shall be released within 30

days of issue of ‘Certificate of Completion’ with respect to the whole
of the Works. In the event the Engineer issues a Taking-over
Certificate for a section or part of the Permanent Works, only such
proposition thereof as the Engineer determines (having regard to the
relative value of such section or part of the Works) shall be
considered by the Engineer for payment to the Contractor.

The balance Retention Money shall be released within 30 days after

completion of 3rd year of DLP (in case of 5 years DLP) and after issue
of ‘Defect Liability Certificate’ (in case of 1 or 2 or 3 years DLP)
provided that the Engineer is satisfied that there is no demand
outstanding against the Contractor. In the event of different Defects
Liability Periods have been specified or become applicable to
different sections or parts of the Permanent Works, the said moneys
will be released within 30 days on expiration of the latest of such
Defects Liability Periods.
Payment of the above mentioned 50% is exclusive of the amounts to
be withheld as stated in and that amount shall be paid as per
condition stated therein.

43
III. Refund of Additional Security Deposit

The additional security deposit shall be released within 30 days of

issue of ‘Certificate of Completion’ with respect to the whole of the
Works. In the event the Engineer issues a Taking-over Certificate for
a section or part of the PermanentWorks, only such proposition
thereof as the Engineer determines (having regard to the relative
value of such section or part of the Works) shall be considered by the
Engineer for payment to the Contractor.

IV. Refund of Performance Guarantee

The Deposit on account of performance guarantee shall be released

within 30 days of completion of Defects Liability Certificate subject
finalization of final bill whichever is later and no recoveries are
pending against the said work, provided that the Engineer is
satisfied that there is no demand outstanding against the
Contractor.

 Summary of time of Refund of deposit is tabulated as follows:

a) Time of Refund for works having 5 years DLP

Deposits refunded after After Completion of

After 3 yrs of DLP DLP
completion

ASD + 50% of RM CD+50% of RM PG

b) Time of Refund for works having 1 or 2 or 3 years DLP

Deposits refunded after After Completion of DLP

completion
ASD + 50% of RM CD+50% of RM+PG

*Note:
a) It shall be clearly mentioned that the BG shall be applicable for
individual work/contract and clubbing of various contracts of the
said contractor will not be allowed. In case of obtaining Bank
Guarantee, it is necessary to mention that the same shall be valid
further 6 months from the completion of defect liability period/
warranty period.
44
 b) It shall be the responsibility of the bidder to keep the submitted
B.G. “VALID” for the stipulated time period in the tender & in
case of its expiry it will attract penalization.
c) Bank Guarantee should be issued by way of General Undertaking
and Guarantee issued on behalfof the Contractor by any of the
Nationalized or Scheduled banks or branches of foreign banks
operating under Reserve Bank of India regulations located in
Mumbai uptoVirar&Kalyan. List of approved Banks is appended
at the end of Instructions to Bidders (ITB). The Bank Guarantee
issued by branches of approved Banks beyond Kalyan and Virar
can be accepted only if the said Bank Guarantee is countersigned
by the Manager of a Regional Branch of the same bank within the
Mumbai City Limit categorically endorsing thereon that the said
Bank Guarantee is binding on the endorsing Branch of the Bank
or the Bank itself within Mumbai Limits and is liable to be
enforced against the said Branch of the Bank or the bank itself in
case of default by the Contractors furnishing the Bank
Guarantee. The Bank Guarantee shall be renewed as and when
required and/or directed from time to time until the Contractor
has executed and completed the works and remedied any defects
therein.

E. Legal + Stationary Charges: (As per applicable circular)

Successful tender shall pay the Legal Charges +Stationary charges as

per Circular no CA/FRG/26 dtd 23.12.2015.

Legal +Stationary
Contract Value
Charges
upto Rs. 3,00,000/- Rs. Rs. Nil
from Rs. 3,00,001/- To Rs. 20,00,000/- Rs. 680/-
from Rs. 20,00,001/- To Rs. 1,00,00,000/- Rs. 2670/-
from Rs. 1,00,00,001/- To Rs. Any amount Rs. 6660/-

The Bidders are requested to note that stationary charges as given in

the table above will be recovered from the successful tenderer for
45
 supply of requisite prescribed forms for preparing certificate bills in
respect of the work.

F. Stamp Duty: (As per applicable circular)

It shall be incumbent on the successful tenderer to pay stamp duty on

the contract.

(i) As per the provision made in Article 63, Schedule I of Bombay

Stamp Act 1958, stamp duty is payable for “works contract” that is
to say, a contract for works and labour or services involving transfer
of property in goods (whether as goods or in some other form) in its
execution and includes a sub-contract, as under :
Where the amount or
value set forth in such
(a) Five Hundred rupees stamp duty
contract does not exceed
rupees ten lakh.
Five hundred rupees plus 0.1% of
Where it exceeds rupees amount above rupees subject to the
(b)
ten lakhs maximum of rupees twenty five lakh
stamp duty.

ii. The successful bidder shall enter into a contract agreement with
M.C.G.M. within 30 days from the date of issue of Work Order and
the same should be adjudicated for payment of Stamp Duty by the
successful bidder.

iii. Further shortfall if any, in amount of stamp duty paid as against

prescribed amount for the documents executed in Mumbai City &
Mumbai Suburban District be recovered from the concerned work
contractors and to deposit the deficit or unpaid Stamp Duty and
penalty by two separate Demand Draft or Pay Order in favour of
“Superintendent of Stamp, Mumbai” within 15 days from intimation
thereof.

iv. All legal charges and incidental expenses in this respect shall be
borne and paid by the successful tenderer.

46
 IMPORTANT DIRECTIONS

1. All the information uploaded shall be supported by the corroborative

documents in absence of which the information uploaded will be
considered as baseless and not accepted for qualification criteria. All the
documents shall be uploaded with proper pagination. The page No. shall
be properly mentioned in the relevant places.

The information shall be uploaded in the sequence as asked for with

proper indexing etc. The Bidder shall be fully responsible for the
correctness of the information uploaded by him.

2. Applicants/Bidders shall refer portal.mcgm.gov.in\tenders for “The

Manual of Bid-Submission for Percentage Rate/Item Rate Tender
Document.” The detail guidelines for creation and submission of bid are
available in the referred document.

Any queries or request for additional information concerning this

TENDER shall be submitted by e-mail to [email protected] subject
shall clearly bear the following identification/ title: “Civil & Structural
Repairs to KMJ Phule Hospital, Kannamwarnagar, Vikhroli(East) in S ward.”
Any changes in mail ID will be intimated on the portal.

3. In case of Equal Percentage of lowest bidders (L1), the allotment of work

shall be done by giving 48 hrs(2 working days) from the day of opening
of packet C on same BID-Document number for re-quoting and such
development needs to done by IT department in MCGM’s SRM system.
Till such development is made; ‘Sealed Bids’ shall be called from the
bidders quoting the same rates i.e. L1.

In case of equal percentage of lowest bidders is obtained even after re-

quoting, then the successful bidder will be decided by lottery system by
concerned Ch.Engr.

47
The bidder shall need to submit the additional ASD if applicable within 7
days after receipt of notification issued by concerned Chief Engineer.

Also, the Performance Guarantee shall be paid in 15 days after receipt of

Letter of Acceptance.

48
 SECTION 7

SCOPE OF WORK

49
Name of work- “Civil & Structural Repairs to KMJ Phule Hospital,
Kannamwarnagar, Vikhroli(East) in S ward.

Civil Work:-

1. Waterproofing of terrace & toilet blocks.

2. Structural repairs such as Column jacketing & Polymer
treatment to slab & beam.
3. Internal/External plastering wherever damaged.
4. Repairs to toilet blocks.
5. False ceiling to CMO room & ICU entry (ground floor).
6. Internal/External painting.
7. Plumbing work.

Electrical Work:-

The electrical estimate is prepared in which removing & refixing of existing

panels, switchgears, pumps, CCTV cameras, Solar Water Heating system,
some part of cabling work is considered. In Medical Gas System, dismantling
of existing system and SITC of new system is considered. The existing panels
in Medical gas room is in working condition so it is not taken in the scope of
work. ICU , Operation theatres , extension bldg. (Laboratary) and few rooms
which are good in condition is not considered for rewiring work. As HVAC
system is under CSMC, it is not considered in this work. Removing and
refixing of HVAC system and window / split A/Cs are to be carried out in
OTs and concerned rooms.

50
 SECTION 8

BILL OF QUANTITIES

51
CIVIL WORKS

52
 Civil &Structural repairs to KMJP hospital, Vikhroli(East) in S ward
BOQ
Sr. Item Description Unit Rate Amount
No. Quantity
Dismantling/Demolition work
1 CS-DD-2 Demolishing R.C.C. work manually/ by mechanical 17.00 Cum 1216 20672
means including
stacking of steel bars and disposal of unserviceable
material within
50 metres lead as per direction of Engineer - in-
charge.

2 CS-DD-65 Removing cement plaster of any finish from the wall, 4690.25 Sqm 87 408051.75
complete with
racking out the joints to a depth of 20 mm.

3 CS-DD-3 Demolishing brick work in lime or cement mortar 114 Cum 309 35226
including plaster, paint, etc. manually/ by mechanical
means including stacking of serviceable material and
disposal of unserviceable material within 50 metres
lead as
per direction of Engineer-in-charge.

4 CS-DD-70 Removing and refixing existing door or window with 65.00 Nos 1457 94705
frames and shutters, making good the damaged
brick work and applying 3 coats of Syn. Ena. paint.

5 CS-DD-71 Removing existing door or windows with frame and 28.00 Nos 362 10136
shutters and making good etc. to the existing surface.

6 CS-DD-64 Removing mosaic, cement marble, granites non- 852.00 Sqm 142 120984
slippery, tandur, kotah, shahabad stone or Indian
Pattern stone, glazed tiles in flooring and dado
including bedding brick bat coba etc., and
delivering materials in Ward Office and carting away
unserviceable materials.

Water proofing work

7 CS-WP- Providing waterproofing treatment as per Item 2106.00 Sqm 1149 2419794
32-b No.CS-WP-32-a with
Broken China mosaic flooring as per design

53
8 CS-WP-39 Providing the waterproofing treatment as per item 44.00 Sqm 1106 48664
no.CS-WP-38 but to the flooring of existing water
closets, bathrooms, kitchen, nahanies, washing places,
sanitary blocks etc. after removing existing flooring
and brickbat coba etc. (The soil pan area will not be
deducted. After completion of work leakage test shall
be carried out after impounding the water for 7 days
without any extra cost. The actual area treated
including soil pan area will be measured and paid
for).

9 CS-WP- Providing waterproofing treatment through 307.00 Sqm 615 188805

38-a specialized agencies to the dado portion of the R.C.C.
side walls upto 1.5 m height from floor area of water
closets, bath-rooms, kitchens, washing places,
sanitaryblocks etc. by giving „INJECTIONS‟ treatment
with waterproofing compound and cement solution.
The walls will then be plastered with waterproof
cement plaster in 1:4 c.s. 12 mm to 15 mm thk. Finally
the walls shall be covered with jointless waterproof
plaster in 1:3 c.s. 12to 15 mm thick finished rough for
receiving tiles. The average thickness of complete
treatment shall not be less than 25 mm. (The actual
treated area will be measured and paid for).
10 CS-WP-44 Water proofing treatment to the chajja after removing 162.00 Sq.m 280 45360
old plaster and roughening the surface and finishing
the top surface with 20mm thk. 1:2 c.s. plaster with
approved water proofing compounds and neat
cement finish, the rate also includes for 1:3 c.s. facia
of chajja to
match the new surface(actual area treated will be
paid).

54
11 CS-WP-30 Providing water proofing treatment to New terrace 33.00 Sqm 737 24321
after cleaning the
surface by giving „INJECTIONS‟ to the terrace slab
wherever
required with necessary water proofing compound
and cement
solution as per specifications so as to fill up all the
inherent holes
cavities, voids, honeycomb etc. making the whole
structure
consistent and homogeneous resistant to water
leakage seepage,
dampness and moisture etc. Brickbat waterproofing
coba in 1:5 C.S.
mortar as per specifications shall be laid over
R.C.C.Slab with
necessary gradient for easy flow of rain water. This
treatment shall
continue along the inner side of parapet of other
adjoining wall upto
height of about 30cm. in the shape of round vata.
Finally the top
surface shall be covered with joint less waterproofing
plaster 1: 4 C.S.
12 mm to 15 mm in thickness as per specifications of
specialized
waterproofing Co. finished smooth with trowel in
cement colour
marked in 30 cm x 30 cm false squares. The average
thickness of
complete treatment shall be 100 mm. The surface
shall be rendered
hard and tough to withstand the weather, normal
domestic use. The
rate is inclusive of the cost of watering, tamping,
curing and cleaning
the top of all dust, loose materials, stains etc.
complete as directed.
Debris shall become contractor’s property. The
finished terrace
surface shall be ponded for a period of 10 days to test
for any
leakage without any extra cost. Clear horizontal
measurement
between walls will be paid for actual area treated
including vata.
12 CS-WP- Extra for providing additional thickness of 106.00 Cum 5260 557560
31 brickbats over 100 mm in1:5 c.s. either due to
location of rain water pipes or due to increase
inthe travel length of flow of rain water or brick
bats required in thesunk portion of baths, W.C.s
nahani etc. The rate includes for fixingbrickbats in
C.M., with waterproofing compound as per
specificationas directed

55
 Tiling/Flooring works
13 CS-FL-07- Providing and laying 8mm thk. ceramic tiles as 88.00 Sqm 1472 129536
d specified below conforming to I.S.15622-2006 for
flooring of an approved, quality, make, size and
pattern /design, for flooring including cement mortar
bedding of 25 mm thick in 1:4 proportion, neat
cement float, cutting, leveling, jointing, filling the
joints by neat cement slurry or approved colour grout,
curing, finishing etc complete as directed by
Engineer In Charge.Dark coloured antiskid / matt
ceramic tiles

14 CS-FL-32- Providing and fixing 8mm thk. ceramic tiles as 703.00 Sqm 1396 981388
a specified below conforming to I.S. 15622-2006 of
approved quality, pattern and colour for dado in the
wet area including preparing the surface and levelling
in the desired line, backing of 20 thk. cement mortar
in porportion 1:3 with approved waterproofing
compound, square cut top edge or chamfered top
edge in cement mortar 1:3, cement float, machine
cutting, leveling, jointing, filling the joints with neat
cement slurry or approved colour grout, finishing,
curing etc complete as directed by Engineer InCharge.
Light coloured glazed ceramic tiles

15 CS-FL-8-c Providing and laying 600 x 600 x 8 mm thk. vitrified 61.00 Sqm 1573 95953
tiles as specified below conforming to I.S.156222006
with water absorbtion less than 0.08% for flooring of
an approved, quality, make and pattern /design for
flooring including cement mortar bedding of 25 mm
thick in 1:4 proportion, cutting, leveling, jointing,
filling the joints by neat cement slurry or approved
colour grout, curing, finishing etc complete as directed
by Engineer In ChargeLight coloured antiskid / matt
vitrified tiles

16 CS-FL-47- Providing and fixing the both face polished natural 7.00 Sqm 1029 7203
a stone as specified below for shelf including making the
slots for support, cutting, jointing in approved
adhesives or any other approved means, filling the
joints with neat cement motar with neat smooth
plastering as required etc. complete as directed by
Engineer-In-Charge. 25 to 30mm thk. Kadappa

56
17 CS-FL-40- Providing and fixing polished natural stone tiles as 173.00 Rm 447 77331
p specified below of approved quality, pattern and
colour for sill and jambs including preparing the
surface and levelling in the desired line, cement
mortar 1:3 bedding or backing, cement float, machine
cutting, leveling, jointing, smooth cement plastering
along the sides to match the existing surface in
cement mortar 1:3, filling the joints with neat cement
or pigment mixed with cement, finishing, curing etc
complete as directed by Engineer In Charge.18mm
thk. green marble for width upto 300 mm

18 CS-FL-43- Providing and fixing all sides polished natural stone 7.00 Sqm 1028 7196
b tiles as specified below of approved quality, pattern,
colour and thickness for partition including making
the groove in existing cladding/ plaster/ concrete/
masonry, machine cutting, leveling, smooth cement
plastering along the sides to match the existing
surface in cement mortar, filling the joints with neat
cement or pigment mixed with cement, cutting for
utility pipe in the shape as directed, cleaning,
finishing, curing etc complete as directed by
Engineer In Charge
25 to 30mm thk. Kadappa stone

19 CS-FL- Bare Polishing (non mirror) on marble work/ 699.00 Sq.m 27 18873
54 granitework/ stone work to give gloss finish
includinglevelling the surface neat, cleaning etc.
complete asdirected by Engineer In Charge

20 CS-FL-38- Providing and fixing polished natural stone slab as 40.00 Rm 554 22160
d specified below of approved quality, pattern and
colour for treads including preparing the surface and
levelling in the desired line, in cement mortar 1:4,
cement float, machine cutting, leveling, jointing,
smooth cement plastering along the sides to match
the existing surface in cement mortar 1:3, filling the
joints with neat cement or pigment mixed with
cement, polishing, finishing, curing etc complete as
directed by Engineer In Charge.Kota stone for width
upto 300 mm

57
21 CS-FL-21- Providing and fixing polished natural stone tiles /slab 40.00 Rm 198 7920
d as specified below of approved quality, pattern and
colour for flush/projected skirting and risers including
preparing the surface and levelling in the desired line,
backing of 20 thk. cement mortar in porportion 1:3,
square cut top edge or chamfered top edge in
cement mortar 1:3, cement float, machine cutting,
leveling, jointing, filling the joints with neat cement or
pigment mixed with cement, polishing, finishing,
curing etc complete as directed by Engineer In
Charge.15 to 20mm thk. Kota stone for height upto
150 mm

22 CE-PD-FA- Providing and fixing vitrified tiles of 600 x 600, min 57.00 Sqm 1221 69597
198 8mm thk in dado of approved make and quality of any
color and shade with CM backing (1:4) upto 20 mm
thk and with neat cement paste and filling t
he joints by white cement grout with matching colour
pi

23 CS-FL-01- Providing and laying polished natural stone 20.00 Sqm 1069 21380
c asspecified below (Machine cut) of an approved
qualityand size for paving /flooring in plain and/or
diamond/approved pattern including cement mortar
beddingof 25 mm thick in 1:4 proportion, cement
float,machine cutting, dressing, leveling, jointing,
filling thejoints with neat cement slurry or with
requiredpigment, machine polishing at site, curing,
finishing,etc complete as directed by Engineer In
Charge.25 to 30 mm thk. Kota stone of size 0.430m
x0.56m(17"x22")

Plastering works
24 CS-PL- Providing and applying 12 mm thick internal 876.00 Sqm 298 261048
05 plaster in cement mortar 1:3 with neeru finish
at all heights and locations in one coat for
masonry (except stone masonry) and
concrete surfaces including racking out joints,
hacking of concrete surface, watering,
finishing, curing, scaffolding etc. complete.

58
25 CS-PL- Providing and applying 20 mm thick internal 830.00 Sqm 430 356900
09-c plaster with neeru finish at all heights and
locations in cement mortar specified below in
two coats for masonry (except stone
masonry) and concrete surfaces including
racking out joints, hacking of concrete
surface, watering, finishing, curing,
scaffolding etc complete as directed By
Engineer In Charge.In cement mortar 1:4

26 CS-PL- Providing and applying 20 mm thick external 2985.00 Sqm 440 1313400
16-c sand faced cement plaster with neat cement
rendering upto 10m from ground level and at
all locations in cement mortar proportion
specified below in two coats for masonry
(except stone masonry) and concrete
surfaces including providing water proofing
compound to the first coat of plaster as per
manufacturers specification, racking out
joints, hacking of concrete surface, finishing,
curing, scaffolding etc complete as directed
By Engineer In Charge.
Min. time lag between two coats shall be 24
hours.(as per IS 2402 of 1963.) in cement
mortar 1:3

27 CS-PL-25 Extra for every additional height of 3 m or part thereof 324.00 Sqm 39 12636
above 10m from ground level for all types of external
plastering
Concrete works
28 CS-CW-54 Chipping /removing loose concrete upto 175.00 Sq.m 150 26250
reinforcement bars, without damaging the
reinforcement, removing all the loose materials and to
make all the exposed surfaces free from oil, dust and
all impurities etc complete.
29 CS-CW-55 Removing corrosion of steel reinforcement by 175.00 Sq.m 460 80500
mechanical means like wire brushing, chipping to
remove loose rust and then applying rust removal
solution by using brush application, leaving the
surface for at
least 15 to 30 minutes, then removing loose materials
by scrubbing or with brush and applying polymer bond
to the old concrete surface before applying Polymer
mortar.

59
30 CS-CW-56 Providing and applying Polymer modified cement 100.00 Sq.m 1955 195500
mortar of average
thickness 15mm using Polymer in one or more layers
in proportion
1:5:15 of Polymer Cement Quartz Sand as
manufacturer’s
specifications in specific layers, curing the surface
after 72 hours of
application with wet gunny bags etc and by finishing
the surface with
12mm thick (1:3) Cement sand plaster.

31 CS-CW-57 Providing and applying Polymer modified cement 75.00 Sq.m 3841 288075
mortar of average thickness 30mm using Polymer in
two layers in proportion 1:5:15 of Polymer Cement
Quartz Sand as manufacturer’s specifications in
specific layers, curing the surfaaace after 72 hours of
application with
wet gunny bags etc and by finishing the surface with
12mm thick (1:3) Cement sand plaster.

32 CS-CW- Jacketting the existing column of size as shown 136 Cum 12330 1676880
44 in the drawing by removing the concrete
cover to reinforcement, by chipping or other
suitable means to expose the reinforcement
of existing column in order to make available
the same for binding the extra reinforcement
as shown in the drawing and also removal of
rust, scales of the reinforcement in order to
provide and apply approved make of epoxy
resin to get proper bond with newly laid M25
grade concrete. The aforesaid concrete shall
be laid by the sides of the existing column
with uniform thickness of 115 mm or as
specified, for jacketing purposes thereby
increasing the sectional dimensions by 150 mm
or as specified (excluding finishing) at any
height with requisite shuttering, centring,
scaffolding, proping, repairing the existing
surface as specified and also removal of
debris, curing etc. complete as per design
and drawing etc. directed. (NOTE :-
Reinforcement will be paid separately under
respective item of schedule ).

60
33 CS-CW- Providing and fixing in position steel bars 14.65 MT 67988 996024.2
35-b reinforcement of various diameters for R.C.C. pile, pile
caps, footings,raft,retaining wall,shear wall, lift wall,
foundations, slabs, beams, columns, canopies,
staircases, newels, chajjas, lintels, pardies, coping,
fins, arches, etc. as per detailed designs, drawings and
bar bending schedules,including straightening, cutting,
bending, hooking the bars, binding with wires or tack
welding, supporting as required etc. all complete at all
levels. HYSD steel bars (Fe 415)

34 CS-CW- Sealing the expansion joints by polysulphide sealant so 229.00 Rm 1405 321745
49-b as to make the joint completely water tight complete
as directed.size 35 mm x 25 mm

35 CS-CW-1- Providing and laying in position plain cement concrete 38.00 Cum 5527 210026
a of specified
grade with trap/granite/quartzite/gneiss metal mixing
in concrete mixer
including bailing out water, compacting, finishing
surface, curing and
including the cost of centering and shuttering at all lev
Nominal Mix of 1:1.5:3 (1 cement : 1.5 coarse sand : 3
graded stone
aggregate 20 mm nominal size)

Plumbing & Sanitation works

36 CS-PS-2-a Providing and fixing white vitreous china pedestal type 12.00 Nos 3455 41460
water closet (European type W.C. pan) with seat and
lid, 10 litre low level white P.V.C. flushing cistern,
including flush pipe, with manually controlled device
(handle lever), conforming to IS : 7231, with all fittings
and fixtures complete including cutting and making
good the walls and floors wherever required :W.C. pan
with ISI marked white solid plastic seat and lid

37 CS-PS- Providing and fixing water closet squatting 8.00 Nos 3495 27960
1-a pan (Indian type W.C. pan ) with 100mm sand
cast Iron P or S trap, 10 litre low level white
P.V.C. flushing cistern, including flush pipe,
with manually controlled device (handle lever)
conforming to IS : 7231, with all fittings and
fixtures complete including cutting and
making good the walls and floors wherever
required :White Vitreous china Orissa pattern
W.C. pan of size 580x440mm with integral
type foot rests.

61
38 CS-PS- Providing and fixing wash basin with C.I. 10.00 Nos 2161 21610
7-a brackets, 15 mm C.P. brass pillar taps,32 mm
C.P. brass waste of standard pattern,
including painting of fittings and brackets,
cutting and making good the walls wherever
require : White Vitreous China Wash basin
size 630x450 mm with a pair of 15 mm
C.P. brass pillar taps.

39 CS-PS-88- Providing and fixing G.I. pipes complete with G.I. 134.00 Rm 193 25862
a fittings and clamps,i/c cutting and making good the
walls etc.Internal work - Exposed on wall 15 mm dia
nominal bore
40 CS-PS-88- Providing and fixing G.I. pipes complete with G.I. 50.00 Rm 223 11150
b fittings and clamps,i/c cutting and making good the
walls etc.Internal work - Exposed on wall 20 mm dia
nominal bore
41 CS-RW- Providing and fixing UV resistant selffit UPVC pipes of 198.00 Rm 179 35442
16-a approved make for Rainwater downtakes confirming
to IS 13592:1992 Type A suitable for 4kg/sqcm
pressure for following pipe diameters including rain
water
receiving recess with pvc plug bend necessary fittings
such as offsets shoes, fixing the pipes on wall with
clips filling the joints with solvent/cement and
necessary scafolding etc. complete as directed by
Engineer In Charge.75 mm dia pipe

42 CS-PS-191 Providing and fixing in position uPVC/SWR pipe 75 mm 56.00 Rm 330 18480
dia. in any position
including all fittings and accessories, making joints /
connections water tight
with solvent cement, scaffolding if necessary and
making good the damages
if any (excluding excavation and refilling the trenches)
etc. complete as
specified and directed.(No seperate payment shall be
made for fittings and
accessories).

43 CS-PS-192 Providing and fixing in position uPVC/SWR pipe 110 104.00 Rm 400 41600
mm dia. in any position including all fittings and
accessories, making joints / connections water
tightwith solvent cement, scaffolding if necessary and
making good the damages
if any (excluding excavation and refilling the trenches)
etc. complete as specified and directed.(No seperate
payment shall be made for fittings and
accessories).

62
44 CS-PS-7-i Providing and fixing wash basin with C.I. brackets, 15 3.00 Nos 2864 8592
mm C.P. brass pillar
taps,32 mm C.P. brass waste of standard pattern,
including painting of
fittings and brackets, cutting and making good the
walls wherever require :
White Vitreous China Surgeon type wash basin of size
660x460 mm with
single 15 mm C.P. brass pillar taps with elbow
operated levers ISI marked.

45 CS-PS- Providing and fixing trap of self cleansing design 25.00 Nos 849 21225
59-a-2 with screwed down or
hinged grating with or without vent arm complete,
including cost of cutting
and making good the walls and floors.Sand Cast
Iron S&S as per IS: 1729

FRP & PVC items

46 CS-PV-01 Providing and fixing Fiber Glass Reinforced plastic 226.00 Rm 492 111192
(FRP) Door Frames of cross-section 90mm x 45mm
having rebates of 32mm x 15mm size to receive
shutter of 30mm thickness. The laminate shall be
moulded withfire resistant grade unsaturated
polyester resin and chopped mat. Door frame
laminate shall be 2mm thick and shall be filled with
suitable wooden block in the frame. The frame shall
be covered with fiberglass from all sides. M.S. stay
shall be provided at the bottom to steady theframe
etc. complete as directed.

47 CS-PV-02 Providing and fixing to frames 30 mm thick Fibre Glass 87.00 Sq.m 2251 195837
Reinforced Plastic (FRP) panelled / extruded profiled
door shutter of approved colour, brand and
manufacture, made with fire - retardant grade
unsaturated polyester resin, moulded to 3 mm thick
FRP laminate for
forming hollow rails and styles, with wooden frame
and suitable blocks of seasoned wood inside at
required places for fixing of fittings, cast monolithically
with 5mm thick FRP laminate for panels conforming to
IS:
14856 - 2000 etc complete as directed.

Painting work

63
48 CS-PN- Providing and applying first single coat of 4410.00 Sq.m 77 339570
2 approved primer and two coats of dry distemper
paint (water bound distemper) of an approved
make and colour as per manufacturers
specifications to
any surface, at all height and locations as directed
including scaffolding, cleaning and preparing
surfaces for painting with
broom, coir and sand paper if necessary or by any
other
approved means, etc. complete as directed by
Engineer-

49 CS-PN-10 Providing and applying first coat of approved cement 3979.00 Sq.m 194 771926
paint and two coats of textured exterior paint of an
approved make and colour as per manufacturers
specifications to textured sand faced or other
surfaces, upto 10m height from ground level and at all
locations as directed including preparing surfaces for
painting by any approved means, watering,
scaffolding, cleaning and curing
etc. complete as directed by Engineer-in-charge.

50 CS-PN- Providing and applying first single coat of 4655.00 Sq.m 94 437570
3 approved primer andtwo coats of acrylic
distemper (oil bound distemper) of anapproved
make and colour as per manufacturers
specifications toany surface, at all height and
locations as directed includingscaffolding,
cleaning and preparing surfaces for painting
withbroom by any approved means, etc. complete
as directed byEngineer-in-charge.

51 CS-PN-15 Extra over item no. CS-PL-7 to CS-PL-12 on exterior 324.00 Sq.m 16 5184
painting
work of height more than 10 m from ground level for
additional
height of 3m or part thereof.

52 CS-PN-4-b Providing and applying first single coat of approved 554.00 Sq.m 130 72020
primer and two coats of synthetic enamel paint/flat oil
paint of an approved make and colour as per
manufacturers specifications to surfaces specifird
below, at all height and locations as directed including
scaffolding, cleaning and preparing surfaces for
painting by any
approved means etc. complete as directed by
Engineer-incharge For woodwork

64
53 CS-PN-4-c Providing and applying first single coat of approved 68.00 Sq.m 132 8976
primer and two coats of synthetic enamel paint/flat oil
paint of an approved make and colour as per
manufacturers specifications to surfaces specifird
below, at all height and locations as directed including
scaffolding, cleaning and preparing surfaces for
painting by any
approved means etc. complete as directed by
Engineer-incharge For steel work

Masonary work
54 FMB-4.12 Brick Masonry, first sort in cement mortar 1:4 in 60.00 Cum 3512 210720
superstructure, piers, steps and plinth complete as
directed and specified.
Aluminium & Wood work (Door windows)
55 CS-AW-02 Providing and fixing in position three track aluminum 11.00 Sq.m 4266 46926
window of extruded modular and anodized aluminum
sections of approved make and of size 92 mm x 45.5
mm x 1.5 mm thk (wt 1.659 kg/Rm) for bottom and 92
mm x 31.75 mm x 1.3 mm thk. (wt 0.933 kg/Rm) for
top and sides mounted on anodized aluminum
rectangular frame of size 100mm x 40mm x
1.3mm.(Wt 0.976 kg/m) The shutter comprising of
bearing bottom and top of size 40mm x 18 mm x 1.25
mm thk (wt. 0.417 Kg/Rm) Interlocking section of size
40mm x 26.7 mm x 1.10 mm thk. (Wt. 0.469 kg./Rm)
and hand sides of 40mm x 18mm x 1.25 mm thk (wt.
0.417kg/Rm) with 5 mm thick plain / frosted / tinted
glass fixed in shutter including approved quality
neoprene gasket, fixtures, fastenings and accessories
like PVC rollers, PVC weep holes, locks, handles etc.
complete as directed by Engineer In Charge. (Note:
anodic film must not be less than 15 microns i.e. AC-
15 as per IS, the anodizing must be scaleted by
keeping the anodized section in boiling deanodized
water for a period of one hour)

65
56 CS-AW-06 Providing and fixing in position side hung window with 49.00 Sq.m 5865 287385
friction hinges, made up of extruded modular and
anodised aluminum section of approved make and of
size 38.10 mm x 25.40 mm x 1.44 mm thk (wt. 0.471
kg/Rm) for outer rectangular tube, 40 mm x 31.5 mm x
1.5 mm (wt. 0.549 kg/Rm) for outer frame, 40 mm x
31.50 mm x 1.50 mm thk (wt. 0.502 kg/Rm) for central
mullion, 40 mm x 31.50 mm x 1.50 mm thk (wt. 0.549
kg/Rm) for shutter frame and 16.50 mm x 14.50 mm x
1.20 mm thk (wt. 0.157 kg/Rm) for glazing clip with 5
mm thick plain / frosted / tinted glass including
neoprene gasket, fixtures, fastenings and accessories
like handles, hinges, locking arrangement etc.
complete as directedby Engineer In Charge. (Note:
anodic film must not be less than 15 microns i.e. AC-
15 as per IS, the anodizing must be scaleted by
keeping the anodized section in boiling deanodized
water for a period of one hour)

57 CS-WW- Providing and fixing superior quality single leaf 10.00 Sq.m 3041 30410
06-d B.W.P. grade solid core flush door shutters of
standard make conforming to IS:22021991 (Part I
& II) including one coat of primer, putty and 2
coats of synthetic enamel paint on both faces etc.
with 12 mm thk teak wood
lipping all around all around etc. complete
(Hinges, aldrop & standard door hardware to be
paid separately)40mm thick shutter

58 CS-HW- Providing and fixing aldrops of 16 mm diameter 5.00 Nos 176 880
06-a-2 bars manufactured asper IS:2681-1991, wherever
they apply for doors and windows withnecessary
materials and labour etc. complete.A] Iron
oxidized / bright finished 300 mm long.

66
59 CS-WW- Providing & Fixing False Ceiling comprising of 28.00 Sq.m 2101 58828
21-a following material including fixing in galvanized steel
sections with white color coated cap comprised of
main tee 34 mm x 24 mm (heavy duty as per ASTMC -
635 standard tested) with pre-punched cross tee slots
(at every 100 mm c/c) to be placed at 1200 mm c/c,
suspended with 4 mm GI (TATA MAKE) straightened
wire at every 1.2 mtr, other end of the wire provided
with GI J hook & nut. All the false ceiling panels
around the perimeter of the false ceiling & around the
RCC columns shall rest on the perimeter G.I. molding
of size 19 mm x 19 mm which is fixed to the walls with
help of rawal plug & GI screw at the same level as
false ceiling. The cross tee of 1200 mm length (26 mm
x 24 mm wide Heavy duty) shall be locked in main tee
at every 600 mm c/c. to form grid of 600 x 1200 mm.
Further 600 mm long tee need to be locked in to 1200
mm tee to make the final grid of 600 mm X 600 mm,
including making provision for cutouts and / or trap
door for electrical and mechanical systems, etc
complete as directed by Engineer In charge.
With Armstrong Orcal Lay in metal ceiling System
consisting of 600x600mm Lay in tiles of pre coated
galvanised steel in 0.5/0.4 mm thickness in white
colour with standard perforation of 2.5mm dia & open
area of 16%. The back of the tile should have black
acoustical fleece with NRC of 0.70 & CAC 36 with life
time warrantee against sag in module size 595 mm X
595 mm at required height above FFLFalse ceiling
60 CS-AW- Providing and fixing anodized (anodic film must not be 7.00 Sqm 1148 8036
15-k less than 15 microns
i.e. AC-15 as per IS, the anodising must be scaleted by
keeping the
anodized section in boiling de-anodized water for a
period of one hour)
aluminum fixed/ sliding / pivoted / top hung / side
hung / louvered type
windows, doors, ventilators and partitions conforming
to IS:1948, 1961 with
6 mm. thick Acrylic sheet

67
61 CS-AW- Providing and fixing anodized (anodic film must not be 21.00 Kg 379 7959
15-a less than 15 microns
i.e. AC-15 as per IS, the anodising must be scaleted by
keeping the
anodized section in boiling de-anodized water for a
period of one hour)
aluminum fixed/ sliding / pivoted / top hung / side
hung / louvered type
windows, doors, ventilators and partitions conforming
to IS:1948, 1961 with
Aluminum section used

62 CS-HW- Providing and fixing tower bolts as described 5.00 Nos 77 385
08-a-5 below conforming to IS:2041992(Part I,II) for
doors & windows with necessary materials and
labouretc. complete 300 mm long.

63 CS-HW- Providing and fixing butt hinges as described 15.00 Nos 44 660
04-a-4 below, manufactured as per
relevant IS for door & windows with necessary
materials and labour costs
etc. complete.iron oxide 150 mm Long

64 CS-HW- Providing and fixing handles as described below, 10.00 Nos 38 380
09-a-5 manufactured as per IS:208-1992 for doors and
windows and with necessary materials and
fixtures like screws etc. and all labour etc.
complete.200 mm long.

Steel work
65 CS-SL-12- Providing and Fixing MS Safety grill of weight 54.00 Sq.m 1995 107730
b specified below for windows as per design including
fabricating the grill using M.S. square / round bar, flats
and angles including painting with one coat of red
oxide zinc chromate primer and two coats of synthetic
enamel paint of approved colour and brand etc
complete as directed.Grill weighing 15 to 20 kg / sqm

68
66 CS-SL-04 Providing and fixing in position collapsible steel gates 12.00 Sq.m 5655 67860
with vertical channels 20 x 10 x 2 mm & braced with
flat iron diagonals 20 x 5 mm size, top & bottom T
section 40 x 40 x 6 mm size, 30 mm steel pulleys
complete with bolts-nuts, locking arrangements,
stoppers, handles and painting with one coat of red
oxide zinc chromate primer and two coats of synthetic
enamel paint including all labour, materials, tools and
equipments, etc complete as directed by Engineer
Incharge

Miscellaneous
67 FMA-696 Removing carefully existing W.I./M.S. grill of any sizes, 254.00 Sqm 11 2794
design and at any level including scaffolding from
corridor, passage, staircase room,
windows, ventilators etc., making surface good with
ceme
nt mortar and handing over the same to ward store
etc., complete as
directed

68 FMA-697 Refixing the existing grill - do - - do - and painting 2 254.00 Sqm 70 17780
coats of synthetic enamel paints and one coat of
primer paint with new fixtures
etc., complete as directed and specified.
69 CS-PS-30 Providing and fixing 600x450 mm beveled edge mirror 10.00 EA 785 7850
of superior glass (ofapproved quality) complete with 6
mm thick hard board ground fixed towooden cleats
with C.P. brass screws and washers complete.

70 FMA-808 Providing and fixing teak wood in square scantlings 50 0.50 Cum 61072 30536
mm and above in
size for doors, window frames or any other work
complete as specified
and directed

69
71 RW-3-15 Providing & Fixing 80 mm thick unishape gray cement 25.00 Sq.m 1083 27075
concrete
interlocking pavers (monolithic-single layer precast
concrete blocks)
in Red ( Terra Cotta), Black, Brownor any colour
withpigment @ 3% by
weight of cement having average crushing strength of
50N/SQMm. in the
carriageway placed on average compacted thickness
of 25 mm. uniformly
graded river sand cushioning with proper compacting
with mec
hanical compactor with the proper level, grade and
camber etc. complete
as specified and as directed by the Engineer.

72 CS-PS-197 P/F R.C.C. cover on inspection chamber of size 90 cm x 10.00 Nos 600 6000
45 cm. and 50 mm.thick, etc., directed

73 CS-RM-95 Providing & fixing factory made Fibreglass Reinforced 30.00 Sqm 4557 136710
plastics (F.R.P.)
chajja 4 mm thick of required colour, size and design
made by Resin
Transfer Moulding (RTM) Machine Technology,
resulting in voi
d free compact laminate in single piece, having
smooth gradual slope
curvature for easy drainage of water and duly
reinforced by 2 nos
vertically and 1 nos horizontally 50x2 mm thick M.S.
flat with 12
mm in built hole for grouting on the existing wall
along with the 50
mm flanges duly inserted and sealed in the wall
complete in one single
piece casted monolithically, including all necessary
fittin
gs. The FRP chajja should be manufactured using
unsaturated Polyester
resin as per IS:6746, duly reinforced with fibre glass
chopped stand
mat (CSM) as per IS:11551 complete with protective
gel coat U
/V coating on top for complete resistance from the
extreme of

70
74 CS-SS- Providing and fixing G.I. crimped wire mesh of 254.00 Sqm 670 170180
14 required openings of size 25 mm x25 mm or of
any size with main and cross wires of 10 gauge
approved type as per manufacture’s specifications
with necessary
fittings including painting with one coat of one
coat of red oxide zinc chromate primer and two
coats of approved synthetic enamal paint etc.
complete as directed by Engineer In Charge. (Iron
works will be paid
separately. The clear visible area of the wire
mesh exclusive overlap
will be paid for

Total 14574539.95
Say 14574540

sd sd sd
SE(HIC)ES AE(HIC)S&T wards EE(HIC)ES

71
ELECTRICAL BOQ

72
 MUNICIPAL CORPORATION OF GREATER MUMBAI
Sub:- Structural repairs to KMJ Phule Hospital, Kannamwar Nagar, Vikhroli (East), 'S' Ward.
Estimate No. AEE/ 50 / P&D of 2016 -2017.
PART – I
SR. UNIFIED DESCRIPTION QTY. RATE Unit
NO SOR FOR in RS. AMOUNT
. M &E in RS.
DEPT
2013
A METER LEADS :-
i ME-1-10-j 3 nos. single core Cu PVC insulated flexible cable 5 8370.00 Mtr 41850.00
of 240 Sq.mm. for phases & 1 single core Cu PVC
insulated flexible cable for neutral of 150 Sq.mm
for 400 Amp. TPNSS switch.

B SWITCHGEARS AT Service Position &

distribution :-
i ME-1-6-a 63 Amp. 415V TPN Switchfuse unit with CRCA 4 3345.00 No. 13380.00
sheet steel powder coated enclosure with HRC
fuses & switch links. (Pump & AC)

ii ME-1-9-b 60 /63A TPN with tinned copper bars of size 20 x 1 5564.00 Mtr. 5564.00
3 mm.
iii ME-1-25- 63Amp. 4Pole ELCB 1 No. 3612.00
g 3612.00
iv ME-1-1-f 32 Amp. 415V TPN Switchfuse unit with CRCA 3 1861.00 No. 5583.00
sheet steel powder coated enclosure with
rewirable fuses

v ME-1-22- Automatic Star Delta Starter for 5 H.P to 15 H.P 3 10991.0 No. 32973.00
c 0
vi ME-1-13- IP 42 Wall/column Mounted distribution board 1 3915.00 No. 3915.00
d with one no of
DP 16/32A MCB as incomer and 6 nos 6A/10A SP
MCB as outgoing (12 way SPN DB) (If reqd)

vii ME-1-13-i IP 42 Wall/column Mounted distribution board 1 6610.00 No. 6610.00

with one no of
32A DP MCB as incomer an 6 nos 6/10A DP MCB
as outgoing
(18 way SPN DB)(If reqd)

73
viii ME-1-13- IP 42 Wall/column Mounted distribution board 4 9284.00 Nos. 37136.00
m with one no of
16/32A 4P MCB and 6 nos 16/32A DP MCB as
outgoing (4 way TPN DB) (ICU & X-Ray deptt. )

ix ME-1-7-h 30Amp.DP switch (i.e. 'TICINO' type) with neon 6 110.00 Nos. 660.00
indicator, fuse links & complete with necessary
fixing arrangement. (Switch shall be of ISI mark
only).

x ME-1-23- 3.0 KVAR Power capacitor 1 No. 2333.00

e 2333.00

C a) SUPPLY & INSTALLATION OF ANGLE IRON FRAME

WORK (TS-7):-

ME- 25 x 25 x 3 mm of M.S.angle 85 125.00 Rmtr 10625.00

i FW137 .
ME- 40 x 40 x 5 mm of M.S.angle. 35 335.00 Rmtr 11725.00
ii FW138 .
ME- 50 x 50 x 6 mm of M.S.angle. 10 500.00 Rmtr 5000.00
iii FW139 .

b) M.S.Flat Bar :-
i ME- Flat bars 25 mm x 3 mm thick. 45 70.00 Mtr. 3150.00
FB140
ii ME- Flat bars 40 mm x 5 mm thick. 20 Mtr.
FB141 180.00 3600.00
iii ME- Flat bars 50 mm x 6 mm thick. 5 Mtr.
FB142 270.00 1350.00
iv ME- Supply and fixing 20 mm thick Marine Ply Plank 20 925.00 Sq. 18500.00
WUD144 Mtr
v ME- Supply and fixing T. W.batten 25 mm x 40 mm. 20 40.00 Mtrs 800.00
WUD145

D a) 1.1 kV grade stranded Al conductor, XLPE insulated,

extruded PVC inner and outer sheathed, galvanised steel
round or strip armoured cables :-

i ME-2-1- 3.5C x 70 Sq.mm 25 343.00 Mtr 8575.00

w
ii ME-2-1-t 4C x 25 Sq.mm 625 171.00 Mtr 106875.00
iii ME-2-1-q 4C x 6 Sq.mm 510 108.00 Mtr. 55080.00
iv ME-2-1-c 2C x 6 Sq.mm 50 84.00 Mtr. 4200.00
v ME-2-1-b 2C x 4.0 Sq.mm 655 73.00 Mtr. 47815.00
vi ME-2-1-a 2C x 2.5 Sq.mm 100 72.00 Mtr. 7200.00
vii ME-2-3-h 6C x 2.5 Sq.mm cu 15 231.00 Mtr. 3465.00

b) Cable End Termination :-

74
 i ME-2-11- 3.5C x 185 Sq.mm 4 Set 5452.00
z 1363.00
ii ME-2-11- 3.5C x 120 Sq.mm 4 Set 4720.00
x 1180.00
iii ME-2-11- 3.5C x 70 Sq.mm 10 Set 8060.00
v 806.00
iv ME-2-11- 4C x 25 Sq.mm 30 Set 12960.00
s 432.00
v ME-2-11- 4C x 6 Sq.mm 44 250.00 Set 11000.00
p
ME-2-11- 2C x 6 Sq.mm 22 232.00 Set 5104.00
vi b
vii ME-2-11- 2C x 2.5/4 Sq.mm 44 191.00 Set 8404.00
a
viii ME-2-12- 6C x 2.5 Sq.mm cu 6 286.00 Set 1716.00
ag

c) Cable End Boxes :-

i ME-2-7-a 100/125 Amp. TPN switch fuse 2 728.00 No 1456.00

d) EXCAVATION:-
i ME-2-8 Excavating the trenches and refilling,reinstatement 20 300.00 Cu. 6000.00
of the same after the cable is laid in approved Mtr
manner (750 mm deep, 600 mm wide),in all types
of soils 1 Cu. Mtr. = 2.2 RMT.

ii ME-2-9 Excavating the trenches and refilling the same 10 463.00 Cu. 4630.00
after the cable is laid in approved manner (Size of Mtr
trench: 750 mm deep, 600 mm wide) in concrete/
masonary / asphalt. 1 Cu. Mtr. = 2.2 RMT. and
reinstatement

e) Supply & laying I.S.I. mark 'B' class GI Pipe for

surface / under ground cable protection

i ME-2-21- 38/40 mm dia. 70 445.00 RMtr 31150.00

e

f) SUPPLYING & LAYING 'C' CLASS G.I. PIPE (I.S.I

MARK) FOR SUCTION / DELIVERY LINE ETC.:

i ME-6-7-g 65 mm dia. 10 680.00 RMtr 6800.00

ii ME-6-7-f 50 mm dia. 50 536.00 RMtr 26800.00
iii ME-6-7-e 40 mm dia. 40 389.00 RMtr 15560.00

75
E ME-3-7 Point wiring by using PVC insulated copper conductors
(alongwith same size of pvc insulated copper conductor
for
earthing & 3 plate ceiling rose) using CASING-N
CAPING

i ME-3-6-a Light /Fan / Ex. fan Points 330 729.00 Each 240570.00
Pt.
ii ME-3-6-b 2/3 Pin Independent Plug (IP) 40 663.00 Each 26520.00
Pt.
iii ME-3-6-c Bell Point with Bell / Buzzer & 1 Bell Push 15 760.00 Each 11400.00
Pt.
iv ME-3-6-i 15 / 5 A / 6 A Combined Power Plug Socket Point 110 990.00 Each 108900.00
with Fuse and Indicating Lamp, One 15 Amp SP Pt.
Switch

ME-3-6-j 5A/6A - 3/5 Pin Plug On Board 65 166.00 Each 10790.00

v Pt.
vi ME-3-6-k Group Control Point Wiring 4-8 Points Controlled 6 189.00 Each 1134.00
by One 15 A Pt.
SP Switch

F Modular Switches :-
i KMJPH- Supplying and erecting modular type switch 6A/ 10 86.00 Each 860.00
F1 10A ISI mark approved make duly erected on Pt.
provided plate and box with wiring connections
complete.

ii KMJPH- Supplying and erecting modular type bell push 6A 10 109.00 Each 1090.00
F2 /10A ISI mark approved make duly erected on Pt.
provided plate and box with wiring connections
complete.

iii KMJPH- Supplying and erecting modular type 3 pin 6A/ 120 157.00 Each 18840.00
F3 16A multi socket with safety shutter , ISI mark Pt.
approved make duly erected on provided plate
and box with wiring connections complete.

iv KMJPH- Supplying and erecting unbreakable concealed 30 194.00 Each 5820.00

F4 type modular switch box with double mounting Pt.
plate for 2 module duly erected flush to wall with
required chiselling and finishing with cement
mortar / POP as per required to match the
background in an approved manner.

76
 v KMJPH- Supplying and erecting unbreakable concealed 10 255.00 Each 2550.00
F5 type modular switch box with double mounting Pt.
plate for 4 module duly erected flush to wall with
required chiselling and finishing with cement
mortar / POP as per required to match the
background in an approved manner.

vi KMJPH- Supplying and erecting unbreakable concealed 10 346.00 Each 3460.00

F6 type modular switch box with double mounting Pt.
plate for 6 module duly erected flush to wall with
required chiselling and finishing with cement
mortar / POP as per required to match the
background in an approved manner.

vii KMJPH- Supplying and erecting unbreakable concealed 10 412.00 Each 4120.00
F7 type modular switch box with double mounting Pt.
plate for 8 module duly erected flush to wall with
required chiselling and finishing with cement
mortar / POP as per required to match the
background in an approved manner.

viii KMJPH- Supplying and erecting pvc surface modular 30 63.00 Each 1890.00
F8 double mounting plate 2 module complete duly
erected in an approved manner.

ix KMJPH- Supplying and erecting pvc surface modular 10 76.00 Each 760.00
F9 double mounting plate 4 module complete duly
erected in an approved manner.

x KMJPH- Supplying and erecting pvc surface modular 10 120.00 Each 1200.00
F10 double mounting plate 6 module complete duly
erected in an approved manner.

xi KMJPH- Supplying and erecting pvc surface modular 10 141.00 Each 1410.00
F11 double mounting plate 8 module complete duly
erected in an approved manner.

G ME-12-4 COMPUTERS CABLES

77
 i ME-12-4- Cat 6 Gigabyte 350 42.00 Mtr 14700.00
b

ME-12-5 COMPUTER ACCESSORIES (SP-ME-TS-57)

i ME-12-5- Switch BOX point for computers through PVC 15 1653.00 Nos 24795.00
b Conduit

ii ME-12-5- PVC box & cover plate with RJ-45 for LAN access 9 294.00 Nos 2646.00
c only
iii ME-12-5- PVC box & cover plate with RJ-11 for Telephone 33 228.00 Nos 7524.00
d access only

H TELEPHONE SYSTEM:-
i ME-12-2- PVC Telephone Cable -2 pair 500 102.00 Mtrs 51000.00
a
ii ME-12-3- Armoured Telephone Cable -10 pair 200 137.00 Mtrs 27400.00
a
iii ME-12-3- Armoured Telephone Cable -20 pair 50 232.00 Mtrs 11600.00
b
iv ME-12-6- 10 pair M.S.Junction Box for EPABX 6 639.00 Nos 3834.00
a
v ME-12-6- 20 pair M.S.Junction Box for EPABX 2 675.00 Nos 1350.00
b
vi ME-12-7- 12 mm X 12 mm - Only Casing-Capping laying 600 26.00 Mtrs 15600.00
c
vii ME-12-5- Aluminium channel 16 SWG. 40 53.00 Mtrs 2120.00
f

I FITTINGS & FIXTURES:-

i ME-4-10- 1x28W, T-5 Fixtures, comprises of M.S. powder 215 1587.00 Nos. 341205.00
e coated with end cap. The fixtures complete with
high efficiency electronics ballast (THD<10%) &
PF > 0.98, complete with bright reflector & T-5
lamp.

ii ME-4-10- 2x28W, T-5 fixtures decorative recessed mirror 32 3886.00 Nos. 124352.00
k optic luminaire
having a unique reflector design of symmetric &
asymmetric
light distribution in one lumunaire both for task /
ambient and
vertical / wall wash applications., The fixtures
complete with
high efficiency electronics ballast (THD<33%) &
PF > 0.95
complete with T-5 lamp.

78
iii ME-4-10- Chalk Board Fitting 1 x 28W T
T-5 2 1004.00 Nos. 2008.00
n
iv ME-4-12- Ceiling fan of 1400 mm sweep with all accessories 50 2810.00 Nos. 140500.00
e including Electronic Regulator for completing
installation as per specification.

v ME-4-12- Wall mounting fan of 400mm sweep, 230 Volts,AC 2 3846.00 Nos. 7692.00
p 50 Hz, oscillating type complete with all necessary
accessories for completing installation.

vi ME-5-13- CFL 9/11 Watt 15 Nos. 1965.00

b 131.00
vii ME-4-12-i Exhaust fan 305 mm sweep 900/1400 RPM 3 3897.00 Nos. 11691.00
Single/Three ph. With 450 CFM free air delivery.

viii ME-4-12- Exhaust fan of 150mm sweep, 1400RPM, AC 230V, 12 2126.00 Nos. 25512.00
g 50 Hz, single phase complete with all necessary
accessories for completing installation as per
specification. (For toilets)

ix ME-4-12- Fan safety rope/ Fan wire. 125 228.00 Nos. 28500.00
s
x ME-4-15- S' type M.S. fan hook fabricated from suitable dia. 15 137.00 Nos. 2055.00
a M.S. rod duly painted for fixing of ceiling fan. The
'S' type hook shall be fixed to steel bar in RCC
ceiling. The ceiling shall be replastered with sand,
cement & neeru etc. The cost of labours for
chipping
ing out ceiling upto steel bar & fixing of 'S'
hook & resurfacing the ceiling is included in the
cost of item.

xi Swan neck type bracket for fixing HPMV / HPSV 4 534.00 Nos. 2136.00
ME-10-3-e lamp fixtures mounting on wall / shed etc. 0.5 to
1.2 Mtrs.

xii ME-1-20- 50mm x 50mm x 50mm size GI Junction box with 10 224.00 Nos. 2240.00
a knock out &
10Amp. Connector block /strip
 Energy efficient street light fixtures with housing
xiii one pieceAluminum Deep drawn body with clear
acrylic cover with high
highpurity Aluminum reflector,
electronic ballast having p.f. 0.98and
0.98 protection
class of IP 65, with following lamps

xiv ME-5-4-b 4 x 24W T-5 8 19682.0 Nos. 157456.00

0
xv ME-4-5-s Gate post fitting with PL 11 watts lamp. 2 2518.00 Nos. 5036.00

xvi ME-10-3- Raceway for fitting / fixtures by using G.I. 2 356.00 Nos. 712.00
f Reducer and 50 mm dia. 'B' class G.I. Pipe of
300mm length (for fixing gate lights)

xvi ME-4-8-a Medical examination lamp suitable for use with 2 8210.00 Nos 16420.00
60W GLS
lamp. The lamp shall be provided with three arms,
adjustable
swiveling, heavy duty ,telescopic. Arms shall be
provided with
nylon nuts and firm grip. Housing shall be made
up of cast Al with spun Al reflector, on/off toggle
tog
switch, bakelite lamp
holder and prewired with twin core flexible
copper cable . the
lamp shall be suitable for use with 240V, 50Hz,
Single phase
AC supply and wall mounting type. K-lite
K 3172 or
equivalant.

xvii ME-4-14- Storage type Horizontal / vertical water heater 3 4 3428.00 Nos 13712.00
a Liters
capacity on wall / loft as per specification.

J 1 FIXING OF TUBE LIGHT FIXTURES USING TWIN

DOWN M.S. CONDUIT, BALL SOCKET, FLANGES /
CHECK NUT ETC. WITH PAINTING:-

ME-4-16- Above 0.5 Mtr. to 1 Mtr. 109 Sets 22672.00

i b 208.00
 2 FIXING OF CEILING FANS WITH EXTENDED 1/2" G.I./
M.S. PIPE WITH SHACKLE MOUNTING ETC. WITH
PAINTING:-

ME-4-17- Above 0.5 Mtr. to 1 Mtr. 274.00 Sets 24660.00

i b 90
ME-4-17- Above 1 mtr. to 1.5 Mtr. 378.00 Sets 1890.00
ii c 5

K EARTHING:-
ii ME-7-4-e 25 mm x 3 mm G.I. 50 97.00 Mtrs 4850.00
iii ME-7-4-l Bare G.I. Conductor size 10 SWG 2100 11.00 Mtrs 23100.00

iv ME-7-4-j Bare Copper Conductor size 10 SWG 50 77.00 Mtrs 3850.00

v Supply and installation of following size Test

Links with required wiring and other accessories
to complete the work.

ME-7-3-a 25 x 3 mm GI (length : 300 mm) 3 29.00 Nos. 87.00

L REMOVAL, REFIXING, ELECTRICAL REPAIRS,

REPLACEMENT :-

i ME-8-1-a Removal of point wiring (Light ,fan 885 7.00 No. 6195.00
points,IP,PP,call bell,gong bell,bell indicator
points)
ii ME-8-1-g Removal of fixtures / fittings / ceiling fans / 522 31.00 No. 16182.00
bulkhead / street light / gyeser etc.

iii ME-8-1- Removal of fan regulator. (All types) 125 6.00 No. 750.00
m
iv ME-8-1-b Removal of switchgears / ELCB / RCCB upto 32 20 6.00 No. 120.00
Amp / 40 Amp.

v ME-8-1-c Removal of switchgears / ELCB / RCCB from 63 10 7.00 No. 70.00

Amp to 100 Amp.

vi ME-8-1-d Removal of switcgears / ELCB / RCCB above 100 3 16.00 No. 48.00
Amp to 400 Amp.

vii ME-8-1-e Removal of switchgears/ DBs upto 200 Amp. 57 16.00 No. 912.00

viii ME-8-1-h Removal of cable from 1.5 sq.mm to 3-1/2 core x 2690 7.00 Mtrs. 18830.00
35 sq.mm.

ix ME-8-1-i Removal of cable above 3-1/2 core x 35 Sq. mm. to 25 11.00 Mtrs. 275.00
3-1/2 core
x 70 sq. Mm

81
 x ME-8-1-j Removal of cable above 3-1/2 core x 70 Sq.mm 25 16.00 Mtrs. 400.00
upto 3-1/2 core x 120 sq. mm.

xi ME-8-1-k Removal of cable above 3-1/2 core x 120 Sq.mm 20 26.00 Mtrs. 520.00
upto 3-1/2 core x 400 sq. mm.

xii ME-8-1-n Removal of 'A' , 'B' & 'C' class G.I. pipe upto 100 35 11.00 Mtrs. 385.00
mm dia.
xiii ME-8-1-t Removal of starter 1 ph. / 3 ph. DOL / Star- Delta 3 11.00 No. 33.00
/ F.A.S.D.
xiv ME-8-1-o Removal of control panel upto 100 Amp. incomer, 1 158.00 Pane 158.00
capacitor etc. l

xv ME-8-1-p Removal of control panel above 100 Amp incomer 1 315.00 Pane 315.00
upto 300 Amp incomer with busbar, capacitor etc. l

xvi ME-8-1-r Removal of busbar chamber from 32 Amp TPN to 1 11.00 No. 11.00
100 Amp TPN.

xvii ME-8-1-s Removal of busbar chamber above 100 Amp TPN 1 26.00 No. 26.00
to 800 Amp TPN.

xvii ME-8-20- Repainting of fans & fixtures with brush 15 113.00 Nos 1695.00
i b

M REFIXING :-
i ME-8-2-a Refixing of switchgear, DBs, busbars upto 100 80 140.00 Nos 11200.00
Amp switch on existing arrangement.

ii ME-8-2-b Refixing of switchgear, DBs, busbars above 100 3 210.00 Nos 630.00
Amp to 800 Amp switch on existing arrangement.

iii ME-8-2-f Refixing of control panel from 16 Amp to 100 Amp 1 322.00 Pane 322.00
incomer l
including terminations, interconnections etc.

iv ME-8-2-g Refixing of control panel above 100 Amp to 800 1 643.00 Pane 643.00
Amp incomer l
including terminations, interconnections etc.

v ME-8-2-d Refixing of ceiling fans. 75 38.00 Nos 2850.00

vi ME-8-2-h Refixing of 2 core/ 3 core/ 3-1/2 core / 4 core/ 6 530 40.00 Mtr 21200.00
core copper / aluminium conductor armoured /
unarmoured cable 1.5 sq.mm. to 16 sq.mm. size on
wall / ceiling etc.

82
vii ME-8-2-i Refixing of 2 core / 3 core / 3-1/2 core / 4 core/ 6 230 60.00 Mtr 13800.00
core copper / aluminium conductor armoured /
unarmoured cable above 16 sq.mm. to 150 sq.mm.
size on wall / ceiling etc.

viii ME-8-2-j Refixing of 3-1/2 core / 4 core copper / 20 70.00 Mtr 1400.00
aluminium armoured cable above 150 sq.mm. to
400 sq.mm. size on wall / ceiling etc.

ix ME-8-2-o Removing & refixing of existing ceiling fan by 35 214.00 Nos 7490.00
replacing new rubber shycle cotter pin ,check nut,
connector 3 core flexible wire, clamps for ceiling
fan, M.S. (High Tension) full threaded nut bolts
etc.

x ME-8-2-c Refixing of tubelight fixture with new flexible wire 80 48.00 Nos 3840.00
accessories & using old conduit pipe or old T. W.
Round block.

N REPAIRS / REWINDING OF CEILING FAN /

PEDESTAL FAN /EXHAUST FAN INCLUDING
TRANSPORTATION CHARGES ETC.
REWINDING OF FANS :

i ME-8-31- 1200 mm sweep ceiling fan 5 526.00 Nos 2630.00

c
ii ME-8-31- 1400 mm sweep ceiling fan 30 619.00 Nos 18570.00
d

REPLACEMENT :-
ME-8-32- Replacement of bearing for fans 1400mm sweep. 10 339.00 Nos 3390.00
d

O 1 Removal of existing Solar Water Heating Panel

alongwith accessories

i KMJPH- Removing Solar Collectors & shifting to storage 1750 17.00 Ltrs. 29750.00
F12 place
ii KMJPH- Removing Rockwool insulation with aluminum 130 17.00 ft. 2210.00
F13 cladding

iii KMJPH- Removing S.S.Hot water tank & shifting to 1 11236.0 no. 11236.00
F14 storage place 0

83
iv KMJPH- Removing & Dismantling M.S Structure frame & 1 8989.00 Job 8989.00
F15 shifting to storage place

2 Refixing of Solar Water Heating Panel

alongwith accessories

i KMJPH- Installation of S.S.Hot Water Tank on M.S.Stand 1 5618.00 Job 5618.00

F16
ii KMJPH- Installing all collectors with new nut bolt and 1750 18.00 Ltrs. 31500.00
F17 gaskets on MS work

iii KMJPH- Fabricating & fixing MS Structure for Solar 1 9629.00 Job 9629.00
F18 collators & G.I Railing

iv KMJPH- Providing & fixing MS stand for hot water tank 1 6018.00 Job 6018.00
F19
v KMJPH- Providing & fixing new rock wool insulation on 50 542.00 Sq.ft 27100.00
F20 S.S.tank with 48kg density with 26G aluminum .
sheet cladding.

vi KMJPH- Providing & fixing locking arrangement on 5 422.00 Nos. 2110.00

F21 taps.
vii KMJPH- Providing & fixing instruction plates near hot 5 241.00 Nos. 1205.00
F22 line connection.

viii KMJPH- Providing & fixing 4’’ temp. gauge 1 4213.00 No. 4213.00
F23
ix KMJPH- Applying black enamel paint on MS Structures. 1 6018.00 Job 6018.00
F24
x ME-5-17- G.I pipe 25mm dia B class with resin bonded 250 777.00 Mtrs 194250.00
b flap rock wool insulation, with necessary .
material as per specification

xi ME-5-17- G.I pipe 20mm dia B class with resin bonded 50 595.00 Mtrs 29750.00
a flap rock wool insulation, with necessary .
material as per specification

P CCTV :-
i VS- Removing and refixing of CCTV cameras :- 9 1258.00 Nos. 11322.00
CCTV-
FR-14
ii ME-12-4- RG 6 450 53.00 Mtr. 23850.00
c

84
iii ME-12-8- 25 mm.- Only PVC Conduits laying 450 39.00 Mtr. 17550.00
a
Total of 'A' to 'P' 2699230.00
Q PART 'II' Medical Gas system :-
i VS-MGP- SITC of COPPER PIPE:12 mmx0.7 mm thick for 300 498.00 Mtrs. 149400.00
FR-1 Medical gas system.

ii VS-MGP- SITC of COPPER PIPE:15 mmx0.9 mm thick for 950 645.00 Mtrs. 612750.00
FR-2 Medical gas system.

iii VS-MGP- SITC of COPPER PIPE:22 mmx0.9 mm thick for 10 1055.00 Mtrs. 10550.00
FR-3 Medical gas system.

iv VS-MGP- Outlet points for Oxygen- Double locking parking 29 4234.03 Nos. 122786.93
FR-4 type
v VS-MGP- Outlet points for N2O- Double locking parking 7 4234.03 Nos. 29638.22
FR-5 type
vi VS-MGP- Outlet points with probe for vaccum -Double 28 4234.03 Nos. 118552.90
FR-6 locking parking type

vii VS-MGP- SITC of brass bodied BPC Flowmeter alongwith 29 2127.00 Nos. 61683.00
FR-7 pipeline adopter & humidifier.

viii VS-MGP- Isolation Valve:15mm 25 2075.20 Nos. 51879.96

FR-8
ix VS-MGP- SITC of Anciliary of Vaccum Regulator with 600 19 6963.26 Nos. 132301.94
FR-9 ml receiving jar

x VS-MGP- Dismantling the Medical gas pipeline of oxygen 1250 50.00 Mtr. 62500.00
FR-10 and Vacuum pipe line including all sizes of pipes.

xi VS-MGP- Imported Vacuum HP antistatic tube, yellow. 60 500.00 Mtr. 30000.00

FR-11 Fully complies and meets with HTM02-01, C 11
Standard and duly CE marked.

xii VS-MGP- Supply, Installation, Testing & Commissioning of 60 500.00 Mtr 30000.00
FR-12 Oxygen H.P. antistatic tube, white EN 739 CE
certified complete in all aspect..It should be Fully
Complies and meets with HTM02-01, C 11
Standard of UK

xiii VS-MGP- Supply, Installation, Testing & Commissioning of 15 500.00 Mtr. 7500.00
FR-13 (Imported) N₂0 H.P. tube with antistatic core,
French blue. .It should be Fully Complies and
meets with HTM02-01, C 11 Standard and duly CE
marked.

85
 Total of 'Q' 1419542.95
Total of 'A' to 'Q' 4118772.95
Say Rs. 4118780.00
(Total In words : Rs. Forty one lacs eighteen thousand seven hundred eighty only).

N 1. Electrical estimate is based on UNIFIED SOR FOR M &

&E
E DEPT. 2013 schedule and some
OT items are included from FME 2010 schedule.
E:
2. The estimate is prepared on the basis of existing site condition and the information/
requirement provided by KMJ Phule Hospital.
3. All the items not considered for rebate should be handed over to hospital concerned staff.

sd sd sd
S.E.(M&E)P&D A.E.(M&E)P&
A.E.(M&E)P&D E.E.MECH.(EI)P&D
SR. UNIFIED DESCRIPTION QTY. RATE in PER AMOUNT in
NO. SOR FOR RS. RS.
M &E
DEPT 2013

Rebate for taking away

removed old material:
i ME-8-4-b Point wiring in copper 615 19.00 Each 11685.00
conductor
ii ME-8-5-a Switchgears upto 100 Amps 4 47.00 Each 188.00
iii ME-8-5-b Switchgears above 100 Amps to 1 93.00 Nos 93.00
200 Amps.
iv ME-8-5-d Rebate for busbar chamber 1 700.00 Nos 700.00
from 32Amp TPN to 100Amp
TPN
v ME-8-7-a Al. cable upto 3 1/2 C x 35 sq. 1955 14.00 Mtr. 27370.00
mm
vi ME-8-7-b Aluminium cable above 3-1/2 25 19.00 Mtr. 475.00
C x 35 sq. mm to 400 sq. mm
vii ME-8-8-a All types of tube light fittings / 184 37.00 Each 6808.00
fixtures with down suspension
rods ball socket and flanges.
viii ME-8-14-a Fan regulator Resistance type 50 5.00 Each 250.00
ix ME-8-14-b Ceiling Fan / Table Fan all 50 149.00 Each 7450.00
types and sizes
x ME-8-14-c Exhaust Fan all types and sizes 2 149.00 Each 298.00
xi ME-8-9-e B' & 'C' G.I. pipe with 100 14.00 Mtr. 1400.00
accessories all sizes.
Total Rs. 56717.00
(Total In words : Rs. Fifty six thousand seven hundred seventeen only).

sd sd sd
S.E.(M & E) P&D A.E.(M & E) P&D E.E. Mech.( E.I.) P&D

87
 SECTION 9

SPECIAL DIRECTIONS TO THE TENDERER

88
 SPECIAL DIRECTIONS TO THE TENDERER

1. The rate quoted shall be inclusive of transporting and disposal of surplus

excavated material.

2. The percentage quoted shall include the cost of any unforeseen item of work
connected with the work in question required for the proper execution of the
work.
3. The materials used shall confirm to the related ISI specifications as well as
MCGM specified specification wherever applicable. Directives of Engineer
concerned will be binding.

4. The water supply to the user department shall not be disturbed during execution
of the work. Contractor shall make alternate arrangement for providing
equivalent capacity tank to restore water supply at their own cost.

5. Maximum care should be taken to the satisfaction of the Engineer to provide and
maintain adequate protection to all electrical and mechanical installations. No
extra payment will be made on this account under any circumstances.

6. Contractor will have to make their own arrangement for getting the electric
supply / temporary electric meter on site for fabrication and allied works at their
own cost.

7. The contractor shall intimate the concerned authorities before starting the work
and execute the work on priority fixed by the Engineer-in-charge. The inventory
of serviceable and unserviceable material must be taken jointly with Site-in-
charge (Sub-Engineer) before starting of work.

8. No separate payment will be made for dewatering the water seeping in the
trenches and foundation pits opened while executing excavation and other
foundation works. The possibility of high water table should be kept in mind
while quoting the percentage.

9. While excavating the trenches for foundation utmost care shall be taken that the
foundation of adjoining structures will not be disturbed.

89
10. Materials brought on the site or debris will not be allowed to be stacked in
passages or in the car park area.

11. After completion of the waterproofing work, the leakage test shall be carried
out after impounding the water and plugging the openings at least for ten days,
without any extra cost.

12. Plumbing and sanitary works will have to be carried out through licensed
plumber. All plumbing lines will be provided 2" away from wall with spaces as
directed. The horizontal and vertical lines should be in line & level.

13. The centering shall be provided only in M.S. plates and M.S. pipe props.

14. Engineer in-charge reserves the right to delete any item, alter / reduce the scope
of the work, no extra claim in this respect will be allowed.

15. Water Proofing Treatment layer should not be removed manually, the layer
have to be removed by battery operated cutter only. No extra payment will be
made.

16. Staircase will not be allowed for transport of materials and contractor will have
to provide mechanical lift or pulley at their own cost. No extra payment will be
made for this arrangement.

17. The contractor shall have to arrange to carry out the work during night time
also as per urgency of the work, at no extra cost with prior approval from
Engineer in-charge.

18. After completion of the proposed work, the tenderer/ contractor will have to
hand over the site in neat and clean condition for which no extra payment will be
made.
19. On receipt of the work order the contractor will have to erect ready-made site
Chowky and Godown in form of porta cabin/container cabin. Before erecting the
Chowky and Godown, he shall have to obtain permission from the concerned
Assistant Commissioner and the Assistant Commissioner shall approve the site
of the Chowky and Godown proposed by the Engineer or may allot another
suitable site. The porta cabin/ container shall preferably ad measure 12.20 m x
90
 2.50 m with two doors and proper ventilation. It should have toilet facility &
lighting arrangement.

The contractor has to provide for site office as per requirement either on his/ her
owned place or rented/ leased place. Cost for this may be charged to MCGM by
incorporating in the offer. No separate payment may be made for providing the
chowky and ancillary items. No permission and space for site chowky will be
given / provided on Municipal road/ footpath. The contractor has to make their
own arrangement on hire/ lease for site office.

20. The noise level shall be maintained within the permissible limit in
Silence Zone area during the construction activities by the Contractors as per
the notification dated 14-02-2000 issued by the Ministry of Environment and
Forests.

21. Municipal Corporation of Greater Mumbai do not have site available for
disposal of Debris / Demolition material / excavated earth. The Contractor shall
dispose these materials properly at his own risk & cost. The contractor shall
quote the tender keeping these in mind. No separate payment shall be made for
disposal of these Debris / Demolition material / excavated earth.

22. It is mandatory for the contractor to maintain the Noise level during the
construction activity within the permissible limits as prescribed by MCGM as
per circular under no. CE/PD/7788/I dt. 05/11/2008.

23. The serviceable material of MCGM obtained during work, such as M.S. Grills,
reinforcement, structural pipes & MS props if provided etc. shall be handed over
in the custody of concerned A.E. (Maint) of concerned ward by taking &
maintaining the proper inventories of the serviceable materials.

24. Tenderer/bidders shall take proper care while carrying out repairing work of
electrical cabins as switchgears & other electrical items needs to be shifted
carefully to avoid any mishap, theft & to have continuous supply on site in
consultation with Ch.E(M & E) staff.

91
25. No extra payment shall be made to make appropriate provision to close door,
window & opening as and where necessary to avoid breakage of glass and entry
of dust during operation using 6 mm commercial plywood. Contractor shall
quote the tender by taking note of it.

26. Appointment of Licensed Structural Engineer by successful bidders

for execution of work. However no payment will be permitted to such
Licensed Structural Engineer by the MCGM.
a. The contractor shall appoint / avail the services of Structural Engineer
registered with MCGM to supervise/ periodicaly supervise the structural
repair work at his own cost and submit his consent along with his registration
/ license certificate before starting the work.

b. The above said registered structural Engineer shall issue a certificate after
completion of structural repair work certifying that the structural repairs have
been carried out under his supervision and the repairs are carried out
satisfactory according to him as per structural audit report. This certificate
should also state that the structure after repairs is stable & fit for human
habitation. (i.e. structural stability certificate)

27. No extra payment shall be paid for removing and refixing of windows
MS grill / aluminium grill. Contractor shall quote the tender by taking note of
it.
28. Work of Deco-grill shall not be allowed in view of circular to this effect.
29. The contractor shall carry out periodic medical check up of employees
working under him.

92
 SECTION 10

GENERAL CONDITIONS OF CONTRACT

93
 General Conditions of Contract

A. General

1. Definitions

1.1 Terms which are defined in the Contract Data are not also defined in
the Conditions of Contract but keep their defined meanings. Capital
initials are used to identify defined terms.

The “Contract” shall mean the tender and acceptance thereof and the
formal agreement if any, executed between the Contractor,
Commissioner and the Corporation together with the documents
referred to therein including these conditions and appendices and any
special conditions, the specifications, designs, drawings, price
schedules, bills of quantities and schedule of rates. All these
documents taken together shall be deemed to form one Contract and
shall be complementary to one another.

The Contract Data defines the documents and other information

which comprise the Contract.

The “Contractor” shall mean the individual or firm or company

whether incorporated or not, whose tender has been accepted by the
employer and the legal successor of the individual or firm or company,
but not (except with the consent of the Employer) any assignee of
such person.

The Bidder is a person or corporate body who has desired to submit

Bid to carry out the Works, including routine maintenance till the
tender process is concluded.

The Contractor's Bid is the completed bidding document submitted by

the Contractor to the Employer.

The “Contract Sum” means the sum named in the letter of acceptance
including Physical contingencies subject to such addition thereto or
deduction there-from as may be made under the provisions
hereinafter contained.

94
Note : The contract sum shall include the following –
 In the case of percentage rate contracts the estimated value of
works as mentioned in the tender adjusted by the Contractor’s
percentage.
 In the case of item rate contracts, the cost of the work arrived at
after finalisation of the quantities shown in schedule of items /
quantities by the item rates quoted by the tenderers for various
items and summation of the extended cost of each item.
 In case of lumpsum contract, the sum for which tender is accepted.
 Special discount / rebate / trade discount offered by the tenderer if
any and acceptedby the Corporation.
 Additions or deletions that are accepted after opening of the
tenders.

The “Contract Cost” means the Contract Sum plus Price Variation.
This cost shall be included in the letter of acceptance.

A Defect is any part of the Works not completed in accordance with

the Contract.

The Defects Liability Certificate is the certificate issued by the

Engineer, after the Defect Liability Period has ended and upon
correction of Defects by the Contractor.

Drawings means all the drawings, calculations and technical

information of a like nature provided by the Engineer to the
Contractor under the Contract and all drawings, calculations,
samples, patterns, models, operation & maintenance manual and
other technical information of like nature submitted by the Contractor
and approved by the Engineer.

The Authority shall mean Municipal Corporation of Greater Mumbai

(MCGM)

The “Employer” shall mean the Municipal Corporation for Greater

Mumbai / Municipal Commissioner for Greater Mumbai, for the time
being holding the said office and also his successors and shall also
include all “Additional Municipal Commissioners, Director
95
(Engineering Services & Projects)” and the Deputy Municipal
Commissioner, to whom the powers of Municipal Commissioner, have
been deputed under Section 56 and 56B of the Mumbai Municipal
Corporation Act.

The Engineer in-charge shall mean the Executive Engineer in

executive charge of the works and shall include the superior officers of
the Engineering department i.e. Dy.Ch.Eng/Ch.Eng. and shall mean
and include all the successors in MCGM

The Engineer's Representative shall mean the Assistant Engineer,

Sub. Engineer/Jr. Engineer in direct charge of the works and shall
include Sub Eng./ Jr. Eng of Civil section/ Mechanical section/
Electrical section appointed by MCGM.

The “Engineer” shall mean the City Engineer / the Hydraulic Engineer
/ the Chief Engineer / the Special Engineer, appointed for the time
being or any other officer or officers of the Municipal Corporation who
may be authorized by the commissioner to carry out the functions of
the City Engineer / the Hydraulic Engineer / the Chief Engineer / the
Special Engineer or any other competent person appointed by the
employer and notified in writing to the Contractor to act in
replacement of the Engineer from time to time.

Contractor’s Equipment means all appliances and things of

whatsoever nature required for theexecution and completions of the
Works and the remedying of any defects therein, but do not include
plant material or other things intended to form or forming part of the
Permanent Works.

The Initial Contract Price is the Contract Price listed in the Employer's
Letter of Acceptance.

The Intended Completion Date is the date on which it is intended that

the Contractor shall complete the construction works. The Intended
Completion Date is specified in the Contract Data. The Intended
Completion Date may be revised only by the Engineer by issuing an
extension of time.

96
Materials are all supplies, including consumables, used by the
Contractor for incorporation in the Works and works of routine
maintenance.

Plant is any integral part of the Works that shall have a mechanical,
electrical, electronic, chemical, or biological function.
Routine Maintenance is the maintenance of activities of the competed
structure for five years as specified in the Contract Data.

The “Site” shall mean the land and other places including water
bodies more specifically mentioned in the special conditions of the
tender, on, under in or through which the permanent works or
temporary works are to be executed and any other lands and places
provided by the Municipal Corporation for working space or any other
purpose as may be specifically designated in the contract as forming
part of the site.

Site Investigation Reports are those that were included in the bidding
documents and are reports about the surface and subsurface
conditions at the Site.

“Specification” shall mean the specification referred to in the tender

and any modification thereof or addition or deduction thereto as may
from time to time be furnished or approved in writing by the Engineer.

The Start Date/Commencement Date is given in the Contract Data. It

is the date when the Contractor shall commence execution of the
Works. It does not necessarily coincide with any of the Site Possession
Dates.

A Nominated Sub-Contractor is a person or corporate body who has a

Contract with the Contractor to carry out a part of the construction
work and/or routine maintenance in the Contract, which includes
work on the Site.

Temporary Works are works designed, constructed, installed, and

removed by the Contractor that are needed for construction or
installation of the Works.

97
 Variation means a change to the:-

i) Specification and /or Drawings (if any) which is instructed by the

Employer.
ii) Scope in the Contract which is instructed by the Employer.
iii) Price in the Contract which is instructed by the Employer.

The Works, as defined in the Contract Data, are what the Contract
requires the Contractor to construct, install, maintain, and turn over
to the Employer. Routine maintenance is defined separately.

Jurisdiction: In case of any claim, dispute or difference arising in

respect of a contract, the cause of action thereof shall be deemed to
have arisen in Mumbai and all legal proceedings in respect of any
claim, dispute or difference shall be instituted in a competent court in
the City of Mumbai only.

2. Interpretation

2.1 In interpreting these Conditions of Contract, singular also means

plural, male also means female or neuter, and the other way around.
Headings have no significance. Words have their normal meaning
under the language of the Contract unless specifically defined. The
Engineer will provide instructions clarifying queries about these
Conditions of Contract.

2.2 If sectional completion is specified in the Contract Data, references

in the Conditions of Contract to the Works, the Completion Date,
and the Intended Completion Date apply to any Section of the Works
(other than references to the Completion Date and Intended
Completion Date for the whole of the Works).

2.3 The documents forming the Contract shall be interpreted in the

following documents: (1) Agreement, (2) Letter of Acceptance, (3)
Notice to Proceed with the Work, (4) Contractor's Bid, (5) Contract
Data, (6) Special Conditions of Contract Part (7) General Conditions
of Contract Part I, (8) Specifications, (9) Drawings, (10) Bill of
Quantities, and (11) Any other document listed in the Contract Data.

98
3 . Engineer's Decisions

3.1 Except where otherwise specifically stated, the Engineer will decide
contractual matters between the Employer and the Contractor in the
role representing the Employer. However, if the Engineer is required
under the rules and regulations and orders of the Employer to
obtain prior approval of some other authorities for specific actions,
he will so obtain the approval, before communicating his decision to
the Contractor.

3.2 Except as expressly stated in the Contract, the Engineer shall not
have any authority to relieve the Contractor of any of his obligations
under the contract.

4. Delegation

4.1 The Engineer, with the approval of the Employer, may delegate any
of his duties and responsibilities to other person(s), except to the
Adjudicator, after notifying the Contractor, and may cancel any
delegation after notifying the Contractor.

5. Communications

All certificates, notices or instructions to be given to the Contractor by

Employer/ Engineer shall be sent on the address or contact details
given by the Contractor of Bid. The address and contact details for
communication with the Employer/ Engineer shall be as per the
details given in Contract Data. Communications between parties that
are referred to in the conditions shall be in writing. The Notice sent by
facsimile (fax) or other electronic means shall be effective on
confirmation of the transmission. The Notice sent by Registered post
or Speed post shall be effective on delivery or at the expiry of the
normal delivery period as undertaken by the postal service.

6. Subcontracting

6.1 Unless specifically mentioned in the contract subletting will not be

allowed. Subletting, where otherwise provided by the contract shall
not be more than 25% of the contract price.

99
 6.2 The Contractor shall not be required to obtain any consent from the
Employer for:

a. the sub-contracting of any part of the Works for which the

Subcontractor is named in the Contract;

b. the provision for labour, or labour component.

c. the purchase of Materials which are in accordance with the

standards specified in the Contract.

6.3 Beyond what has been stated in clauses 6.1 and 6.2, if the
Contractor proposes sub-contracting any part of the work during
execution of the Works, because of some unforeseen circumstances
to enable him to complete the Works as per terms of the Contract,
the Employer will consider the following before according approval:

a. The Contractor shall not sub-contract the whole of the Works.

b. The permitted subletting of work by the Contractor shall not

establish any contractual relation-ship between the sub-contractor
and the MCGM and shall not relieve the Contractor of any
responsibility under the Contract.
6.4 The Engineer should satisfy himself before recommending to the
Employer whether

a. the circumstances warrant such sub-contracting; and

b. the sub-Contractor so proposed for the Work possesses the
experience, qualifications and equipment necessary for the job
proposed to be entrusted to him.

7. Other Contractors

7.1 The Contractor shall cooperate and share the Site with other
Contractors, public authorities, utilities, and the Employer between
the dates given in the Schedule of Other Contractors, as referred to
in the Contract Data. The Contractor shall also provide facilities and
services for them as described in the Schedule. The Employer may

100
 modify the Schedule of Other Contractors, and shall notify the
Contractor of any such modification.

7.2 The Contractor should take up the works in convenient reaches as

decided by the Engineer to ensure there is least hindrance to the
smooth flow and safety of traffic including movement of vehicles and
equipment of other Contractors till the completion of the Works.

8. Personnel

8.1 The Contractor shall employ for the construction work and routine
maintenance the key personnel including technical personnel named
in the Contract Data or other personnel approved by the Engineer.
The Engineer will approve any proposed replacement of technical
personnel only if their relevant qualifications and abilities are
substantially equal to those of the personnel stated in the Contract
Data.

8.2 The Contractor’s personnel shall appropriately be qualified, skilled

and experienced in their respective trades or occupations. The
Engineer shall have authority to remove, or cause to be removed,
any person employed on the site or works, who carries out duties
incompetently or negligently and persists in any conduct which is
prejudicial to safety, health or the protection of the environment.

8.3 If the Engineer asks the Contractor to remove a person who is a

member of the Contractor's staff or work force, stating the reasons,
the Contractor shall ensure that the person leaves the Site within
seven days and has no further connection with the Works in the
Contract.

8.4 The Contractor shall not employ any retired Gazetted officer who has
worked in the Engineering Department of the MCGM /State
Government and has either not completed two years after the date of
retirement or has not obtained MCGM/State Government’s
permission to employment with the Contractor.

101
9. Employer's and Contractor's Risks

9.1 The Employer carries the risks which this Contract states are
Employer's risks, and the Contractor carries the risks which this
Contract states are Contractor's risks.

10. Employer's Risks

10.1 The Employer is responsible for the excepted risks which are (a) in
so far as they directly affect the execution of the Works in the
Employer’s country, the risks of war, invasion, act of foreign
enemies, rebellion, revolution, insurrection or military or usurped
power, civil war, riot, commotion or disorder (unless restricted to
the Contractor’s employees) and contamination from any nuclear
fuel or nuclear waste or radioactive toxic explosive, or (b) a cause
due solely to the design of the Works, other than the Contractor’s
design.

11. Contractor's Risks

11.1 All risks of loss of or damage to physical property and of personal

injury and death which arise during and in consequence of the
performance of the Contract other than the excepted risks, referred
to in clause 11.1, are the responsibility of the Contractor.

12. Insurance

12.1 The Contractor at his cost shall provide, in the joint names of the
Employer and the Contractor, insurance cover from the Start Date
to the end of Defects Liability Period, in the amounts and
deductibles stated in the Contract Data for the following events
which are due to the Contractor's risks:

a) Loss of or damage to the Works, Plant and Materials;

b) Loss of or damage to Equipment;
c) Loss of or damage to property (other than the Works, Plant,
Materials, and Equipment) in connection with the Contract; and
d) Personal injury or death.

102
 12.2 Insurance policies and certificates for insurance shall be delivered
by the Contractor to the Engineer for the Engineer's approval
before the Start Date. All such insurance shall provide for
compensation to be payable in the types and proportions of
currencies required to rectify the loss or damage incurred.

12.3 Alterations to the terms of insurance shall not be made without the
approval of the Engineer.

12.4 Both parties shall comply with any conditions of the insurance
policies.

12.5 If the Contractor does not provide any of the policies and
certificates required, the Employer may affect the insurance which
the Contractor should have provided and recover the premiums the
Employer has paid, from payments otherwise due to the Contractor
or if no payment is due, the payment of premiums shall be debt
due.

13. Site Investigation Reports

13.1 The Contractor, in preparing the Bid, may rely, at his own risk, on
any Site Investigation Reports referred to in the Contract Data,
supplemented by any other information available to him, before
submitting the bid.

14. Queries about the Contract Data

14.1 The Engineer will clarify queries on the Contract Data.

15. Contractor to Construct the Works and Undertake Maintenance (if

specified in the tender)

15.1 The Contractor shall construct, and install and maintain the Works
in accordance with the Specifications and Drawings and as per
instructions of the Engineer.

103
15.2 The Contractor shall construct the works with intermediate
technology, i.e., by manual means with medium input of
machinery required to ensure the quality of works as per
specifications. The Contractor shall deploy the equipment and
machinery as required in the contract.

15.3 The Contractor shall take all reasonable steps to protect the
environment he Site and to avoid damage or nuisance to persons or
to property of the public or others resulting from pollution, noise or
other causes arising as a consequence of his methods of operation.

During continuance of the contract, the Contractor and his sub-

contractors shall abide at all times by all existing enactments on
environmental protection and rules made there under, regulations,
notifications and byelaws of the State or Central Government, or
local authorities and any other law, bye-law, regulations that may
be passed or notification that may be issued in future by the State
or Central Government or the local authority. Salient features of
some of the major laws that are applicable are given below:

 The Water (Prevention and Control of Pollution) Act, 1974, this

provides for the prevention and control of water pollution and
the maintaining and restoring of wholesomeness of water.
‘Pollution’ means such contamination of water or such
alteration of the physical, chemical or biological properties of
water or such discharge of any sewage or trade effluent or of
any other liquid, gaseous or solid substance into water (whether
directly or indirectly) as may, or is likely to, create a nuisance or
render such water harmful or injurious to public health or
safety, or to domestic, commercial, industrial, agricultural or
other legitimate uses, or to the life and health of animals or
plants or of aquatic organisms.

 The Air (Prevention and Control of Pollution) Act, 1981, this

provides for prevention, control and abatement of air pollution.
‘Air Pollution’ means the presence in the atmosphere of any ‘air
pollutant’, which means any solid, liquid or gaseous substance
(including noise) present in the atmosphere in such
104
 concentration as may be or tend to be injurious to human
beings or other living creatures or plants or property or
environment.

 The Environment (Protection) Act, 1986, this provides for the

protection and improvement of environment and for matters
connected therewith, and the prevention of hazards to human
beings, other living creatures, plants and property.
‘Environment’ includes water, air and land and the inter-
relationship which exists among and between water, air and
land, and human beings, other living creatures, plants, micro-
organism and property.

 The Public Liability Insurance Act, 1991, This provides for

public liability insurance for the purpose of providing immediate
relief to the persons affected by accident occurring while
handling hazardous substances and for matters connected
herewith or incidental thereto. Hazardous substance means any
substance or preparation which is defined as hazardous
substance under the Environment (Protection) Act 1986, and
exceeding such quantity as may be specified by notification by
the Central Government.

16. The Works and Routine Maintenance to be completed by the

Intended Completion Date

16.1 The Contractor may commence execution of the Works on the Start
Date and shall carry out the Works and Routine Maintenance, if
specified in the tender, in accordance with the Programme
submitted by the Contractor, as updated with the approval of the
Engineer, and complete them by the Intended Completion Date.

17. Approval by the Engineer

17.1 The Contractor shall submit Specifications and Drawings showing

the proposed Temporary Works to the Engineer, who is to approve
them if they comply with the Specifications and Drawings.

105
 17.2 The Contractor shall be responsible for design and safety of
Temporary Works.

17.3 The Engineer's approval shall not alter the Contractor's

responsibility for design and safety of the Temporary Works.

17.4 The Contractor shall obtain approval of third parties to the design
of the Temporary Works, where required.

17.5 All Drawings prepared by the Contractor for the execution of the
temporary or permanent Works, are subject to prior approval by
the Engineer before their use.

18. Safety

18.1 The Contractor shall be responsible for the safety of all activities on
the Site. He shall comply with all applicable safety requirements
and take care of safety of all persons entitled to be on the site and
the works. He shall use reasonable efforts to keep the site and the
works, both during construction and maintenance, clear of
unnecessary obstruction so as to avoid danger to the persons and
the users.

 Workers employed on mixing asphaltic materials, cement and

lime mortars shall be provided with protective footwear and
protective goggles.

 Stone breaker shall be provided with protective goggles and

protective clothing and seated at sufficiently safe intervals.

 The area should be barricaded or cordoned off by suitable

means to avoid mishaps of any kind. Power warning signs
should be displayed for the safety of the public whenever
cleaning works are undertaken during night or day.

 The workers engaged for cleaning the manholes/sewers should

be properly trained before allowing working in the manhole.

18.2 Safety Programs:-

106
  Have adequate safety supervision in place to ensure that safety
programs set up by the firms/agencies are in compliance with
prevalent laws and regulations.
 Review safety programs developed by each of the trade firms,
prepare and submit a comprehensive safety program.
 Monitor day to day implementation of safety procedures.

18.3 First Aid Facilities: -

i. At every work place there shall be provided and maintained, so

as to be easily accessible during working hours, first-aid boxes
at the rate of not less than one box for 150 contract labour or
part thereof ordinarily employed.

ii. The first-aid box shall be distinctly marked with a red cross on
white back ground.

iii. Adequate arrangements shall be made for immediate

recoupment of the equipment when necessary.

iv. Nothing except the prescribed contents shall be kept in the

First-aid box.
v. The first-aid box shall be kept in charge of a responsible person
who shall always be readily available during the working hours
of the work place.
vi. A person in charge of the First-aid box shall be a person trained
in First-aid treatment, in the work places where the number of
contract labour employed is 150 or more.

19. Discoveries

19.1 Anything of historical or other interest or of significant value

unexpectedly discovered on the Site shall be the property of the
Employer. The Contractor shall notify the Engineer of
suchdiscoveries and carry out the Engineer's instructions for
dealing with them.

107
20. Possession of the Site

20.1 The Employer shall handover complete or part possession of the

site to the Contractor 7 days in advance of construction
programme. At the start of the work, the Employer shall handover
the possession of at-least 75% of the site free of all encumbrances,
the remaining 25 % of the possession as per contractor’s
construction programme.

21. Access to the Site

21.1 The Contractor shall allow access to the Site and to any place
where work in connection with the Contract is being carried out, or
is intended to be carried out to the Engineer and any
person/persons/agency authorized by: a. The Engineer b. The
Employer or authorized by the Employer.

22. Instructions

22.1 The Contractor shall carry out all instructions of the Engineer,
which comply with the applicable laws where the Site is located.

22.2 The Contractor shall permit the appointed and/or authorized

persons to inspect the Site and/or accounts and records of the
Contractor and its subcontractors relating to the performance of
the Contract, and to have such accounts and records audited by
auditors appointed, if so required. The Contractor’s attention is
invited to Clause of ‘Fraud and Corruption’, which provides, inter
alia, that acts intended to materially impede the exercise of the
inspection and audit rights provided for under the Clause &
constitute a obstructive practice subject to contract termination.

22.3 Engineer to have power to issue further drawings or instructions:

The Engineer shall have the power and authority from time to time
and at all times to make and issue such further drawings and to
give such further instructions and directions as may appear to him
necessary or proper for the guidance of the contractor and the good
and sufficient execution of the works according to terms of the
specifications and Contractor shall receive, execute, obey and be

108
 bound by the same, according to the true intent and meaning
thereof, as fully and effectually as though the same had
accompanied or had been mentioned or referred to in the
specification, and the Engineer may also alter or vary the levels or
position of nature of works contemplated by the specifications, or
may order any of the works contemplated thereby to be omitted,
with or without the substitution of any other works in lieu thereof,
or may order any work or any portion of work executed orpartially
executed, to be removed, changed or altered, added if needful, may
order that other works shall be substituted instead thereof and
difference of expense occasioned by any such diminution or
alteration so ordered and directed shall be added to or deducted
from the amount of this Contract, as provided under condition
no.10(a) hereinafter.

No work which radically changes the original nature of the

Contract shall be ordered by the Engineer and in the event of any
deviation being ordered which in the opinion of the Contractor
changes the original nature of Contract he shall nevertheless carry
it out and disagreement as to the nature of the work and the rate
to be paid therefore shall be resolved in accordance with condition
no.13d.

The time for completion of the Works, shall be in even of any

deviations resulting in additional cost over the contract price being
ordered, be extended or reduced reasonably by the Engineer. The
Engineer’s decision in this case shall be final.

B. Time Control

23. Programme

23.1 Within the time stated in the Contract Data, the Contractor shall
submit to the Engineer for approval a Programme, including
Environment Management Plan showing the general methods,
arrangements, order, and timing for all the activities in the Works,
along with monthly cash flow forecasts for the construction of
works.
109
 After the completion of the construction works, the programme for
the Routine Maintenance Work, showing the general methods,
arrangements, order and timing for all the activities involved in the
Routine Maintenance will also be submitted by the Contractor to
the Engineer for approval if specified in the tender. The programme
for Routine Maintenance will be submitted in each year for the
period of Maintenance.

23.2 The Contractor shall submit the list of equipment and machinery
being brought to site, the list of key personnel being deployed, the
list of machinery/ equipments being placed in field laboratory and
the location of field laboratory along with the Programme. The
Engineer shall cause these details to be verified at each appropriate
stage of the programme.

23.3 An update of the Programme shall be a programme showing the

actual progress achieved on each activity and the effect of the
progress achieved on the timing of the remaining Works, including
any changes to the sequence of the activities.

23.4 The Contractor shall submit to the Engineer for approval an

updated Programme at intervalsno longer than the period stated in
the Contract Data. If the Contractor does not submit an updated
Programme within this period, the Engineer may withhold the
amount stated in the Contract Data from the next payment
certificate and continue to withhold this amount until the next
payment after the date on which the overdue Programme has been
submitted.

23.5 The Engineer's approval of the Programme shall not alter the
Contractor's obligations. The Contractor may revise the Programme
and submit it to the Engineer again at any time. A revised
Programme shall show the effect of Variations and Compensation
Events.

110
24. Extension Of Time In Contracts:

Subject to any requirement in the contract as to completion of any

portions or portions of the works before completion of the whole, the
contractor shall fully and finally complete the whole of the works
comprised in the contract (with such modifications as may be directed
under conditions of this contract) by the date entered in the contract or
extended date in terms of the following clauses:

a) Extension attributable to MCGM

(i) Extension Due To Modification: If any modifications have been

ordered which in the opinion of the Engineer have materially
increased the magnitude of the work, then such extension of
the contracted date of completion may be granted as shall
appear to the Engineer to be reasonable in the circumstances,
provided moreover that the Contractor shall be responsible for
requesting such extension of the date as may be considered
necessary as soon as the cause thereof shall arise and in any
case should not be less than 30 days before the expiry of the
date fixed for completion of the works.

(ii) Extension For Delay Due To MCGM: In the event of any

failure or delay by the MCGM to hand over the Contractor
possession of the lands necessary for the execution of the
works or to give the necessary notice to commence the works
or to provide the necessary drawings or instructions or any
other delay caused by the MCGM due to any other cause
whatsoever, then such failure or delay shall in no way affect or
vitiate the contract or alter the character thereof or entitle the
contractor to damages or compensation therefore, but in any
such case, the MCGM may grant such extension(s) of the
completion date as may be considered reasonable.

Note: For extension of time period as governed in (i) and (ii)

above, any modifications in design/drawings,
specifications, quantities shall be needed to be justified
with recorded reasons with approval of Ch.Eng. for not

111
 anticipating the same while preparing estimates and
draft tender.
b) Extension Of Time For Delay Due To Contractor: The time for the
execution of the work or part of the works specified in the contract
documents shall be deemed to be the essence of the contract and
the works must be completed no later than the date(s) / the
programmefor completion of work as specified in the contract. If the
contractor fails to complete the works within the time as specified in
the contract for the reasons other than the reasons specified in
above as (a.i) and (a.ii), the MCGM may, if satisfied that the works
can be completed by the contractor within reasonable short time
thereafter, allow the contractor for further extension of time as the
Engineer may decide. On suchextension the MCGM will be entitled
without prejudice to any other right and remedy available on that
behalf, to recover the compensation as governed by Clause 8(e) of
GCC.

For the purpose of this Clause, the contract value of the works shall
be taken as value of work as per contract agreement including any
supplementary work order/contract agreement issued.

Further, competent authority while granting extension to the

currency of contract under Clause (b) of as above may also consider
levy of penalty, as deemed fit based on the merit of the case. Also,
the reasons for granting extension shall be properly documented.

25. Delays Ordered by the Engineer

25.1 The Engineer may instruct the Contractor to delay the start or
progress of any activity within the Works. Delay/delays totalling more
than 30 days will require prior written approval of the DMC/AMC.

26. Management Meetings

26.1 The Engineer may require the Contractor to attend a management

meeting. The business of a management meeting shall be to review the
plans for progress of the Works.

112
26.2 The Engineer shall record the business of management meetings and
provide copies of the record to those attending the meeting. The
responsibility of the parties for actions to be taken shall be decided by
the Engineer either at the management meeting or after the
management meeting and stated in writing to all those who attended
the meeting.
C. Quality Control

27.1. Work to be open to Inspection and Contractor or Responsible

agent to be present:All works under or in course of execution or
executed in pursuance of the contract shall at all times be open to the
inspection and supervision of the Eng-in-charge and his subordinates
and the contractor shall at all times during the usual working hours,
at all other times, during the usual working hours and at all other
times at which reasonable notice of the intention of the Eng-in-charge
and his subordinates to visit the works shall have been given to the
contractor, either himself be present to receive orders and instruction
or have responsible agent duly accredited in writing present for that
purpose. Order given to the contractors’ duly authorized agent shall
be considered to have the same force and effect as if they had been
given to the contractor himself.

27.2. Notice To Be Given Before Work Is Covered Up:

The contractor shall give not less than ten days’ notice in writing to
the Eng-In-Charge or his subordinate incharge of the work before
covering up or otherwise placing beyond the reach of measurement
any work in order that the same may be measured and correct
dimension thereof taken before the same is so covered up or placed
beyond the reach of measurements and shall not cover up or place
beyond the reach of measurement any work without the consent in
writing of the Eng-In-Charge or his subordinate incharge of the work,
and if any work shall be covered up or placed beyond the reach of
measurement, without such notice having been given or consent
obtained the same shall be uncovered at the contractors expenses,
and in default thereof no payment or allowance shall be made for such
work or for the materials with which the same was executed.

113
27.3 Works to be executed in accordance with specifications /
drawings / orders etc.:

The contractor shall execute the whole and every part of the work the
most substantial and workman like manner and both has regards
material and every other respect in strict accordance with
specifications. The contractor shall also confirm exactly, fully and
faithfully to the designs, drawings and instructions in writing relating
to the work signed by the Engineer In-charge and lodged in his office
and to which the contractor shall be entitled to have access for the
purpose of inspection at such office, or on the site or work during
office hours. The contractor shall be entitled to receive three sets of
contract drawings and working drawings as well as one certified copy
of the accepted tender along with the work order free of cost.

27.4 Ready Mix Concrete/ Asphalt Mix:

i) The contractor shall have to arrange Ready Mix concrete

(RMC)/Asphalt from RMC/ASPHALT producing plants registered
with MCGM

ii) The contractor shall, within a 7 days of award of the work,

submit a list of at least three RMC/Asphalt producers with details
of such plants including details and number of transit, mixers &
pumps etc. to be deployed indicating name of owner/company, its
location, capacity, technical establishment.

The Engineer-in-charge will reserve right to inspect at any stage

and reject the concrete if he is not satisfied about quality of
Product at the user’s end.

iii) The Engineer-in-charge reserves the right to exercise control over

the:-

a) Calibration check of the RMC/Asphalt plant.

b) Weight and quantity check on the ingredients, water and
admixtures added for batch mixing for RMC plants
c) Time of mixing of concrete/grade of asphalt.

114
 d) Testing of fresh concrete/asphalt mix, recording of results
and declaring the mix fit or unfit for use. This will include
continuous control on the work ability during production
and taking corrective action, if required.
e) For exercising such control, the Engineer-in-charge shall
periodically depute his authorized representative at the
RMC/Asphalt plant. It shall be responsibility of the
contractor to ensure that all necessary equipment,
manpower & facilities are made available to Engineer-in-
charge and or his authorized representative at RMC/Asphalt
plant.
f) All required relevant records of RMC/Asphalt mix shall be
made available to the Engineer-in-charge or his authorized
representative. Engineer-in-charge shall, as required, specify
guidelines & additional procedures for quality control &
other parameters in respect of material production&
transportation of concrete mix which shall be binding on the
contractor & the RMC/Asphalt plant. Only concrete as
approved in design mix by Engineer-in-charge shall be
produced in RMC plant and transported to the site.
g) The contactor shall have to produce a copy of chalan
receipts/SCADA reports/VTS reports as issued by the
RMC/Asphalt plant as a documentary proof in lieu of supply
of RMC/Asphalt mix before releasing payment.

28. Identifying Defects

28.1 The Engineer shall check the Contractor's work and notify the
Contractor of any Defects that are found. Such checking shall not
affect the Contractor's responsibilities. The Engineer may instruct
the Contractor to search for a Defect and to uncover and test any
work that the Engineer considers may have a Defect.

28.2 The Contractor shall permit the Employer’s technical person(s) to

check the Contractor’s work and notify the Engineer and
Contractor if any defects that are found.

115
29. Tests

29.1 For carrying out mandatory tests as prescribed in the

specifications, the Contractor shall establish field laboratory at
the location decided by Engineer. The field laboratory will have
minimum of equipments as specified in the Contract Data. The
contractor shall be solely responsible for:
a. Carrying out the mandatory tests prescribed in the
Specifications, and
b. For the correctness of the test results, whether preformed in
his laboratory or elsewhere.

29.2 If the Engineer instructs the Contractor to carry out a test not
specified in the Specification/ Quality Assurance Handbook to
check whether any work has a Defect and the test shows that it
does, the Contractor shall pay for the test and any samples. If
there is no defect, the test shall be a compensation event.

When required by the Engineer-in-charge the contractor(s) shall

supply for the purpose of testing samples of all materials
proposed to be used in the works. Samples submitted either to
govern bulk supplies or required for testing before use shall be in
suitable packages to contain them and shall be provided free of
charge by the contractor. The cost of testing shall be borne by the
contractor even if the result of the sample confirm or do not
confirm to the relevant BIS code specifications.

i. All expenditure required to be incurred for taking the

samples conveyance, packing shall be borne by the contactor
himself.

ii. The failed material shall be removed from the site by the
contractor at his own cost within a week time of written
order of the Engineer-in-charge.

116
29.3 Setting of Site Laboratories:

Contractors shall set up a laboratory at site before

commencement of work at their cost for performing various tests
and at least the following machines and equipments shall be
provided therein –

1. Set of Sieves as per I.R.C. /I.S.

2. Compressive Testing Machine(For new works)
3. Oven, Electrically Operated
4. Weighing Balance (20 kg capacity)
5. 3 m straight edge
6. Sieve shaker
7. First Aid Box
8. Measuring Jar (for silt content)
9. Other Machines/apparatus as may be directed by the
Engineer
10. VernierCaliber
11. Level / Theodolite

All the test records shall be maintained in the site office and made
available as and when required. The laboratory must be established
within 15 days from the date of receipt of the orders from Engineer In
charge. On failure to do so, a penalty of Rs 1000/- per day shall be
imposed.

The contractor shall install testing equipment at site. The contractor

shall ensure and certify the calibration of the equipment so installed
and shall maintain the same in working order throughout the period
of construction. The contractor shall also provide necessary
technically qualified experienced trained staff for carrying out such
tests for using such equipment. The tests shall be carried out under
the supervision of the Engineer-in-charge. The calibration shall be
checked every twelve months as directed by Engineer-in-charge.

117
30. Correction of Defects noticed during the Defects Liability Period.

30.1 (a) The Engineer shall give notice to the Contractor of any Defects
before the end of the Defects Liability Period, which begins at
Completion and ends after five years. The Defects Liability Period
shall be extended for as long as Defects remain to be corrected.

(b) Every time notice of Defect/Defects is given, the Contractor shall

correct the notified Defect/Defects within the duration of time
specified by the Engineer’s notice.

(c) The Engineer may issue notice to the Contractor to carry out
removal of defects or deficiencies, if any, noticed in his inspection,
or brought to his notice. The Contractor shall remove the defects
and deficiencies within the period specified in the notice and
submit to the Engineer a compliance report.

31. Uncorrected Defects and Deficiencies

31.1 If the Contractor has not corrected a Defect pertaining to the Defect
Liability Period under clause and deficiencies in maintenance, to the
satisfaction of the Engineer, within the time specified in the Engineer's
notice, the Engineer will assess the cost of having the Defect or
deficiency corrected, and the Contractor shall pay this amount, on
correction of the Defect or deficiency by another agency.

D. Cost Control

32. Variations
The Engineer shall, having regard to the scope of the Works and the
sanctioned estimated cost, have power to order, in writing, Variations
within the scope of the Works he considersnecessary or advisable
during the progress of the Works. Such Variations shall form part of
the Contract and the Contractor shall carry them out and include
them in updated Programmes produced by the Contractor. Oral orders
of the Engineer for Variations, unless followed by written
confirmation, shall not be taken into account.

118
33. Payments for Variations

33.1 If rates for Variation items are specified in the Bill of

Quantities, the Contractor shall carry out such work at the
same rate.

33.2 The rate for Extra/Excess shall be governed by clause 10.A of

Standard General Condition of Contract

34. Cash Flow Forecasts

When the Programme is updated, the Contractor shall provide the
Engineer with an updated cash flow forecast.

35. Payment Certificates

The payment to the Contractor will be as follows for construction

work:

(a) A bill shall be submitted by the Contractor monthly or before the

date fixed by the Engineer In-charge for all works executed in the
previous month, and the Engineer In-charge shall take or cause
to be taken requisite measurement for the purpose of having the
same verified and the claim, so far as it is admissible, shall be
adjusted, if possible, within 10 days from the presentation of the
bill. If the contractor does not submit the bill within the time
fixed as aforesaid, the Engineer In-charge may depute a
subordinate to measure up the said work in the presence of the
contractor or his duly authorized agent whose counter signature
to the measurement list shall be sufficient warrant, and Engineer
In-Charge may prepare a bill from such list which shall be
binding on the contractor in all respects.

(b) The Engineer shall check the Contractor's fortnightly/monthly

statement within 14 days and certify the amount to be paid to the
Contractor.

(c) The value of work executed shall be determined, based on

measurements by the Engineer.

119
 (d) The value of work executed shall comprise the value of the
quantities of the items in the Bill of Quantities completed.

(e) The value of work executed shall also include the valuation of
Variations and Compensation Events.

(f) The Engineer may exclude any item certified in a previous

certificate or reduce the proportion of any item previously
certified in any certificate in the light of later information.
(g) The contractor shall submit all bills on the printed forms at the
office of Engineer In-charge. The charges to be made in the bills
shall always be entered at the rates specified in tender.

36 Payments

36.1 Payments shall be adjusted for deductions for advance

payments, retention, security deposit, other recoveries in terms of
the Contract and taxes at source, as applicable under the law.
The Employer shall pay the Contractor the amounts certified by
the Engineer within 15 days of the date of each certificate.

36.2 All sums payable by a contractor by way of compensation under

any of these conditions, shall be considered as a reasonable
compensation to be applied to the use of MCGM without reference
to the actual loss or damage sustained and whether any damage
has or has not been sustained.

36.3 No payment shall be made for any work estimated to cost less
than Rupees One Thousand till after the whole of work shall have
been completed and the certificate of completion given. But in the
case of works estimated to cost more than Rs. One Thousand, the
contractor shall on submitting a monthly bill therefore be entitled
to receive payment proportionate to the part of the work than
approved and passed by the Engineer In-charge, whose certificate
of such approval and passing of the sum so payable shall be final
and conclusive against the contractor. All such intermediate
payments shall be regarded as payments by way of advance
against the final payments only and not as payments for work
actual done and completed and shall not preclude the Engineer
120
 In-charge from requiring any bad, unsound, imperfect or
unskilful work to be removed or taken away and reconstructed or
re-erected nor shall any such payment be considered as an
admission of the due performance of the contract or any part
thereof in any respect or the offering of any claim not shall it
conclude, determine or effect in any other way, the powers of the
Engineer In-charge as to the final settlement and adjustment of
the accounts or otherwise, or in any other way vary or effect the
contract. The final bill shall be submitted by the Contractor
within one month of the date fixed for the completion of the work
otherwise the Engineer In-charge’s certificate of the
measurements and of the total amount payable for the work shall
be final and binding on all parties.

37. The Contractor shall not be entitled to compensation to the extent that
the Employer's interests are adversely affected by the Contractor for not
having given early warning or not having cooperated with the Engineer.

38. Tax

All taxes, duties, cess and charges such as Octroi, Service Tax,
Terminal or Sales Tax, VAT etc. and other duties on material obtained
for the work from any source including the tax applicable as per
Maharashtra Sales Tax Act, on the transfer of property in goods
involved in the execution of work contract (re-enacted) Act 1989 or as
amended shall be borne by tenderer. The tenderer will not be
reimbursed the taxes, duties, cess and charges whether now in force or
that may be enforced in future.

Rates accepted by MCGM shall hold good till completion of work and no
additional individual claim shall be admissible on account of
fluctuations in market rates; increase in taxes/any other levies/tolls
etc. except that payment/recovery for overall market situation shall be
made as per Price Variation.

39. Currencies: All payments will be made in Indian Rupees.

40. Liquidated Damages

121
 Both, the Contractor and the Employer have agreed that it is not
feasible to precisely estimate the amount of losses due to delay in
completion of works and the losses to the public and the economy,
therefore, both the parties have agreed that the Contractor shall pay
liquidated damages to the Employer and not by way of penalty, at the
rate per week or part thereof stated in the Contract Data for the period
that the Completion Date is later than the Intended Completion Date.
Liquidated damages at the same rates shall be withheld if the
Contractor fails to achieve the milestones prescribed in the Contract
Data. However, in case the Contractor achieves the next milestone, the
amount of the liquidated damages already withheld shall be restored to
the Contractor by adjustment in the next payment certificate. The
Employer and the contractor have agreed that this is a reasonable
agreed amount of liquidated damage. The Employer may deduct
liquidated damages from payments due to the Contractor. Payment of
liquidated damages shall not affect the Contractor’s other liabilities.

41. Cost of Repairs

Loss or damage to the Works or Materials to be incorporated in the
Works between the Start Date and the end of the Defects Correction
periods shall be remedied by the Contractor athis cost if the loss or
damage arises from the Contractor's acts or omissions.

E. Finishing the Contract

42. Completion of Construction and Maintenance

42.1 The Contractor shall request the Engineer to issue a certificate of

completion of the construction of the works, and the Engineer will
do so upon deciding that the works is completed. This shall be
governed as per clause no.8(g) of Standard General Conditions of
Contract.

43. Taking Over

43.1 The Employer shall take over the works within seven days of the
Engineer issuing a certificate of completion of works. The

122
 Contractor shall continue to remain responsible for its routine
maintenance during the maintenance period if specified in the
contract.

44. Final Account

Final joint measurement alongwith the representatives of the contractor

should be taken recorded and signed by the Contractors. Contractors
should submit the final bill within 1 month of physical completion of
the work.

If the contractor fails to submit the final bill within 1 month, the MCGM
staff will prepare the final bill based on the joint measurement within
next 3 months.

Engineer’s decision shall be final in respect of claims for defect and

pending claims against contractors.

No further claims should be made by the Contractor after submission of

the final bill and these shall be deemed to have been waived and
extinguished. Payment of those items of the bills in respect of which
there is no dispute and of items in dispute, for quantities and rates as
approved by the Commissioner shall be made within a reasonable
period as may be necessary for the purpose of verification etc.
After payment of the final bill as aforesaid has been made, the
contractor may, if he so desires, reconsider his position in respect of a

disputed portion of the final bills and if he fails to do so within 84 days,

his disputed claim shall be dealt with as provided in the contract.

A percentage of the retention money, over and above the actual

retention money as indicated below shall be held back from payments
till the finalization of final bill to be submitted as per above and will be
paid within 30 days of acceptance of the final bill.

Sr.n Amount of Minimum Payable Amount in final bill

o. Contract Cost
1 Upto Rs.5 Crs. Rs.10 Lacs or final bill whichever is more

123
 2 Upto Rs.25 Crs. Rs.1 Crore or final bill amount whichever is more

3 UptoRs. 50 Crs. Rs.2 Crores or final bill amount whichever is

more
4 Upto Rs.100 Crs. Rs.4 Crore or final bill amount whichever is more

5 More than Rs.7 Crore or final bill amount whichever is more

Rs.100 Crs.

The contractor have to submit the bill for the work carried out within 15 days
from the date of completion of the work to the respective executing
department. If the contractor fails to submit their bills to concerned
executing department, penalty or action as shown below will be taken for
each delayed bill:-

After 15 days from the date of Equal to 5% of bill amount

completion/running bill upto certain date, upto
next 15 days i.e. upto 30 days
Next 15 days upto 45 days from the date of Equal to 10% of bill amount
completion/running bill upto specified date
If not submitted within 45 days from the date of Bill will not be admitted for
completion/ R.A. bill payment.

45. Operating and Maintenance Manuals

45.1 If "as built" Drawings and/or operating and maintenance

manuals are required, the Contractor shall supply them by the
dates stated in the Contract Data.

45.2 If the Contractor does not supply the Drawings and/or manuals
by the dates stated in the Contract Data, or they do not receive
the Engineer's approval, the Engineer shall withhold the amount
stated in the Contract Data from payments due to the Contractor.

46. Termination

46.1 The Employer or the Contractor may terminate the Contract if the
other party causes a fundamental breach of the Contract.

124
46.2 Fundamental breaches of Contract shall include, but shall not be
limited to, the following:

a) the Contractor stops work for 30 days when no stoppage of

work is shown on the current Programme and the stoppage
has not been authorized by the Engineer;

b) the Contractor is declared as bankrupt or goes into liquidation

other thanfor approved reconstruction or amalgamation;

c) the Engineer gives Notice that failure to correct a particular

Defect is a fundamental breach of Contract and the Contractor
fails to correct it within a reasonable period of time determined
by the Engineer;

d) the Contractor does not maintain a Security, which is required;

e) the Contractor has delayed the completion of the Works by the

number of days for which the maximum amount of liquidated
damages can be paid, as defined in relevant clause.

f) the Contractor fails to provide insurance cover as required

under relevant clause .

g) if the Contractor, in the judgment of the Employer, has

engaged in the corrupt or fraudulent practices as defined in
GCC in competing for or in executing the Contract.

h) if the Contractor fails to set up a field laboratory with the

prescribed equipment, within the period specified in the
Contract Data; and

i) any other fundamental breaches as specified in the Contract

Data.

j) if the Contractor fails to deploy machinery and equipment or

personnel as specified in the Contract Data at the appropriate
time.

46.3 When either party to the contract gives notice of a breach of

contract to the Engineer for a cause other than those listed

125
 above, the Engineer shall decide whether the breach is
fundamental or not.

46.4 Notwithstanding the above, the Employer may terminate the

Contract for convenience.

46.5 If the Contract is terminated, the Contractor shall stop work

immediately, make the Site safe and secure, and leave the Site as
soon as reasonably possible.

47. Payment upon Termination

47.1 If the Contract is terminated because of a fundamental breach of

Contract by the Contractor, the Engineer shall issue a certificate
for value of the work done and materials ordered less liquidated
damages, if any, less advance payments received up to the date of
the issue of the certificate and less the percentage to apply to the
value of the work not completed, as indicated in the Contract
Data. If the total amount due to the Employer exceeds any
payment due to the Contractor, the difference shall be recovered
from the security deposit, and performance security. If any
amount is still left un-recovered it will be a debt due from the
Contractor to the Employer

47.2 If the Contract is terminated at the Employer's convenience, the

Engineer shall issue a certificate for the value of the work done,
the reasonable cost of removal of Equipment, repatriation of the
Contractor's personnel employed solely on the Works, and the
Contractor's costs of protecting and securing the Works and less
advance payments received up to the date of the certificate, less
other recoveries due in terms of the Contract, and lesstaxes due
to be deducted at source as per applicable law.

48. Property

48.1 All Materials on the Site, Plant, Equipment, Temporary Works,

and Works shall be deemed to be the property of the Employer for
use for completing balance construction work if the Contract is
terminated because of the Contractor's default, till the Works is

126
 completed after which it will be transferred to the Contractor and
credit, if any, given for its use.

49. Release from Performance

If the Contract is frustrated by the outbreak of war or by any other

event entirely outside the control of the Employer or the Contractor,
the Engineer shall certify that the Contract has been frustrated. The
Contractor shall make the Site safe and stop work as quickly as
possible after receiving this certificate and shall be paid for all work
carried out before receiving it and for any work carried out afterwards
to which a commitment was made.

A) Other Conditions of Contract

50. Labour

50.1 The Contractor shall, unless otherwise provided in the Contract,

make his own arrangements for the engagement of all staff and
labour, local or other, and for their payment, housing, feeding
and transport.

50.2 The Contractor shall, if required by the Engineer, deliver to the

Engineer a return in detail, in such form and at such intervals as
the Engineer may prescribe, showing the staff and the number of
the several classes of labour from time to time employed by the
Contractor on the Site and such other information as the
Engineer may require.

51. Compliance with Labour Regulations

(a) During continuance of the Contract, the Contractor and his sub-
Contractors shall abide at all times by all existing labour
enactments and rules made there under, regulations, notifications
and bye laws of the State or Central Government or local authority
and any other labour law (including rules), regulations, bye laws
that may be passed or notification that may be issued under any
labour law in future either by the State or the Central Government
or the local authority.

127
 (b) Furthermore, the Contractor shall keep the Employer indemnified in
case any action is taken against the Employer by the competent
authority on account of contravention of any of the provisions of
any Act or rules made there under, regulations or notifications
including amendments. If the Employer is caused to pay or
reimburse, such amounts as may be necessary to cause or observe,
or for non-observance of the provisions stipulated in the
notifications/ bye-laws/Acts/Rules/regulationsincluding
amendments, if any, on the part of the Contractor, the
Engineer/Employer shall have the right to deduct any money due to
the Contractor including his amount of performance guarantee. The
Employer/Engineer shall also have right to recover from the
Contractor any sum required or estimated to be required for making
good the loss or damage suffered by the Employer.

(c) The Contractor shall require his employees to obey all applicable
laws, including those concerning safety at work.

(d) The employees of the Contractor and the Sub-Contractor in no case

shall be treated as the employees of the Employer at any point of
time.

52. Drawings and Photographs of the Works

52.1 The Contractor shall do photography/video photography of the

site firstly before the start of the work, secondly mid-way in the
execution of different stages of work as required by Engineer In-
charge and lastly after the completion of the work. No separate
payment will be made to the Contractor for this.

52.2 The Contractor shall not disclose details of Drawings furnished to

him and works on which he is engaged without the prior approval
of the Engineer in writing. No photograph of the works or any
part thereof or plant employed thereon, except those permitted
under above clause, shall be taken or permitted by the Contractor
to be taken by any of his employees or any employees of his sub-
Contractors without the prior approval of the Engineer in writing.
No photographs/ Video photography shall be published or

128
 otherwise circulated without the approval of the Engineer in
writing.

53. The Apprentices Act, 1961

The Contractor shall duly comply with the provisions of the Apprentices
Act 1961 (III of 1961), the rules made there under and the orders that
may be issued from time to time under the said Act and the said Rules
and on his failure or neglect to do so, he shall be subject to all liabilities
and penalties provided by the said Act and said Rules.

54 Contract Document

The documents forming the contract are to be taken as mutually

explanatory of one another. Unless otherwise provided in the contract,
the priority of the documents forming the contract shall be, as follows:
1) Contract Agreement (if completed)
2) The letter of Acceptance
3) The Bid:
4) Addendum to Bid; if any
5) Tender Document
6) The Bill of Quantities:
7) The Specification:
8) Detailed Engineering Drawings
9) Standard General Conditions of Contracts (GCC)
10) All correspondence documents between bidder/contractor and
MCGM.

55 Conflict of Interest

The Applicant shall not have a conflict of interest (the “Conflict of

Interest”) that affects the Bidding Process. Any Applicant found to have
a Conflict of Interest shall be disqualified. An Applicant shall be deemed
to have a Conflict of Interest affecting the Bidding Process, if

1. A constituent of such Applicant is also a constituent of another

Applicant; or

2. Such Applicant has the same legal representative for purposes of

this Application as any other Applicant; or
129
 3. Such Applicant, or any Associate thereof has a relationship with
another Applicant, or any Associate thereof, directly or through
common third party/ parties, that puts either or both of them in a
position to have access to each other’s information about, or to
influence the Application of either or each other; or

4. The Applicant shall be liable for disqualification if any legal, financial

or technical adviser of the Authority in relation to the Project is
engaged by the Applicant, its Member or any Associate thereof, as the
case may be, in any manner for matters related to or incidental to the
Project. For the avoidance of doubt, this disqualification shall not
apply where such adviser was engaged by the Applicant, its Member
or Associate in the past but its assignment expired or was terminated
6 (six) months prior to the date of issue of this TENDER. Nor will this
disqualification apply where such adviser is engaged after a period of
3 (three) years from the date of commercial operation of the Project.

56. Applications and costs thereof

No Applicant shall submit more than one Application for the Project. An
applicant applying individually shall not be entitled to submit another
application either individually. The Applicant shall be responsible for all
of the costs associated with the preparation of their Applications and
their participation in the Bid Process. The Authority will not be
responsible or in any way liable for such costs, regardless of the
conduct or outcome of the Bidding Process.

57. Acknowledgment by Applicant

It shall be deemed that by submitting the Application, the Applicant

has:

a. made a complete and careful examination of the tender;

b. received all relevant information requested from the Authority;

c. accepted the risk of inadequacy, error or mistake in the

information provided in the tender or furnished by or on behalf of
the Authority relating to any of the matters referred; and
130
 d. Agreed to be bound by the undertakings provided by it under and
in terms hereof. “The Authority” shall not be liable for any
omission, mistake or error in respect of any of the above or on
account of any matter or thing arising out of or concerning or
relating to the TENDER or the Bidding Process, including any error
or mistake therein or in any information or data given by the
Authority.

58. Right to accept or reject any or all Applications/ Bids

Notwithstanding anything contained in this TENDER, “The Authority”

reserves the right to accept or reject any Application and to annul the
Bidding Process and reject all Applications/ Bids, at any time without
any liability or any obligation for such acceptance, rejection or
annulment, and without assigning any reasons therefore. In the event
that the Authority rejects or annuls all the Bids, it may, in its
discretion, invite all eligible Bidders to submit fresh Bids hereunder.

“The Authority” reserves the right to reject any Application and/ or Bid
if:
a. at any time, a material misrepresentation is made or uncovered, or
b. the Applicant does not provide, within the time specified by the
Authority, the supplemental information sought by the Authority
for evaluation of the Application.
In case it is found during the evaluation or at any time before signing
of the Agreement or after its execution and during the period of
subsistence thereof including the concession thereby granted by “The
Authority”, that one or more of the pre-qualification conditions have
not been met by the Applicant, or the Applicant has made material
misrepresentation or has given any materially incorrect or false
information, the Applicant shall be disqualified forthwith if not yet
appointed as the Successful Bidder either by issue of the LOA (Letter
of Approval) or entering into of the Agreement, and if the Applicant
has already been issued the LOA or has entered into the Concession
Agreement, as the case may be, the same shall, notwithstanding
131
 anything to the contrary contained therein or in this TENDER, be
liable to be terminated, by a communication in writing by “The
Authority” to the Applicant, without the Authority being liable in any
manner whatsoever to the Applicant and without prejudice to any
other right or remedy which the Authority may have under this
TENDER, the Bidding Documents, the Concession Agreement or
under applicable law.
“The Authority” reserves the right to verify all statements, information
and documents submitted by the Applicant in response to the
TENDER. Any such verification or lack of such verification by the
Authority shall not relieve the Applicant of its obligations or liabilities
hereunder nor will it affect any rights of the Authority there under.

59 The bid shall be rejected if the bidder-

a. Stipulates the validity period less than 180 days.

b. Stipulates own condition/conditions.

c. Does not fill and (digital) sign undertaking forms, which are
incorporated, in the document.

60 Clarifications

Applicants requiring any clarification on the tender may notify “the

Authority” in writing or by fax or e-mail. They should send in their
queries before the date specified in the header data. “The Authority”
shall Endeavour to respond to the queries within the period specified
therein. The responses will be sent by fax and/or e-mail. The Authority
will forward all the queries and its responses thereto, to all purchasers
of the TENDER without identifying the source of queries.

“The Authority” shall Endeavour to respond to the questions raised or

clarifications sought by the Applicants. However, the Authority reserves
the right not to respond to any question or provide any clarification, in
its sole discretion, and nothing in this Clause shall be taken or read as
compelling or requiring the Authority to respond to any question or to

132
 provide any clarification, but not later than the date provided in header
data.
“The Authority” may also on its own motion, if deemed necessary, issue
interpretations and clarifications to all Applicants. All clarifications and
interpretations issued by the Authority shall be deemed to be part of
the tender. Verbal clarifications and information given by Authority or
its employees or representatives shall not in any way or manner be
binding on the Authority.

61 Amendment of tender

At any time prior to the deadline for submission of Application, the

Authority may, for any reason, whether at its own initiative or in
response to clarifications requested by an Applicant, modify the tender
by the issuance of Addendum.

Any Addendum thus issued will be sent in writing/ Fax/ Email to all
those who have purchased the tender.

In order to afford the Applicants a reasonable time for taking an

Addendum into account, or for any other reason, the Authority may, in
its sole discretion, extend the Application Due Date.

Preparation and Submission of Application

62 Language

The Application and all related correspondence and documents in

relation to the Bidding Process shall be in English language. Supporting
documents and printed literature furnished by the Applicant with the
Application may be in any other language provided that they are
accompanied by translations of all the pertinent passages in the
English language, duly authenticated and certified by the Applicant.
Supporting materials, which are not translated into English, may not be
considered. For the purpose of interpretation and evaluation of the
Application, the English language translation shall prevail.

63 Format and signing of Application

133
 The Applicant shall provide all the information sought under this
TENDER. The Authority will evaluate only those Applications that are
received in the required formats and complete in all respects.
Incomplete and /or conditional Applications shall be liable to rejection.

The Applicant will upload bid in One Folder in electronic form which
shall contain the scanned certified copies of the documents given below
and the documents uploaded has to be digitally signed by the bidder.
These copies shall be certified by Practicing Notary approved by the
Govt. of Maharashtra or Govt. of India with his stamp, clearly stating
hisname& registration number, except where original documents are
demanded

64 Marking of Applications

The Applicant shall submit the Application in the format specified at

Appendix-I, together with the documents, upload in folder as
“VENDOR” together with their respective enclosures
Applications submitted by fax, telex, telegram shall not be entertained
and shall be rejected outright.

65 Late Applications

Applications received by the Authority after the specified time on the

Application Due Date shall not be eligible for consideration and shall be
summarily rejected.

66 Confidentiality

Information relating to the examination, clarification, evaluation, and

recommendation for the short-listed qualified Applicants shall not be
disclosed to any person who is not officially concerned with the process
or is not a retained professional advisor advising the Authority in
relation to or matters arising out of, or concerning the Bidding Process.
The Authority will treat all information, submitted as part of
Application, in confidence and will require all those who have access to
such material to treat the same in confidence. The Authority may not

134
 divulge any such information unless it is directed to do so by any
statutory entity that has the power under law to require its disclosure
or is to enforce or assert any right or privilege of the statutory entity
and/ or the Authority or as may be required by law or in connection
with any legal process.

67 Clarification Of Financial Bids

To assist in the examination, evaluation and comparison of Bids, the

Engineer may, at his discretion, ask any bidder for clarification of his
Bid, including breakdown of unit rates. The request for clarification and
the response shall be in writing or by post/facsimile/e-mail. No Bidder
shall contact the Engineer on any matter relating to his bid from the
time of the bid opening to the time the contract is awarded. Any effort
by the Bidder to influence the Engineer in the Engineer’s bid
evaluation, bid comparison or contract award decisions may result in
the rejection of the Bidder’s bid.

68 Inspection of site and sufficiency of tender:

1. The Contractor shall inspect and examine the site and its
surrounding and shall satisfy himself before submitting his tender
as to the nature of the ground and subsoil (so far as is practicable),
the form and nature of the site, the quantities and nature of the
work and materials necessary for the completion of the works and
means of access to the site, the accommodation he may require and
in general shall himself obtain all necessary information as to risk,
contingencies and other circumstances which may influence or affect
his tender. He shall also take into consideration the hydrological and
climatic conditions.

2. The Employer may make available to the Contractor data on

hydrological and sub-surface conditions as obtained by or on his
behalf from investigations relevant to the works but the Contractor
shall be responsible for his own interpretation thereof. The contractor
shall engage his investigating agency with prior approval of the
Engineer from the approved list of such agencies by MCGM or Govt at
his cost initially before commencing actual work and which shall be

135
 reimbursed immediately subject to satisfaction of the Engineer for
faithful compliance and submission of required data regarding such
investigation within specified time.
3. The Contractor shall be deemed to have satisfied himself before
tendering as to the correctness and sufficiency of his tender for the
works and of the rates and prices quoted in the schedule of works /
items / quantities, or in Bill of Quantities, which rates and prices
shall, except as otherwise provided cover all his obligations under the
Contract and all matters and things necessary for proper completion
and maintenance of the works. No extra charges consequent on any
misunderstanding.
4. Not Foreseeable Physical Obstructions or Conditions: If, however,
during the execution of the Works the Contractor encounters physical
obstructions or physical conditions, other than climatic conditions on
the Site, which obstructions or conditions were, in his opinion, not
foreseeable by an experienced contractor, the Contractor shall
forthwith give notice thereof to the Engineer. On receipt of such
notice, the Engineer shall, if in his opinion such obstructions or
conditions could not have been reasonably foreseen by an experienced
contractor, after due consultation with the Contractor, determine:

 any extension of time to which the Contractor is entitled and

 The amount of any costs which may have been incurred by the
Contractor by reason of such obstructions or conditions having been
encountered, which shall be added to the Contract Price.

 and shall notify the Contractor accordingly. Such determination

shall take account of any instruction which the Engineer may issue
to the Contractor in connection therewith, and any proper and
reasonable measures acceptable to the Engineer which the
Contractor may take in the absence of specific instructions from the
Engineer.However such costings shall be got approved by the
competent authority as governed vide rules prevailing with authority.

5. Office for the Engineer (Works costing upto Rs.50 Lakhs)

136
 The Contractor shall at his own cost and to satisfaction of the
Engineer provide a small temporary office, at the work-site which
will include tables, chairs and lockers for keeping the records. He
shall also make necessary arrangements for drinking water,
telephone with a pre-requisite of e-governance and electronic
communication. These offices are not to be allowed on public roads
without the written instruction of the Engineer. These offices should
be preferably located within 50 to 500 m of the worksite. In case the
office is more than 500m away from the worksite, the contractor is to
provide conveyance for Municipal Staff.

6. Office for the Engineer (Works costing above Rs.50 lakhs)

The Contractor shall at his own cost and to satisfaction of the

Engineer provide a temporary office at the work-site which will
include tables, chairs and lockers for keeping the records. He shall
also make necessary arrangements for drinking water, latrines, with
doors, windows, locks, bolts and fastenings sufficient for security for
the Engineer, and his subordinates, as close to the works from time
to time in progress as can be conveniently arranged, and shall at his
own cost furnish the office with such chairs, tables, lockers, locks
and fastenings as may be required by the Engineer, and no expense
of any kind in connection with the erection or upkeep of the offices
or fittings shall be borne by the Corporation, but all such work shall
be carried out by the Contractor and the expenses thereof defrayed
by him. The Contractor shall also make water connections and fit up
stand pipe with a bib tap at each office. The latrines and the water
connections shall be subject to all the conditions herein elsewhere
laid down for temporary water connection and latrines generally with
all requisite equipments for e-governance and electronic and digital
communication. These offices are not to be allowed on public roads
without the written instruction of the Engineer. These offices should
be preferably located within 50 to 500 m of the worksite. In case the
office is more than 500m away from the worksite, the contractor is to
provide conveyance. Also, for staff working beyond working hours
the contractor has to provide conveyance.

137
 7. Permission for provision and removal of office on completion of
work: The tenderer shall obtain permission for provision of site
office, cement go-down, store, etc. on payment of necessary cost
implication. The cement go-down, Watchman cabins, etc. shall be
provided as directed and shall be removed by the Tenderers on
completion of the work at their cost. It is binding on the Tenderer to
fulfill requirements of Environmental Authorities. The location of
such office shall be finalized and got approved from the Engineer
before erection/commencement work.

8. Contractor’s office near works: The Contractor shall have an office

near the works at which notice from the Commissioner or the
Engineer may be served and shall, between the hours of sunrise and
sunset on all working days, have a clerk or some other authorized
person always present at such office upon whom such notices may
be served and service of any notices left with such clerk or other
authorized person or at such office shall be deemed good service
upon the Contractor and such offices shall have pre-requisite
facilities for e-governance.

69 Official Secrecy:

The Contractor shall of all the persons employed in any works in

connection with the contract that the India Official Secrets Act 1923
(XIX of 1923) applies to them and will continue to apply even after
execution of the said works and they will not disclose any information
regarding this contract to any third party. The contractor shall also
bring into notice that, any information found to be leaked out or
disclosed the concern person as well as the Contractor will be liable for
penal action; further the Corporation will be at liberty to terminate the
contract without notice.

138
70 Subsequent Legislation:

If on the day of submission of bids for the contract, there occur changes
to any National or State stature, Ordinance, decree or other law or any
regulation or By-laws or any local or other duly constituted authority or
the introduction of any such National or State Statute, Ordinance,
decree or by which causes additional or reduced cost to the Contractor,
such additional or reduced cost shall, after due consultation with the
Contractor, be determined by the concerned Engineering Department of
MCGM and shall be added to or deducted from the Contract Price with
prior approval of competent authority and the concerned Engineering
Department shall notify the Contractor accordingly with a copy to the
Employer. MCGM reserve the right to take decision in respect of
addition/reduction of costing contract.

71 Patent, Right and Royalties:

The contractor shall save harmless and indemnify the Corporation from
and against all claims and proceedings for or on account of
infringement of any Patent rights, design trademark or name of other
protected rights in respect of any constructional plant, machine work,
or material used for or in connection with the Works or any of them and
from and against all claims, proceedings, damages, costs, charges and
expenses whatsoever in respect thereof or in relation thereto. Except
where otherwise specified, the contractor shall pay all tonnage and
other royalties, rent and other payments or compensation, if any, for
getting stone, sand, gravel, clay or other materials required for the
works or any of them.

72 Payments, Tax and Claims:

 The limit for unforeseen claims

Under no circumstances whatever the contractor shall be entitled to

any compensation from MCGM on any account unless the contractor
shall have submitted a claim in writing to the Eng-in-change within 1
month of the case of such claim occurring.

 No interest for delayed payments due to disputes, etc:

139
 It is agreed that the Municipal Corporation of Greater Mumbai or its
Engineer or Officer shall not be liable to pay any interest or damage
with respect of any moneys or balance which may be in its or its
Engineer’s or officer’s hands owing to any dispute or difference or claim
or misunderstanding between the Municipal Corporation of Greater
Bombay or its Engineer or Officer on the one hand and the contractor
on the other, or with respect to any delay on the part of the Municipal
Corporation of Greater Bombay or its Engineer or Officers in making
periodical or final payments or in any other respect whatever.
73 Settlement of Disputes:

 Termination of contract for death

If the Contractor is an individual or a proprietary concern and the

individual or the proprietor dies and if the Contractor is a partnership
concern and one of the legal representative of the individual Contractor
or the proprietor of the proprietary concern and in case of partnership,
the surviving partners, are capable of carrying out and completing the
contract, the Commissioner shall be entitled to cancel the contract as to
its uncompleted part without the Corporation being in any way liable to
payment of any compensation to the estate of the deceased Contractor
and or to the surviving partners of the Contractor’s firm on account of
the cancellation of the contract. The decision of the Commissioner that
thelegal representative of the deceased Contractor or surviving partners
of the Contractor’s firm cannot carry out and complete the contract
shall be final and binding on the parties. In the event of such
cancellation the Commissioner shall not hold estate of the deceased
Contractor and or surviving partners of the Contractor’s firm liable in
damages for not completing the contract.

 Settlement of Disputes:

If any dispute or differences of any kind whatsoever other than those in

respect of which, the decision of any person is, by the Contract,
expressed to be final and binding) shall arise between the Employer and
the Contractor or the Engineer and the Contractor in connection with or
arising out of the Contract or carrying out of the Works (Whether during

140
 the progress of the Works or after their completion and whether before
or after the termination, abandonment or breach of the Contract) it, the
aggrieved party may refer such dispute within a period of 7 days to the
concerned Addl. Municipal Commissioner who shall constitute a
committee comprising of three officers i.e. concerned Deputy Municipal
Commissioner or Director (ES&P), Chief Engineer other than the
Engineer of the Contract and concerned Chief Accountant. The
Committee shall give decision in writing within 60 days. Appeal on the
Order of the Committee may be referred to the Municipal Commissioner
within 7 days. Thereafter the Municipal Commissioner shall constitute
a Committee comprising of three Addl. Municipal Commissioners
including Addl. Municipal Commissioner in charge of Finance
Department. The Municipal Commissioner within a period of 90 days
after being requested to do so shall give written notice of committee’s
decision to the Contractor. Save as herein provided such decision in
respect of every matter so referred shall be final and binding upon both
parties until the completion of the works, and shall forthwith be given
effect to by the Contractor who shall proceed with the works with due
diligence, whether he requires arbitration as hereinafter provided or
not. If the Commissioner has given written notice of the decision to the
Contractor and no Claim to arbitration has been communicated within
a period of 90 days from receipt of such notice the said decision shall
remain final and binding upon the Contractor.
74 Arbitration and Jurisdiction:

If the Commissioner shall fail to give notice of the decision as aforesaid

within a period of 90 days after being requested as aforesaid, or if the
Contractor be dissatisfied with any such decision, then and in any such
case the Contractor may within 90 days after receiving notice of such
decision or within 90 days after the expirations of the first named
period of 90 days (as the case may be) require that the matter or
matters in dispute be referred to arbitration ashereinafter provided. All
disputes or differences in respect of which the decision (if any) of the
Commissioner has not become final and binding as aforesaid shall be
finally settled by Arbitration as follows:

141
 Arbitration shall be effected by a single arbitrator agreed upon the
parties. The arbitration shall be conducted in accordance with the
provisions of the Arbitration Act, 1996 or any statutory modifications
thereof, and shall be held at such place and time within the limits of
BrihanMumbai as the arbitrator may determine. The decision of the
arbitrator shall be final and binding upon the parties hereto and the
expense of the arbitration shall be paid as may be determined by the
arbitrator. Performance under the Contract shall, if reasonably be
possible, continued during the arbitration proceedings and payment
due to the Contractor by the Employer shall not be withheld unless
they are the subject matter of arbitration proceedings. The said
arbitrator shall have full power to open up, review and revise any
decision, opinion, direction, certification or valuation of the
Commissioner and neither party shall be limited in the proceedings
before such arbitrator to the evidence or arguments put before the
Commissioner for the purpose of obtaining his said decision. No
decision given by the Commissioner in accordance with the foregoing
provisions shall disqualify him from being called as a witness and giving
evidence before the arbitrator on any matters whatsoever relevant to the
disputes or difference referred to the arbitrator as aforesaid. All awards
shall be in writing and for claims equivalent to 5,00,000 or more such
awards shall state reasons for amounts awarded. The expenditure of
arbitration shall be paid as may be determined by arbitrator.
In case of any claim, dispute or difference arising in respect of a
contract, the cause of action thereof shall be deemed to have arisen in
Mumbai and all legal proceedings in respect of any claim, dispute or
difference shall be instituted in a competent court in the City of
Mumbai only.

75 Copyright:

The copyright of all drawings and other documents provided by the

Contractor under the contract shall remain vested in the Contractor or
his sub-contractors as the case may be the employer shall have a
license to use such drawings and other documents in connection with
the design, construction, operation, maintenance of the works. At any
142
 time the Employer shall have further license without additional
payment to the Contractor to use any such drawings or documents for
the purpose of making any improvement of the works or enlargement or
duplication of any part thereof, provided that such improvement,
enlargement, or duplication by itself or in conjunction with any other
improvements,enlargements or duplications already made in
accordance with the further license does not result in the duplication of
the whole works.
76. Receipts to be signed in firm’s name by any one of the partners:

Every receipt for money which may become payable or for any security
which may become transferable to the Contractor under these present
shall, if signed in the partnership name by any one of the partners, be a
good and sufficient discharge to the Commissioner and Municipal
Corporation in respect of the money or security purporting to be
acknowledged thereby, and in the event of death of any of the partners
during the pendency of this contract, it is hereby expressly agreed that
every receipt by any one of the surviving partners shall, if so signed as
aforesaid, be good and sufficient discharge as aforesaid provided that
nothing in this clause contained shall be deemed to prejudice or effect
any claim which the Commissioner or the Corporation may hereafter
have against the legal representatives of any partners so dying or in
respect of any breach of any of the conditions thereof, provided also
that nothing in this clause contained shall be deemed prejudicial or
affect the respective rights or obligations of the Contractors and of the
legal representatives of any deceased Contractors interest.

77 Proprietary data

All documents and other information supplied by the Authority or

submitted by an Applicant to the Authority shall remain or become the
property of the Authority. Applicants are to treat all information as
strictly confidential and shall not use it for any purpose other than for
preparation and submission of their Application. The Authority will not
return any Application or any information provided along therewith.

143
78 Correspondence with the Applicant

Save and except as provided in this TENDER, the Authority shall not
entertain any correspondence with any Applicant in relation to the
acceptance or rejection of any Application.

79 Price Variation Clause

The Contractor shall be reimbursed or shall refund to the Corporation

as he case may be the variation in the value of the work carried out
from time to time, depending on whether the prices of material and
labour as a whole rise or fall, and the method adopted for such
computations shall be as given below, it being clearly understood that
the contractor shall have no claim for being reimbursed on the ground
that the price of a particular material orgroup of materials have risen
beyond the limits of the presumptions made in the following paras,
however, no price variations shall be made applicable for contracts upto
12 months:
A) Controlled materials: Price variations shall be permitted in respect
of these materials the price level of which is controlled by the
Government or its agency. The rate ruling on the date of
submission of the tender shall be considered as the basic price of
such material for adjustment. Any variation in this rate shall be
considered for reimbursement to the contractor or refund to be
claimed from the contractor as the case may be. The contractor
shall, for the purpose of adjustment submit in original the relevant
documents from the suppliers.

B) Labour and other materials: For the purpose of this contract and
for allowing reimbursement of refund on account of variation of
prices of (i) labour, and (ii) materials other than materials
mentioned in A above, computation will be based on the formula
enunciated below which is based on the presumptions that :

i) The general price level of labour, rises or falls in proportion to the

rise or fall of consumer price index number 9 (general) for working
class in Mumbai.
144
 ii) The general price level of materials rises or falls in proportion to
rise or fall of whole-sale price index as published by ‘Economic
Adviser to Govt. of India’.

iii) And that the component of labour is to the extent of 30 percent of

88 percent and the component of materials is to the extent of 70
percent of 88 percent of the value of the work carried out. The
remaining 12 percent being the presumptive profit of the
contractor.

a) Formula for Labour component:

VL = (0.88 R) x 30x (I – IO)

------------------------------------
100 IO
b) Formula for Material component :

VM = (0.88 R x 70 - C) x (W – WO)
-----------------------------------------
100 WO
Where –

VL = Amount of price variation to be reimbursed or claimed as refund on

account of general rise or fall of index referred to above.

I= Consumer Price Index number of working class for Mumbai (declared

by the Commissioner of Labour and Director of Employment, Mumbai)
applicable to the period under reference (base year ending 2004-05 as
100 i.e. new series of indices).

IO = Consumer price index number for working class for Mumbai (declared
by the Commissioner of labour and Director of Employment, Mumbai)
prevailing, on the day of 28 days prior to the date of submission of the
tender.

VM = The amount of price variation to be reimbursed or claimed as refund

on account of general rise or fall of wholesale price index for period
under reference.

W= Average wholesale price index as published by Economic Adviser to

Govt. of India applicable to the period under reference.

145
WO = Wholesale price index as stated above prevailing on the day of 28 days
prior to the date of submission of the tender.

R= Total value of the work done during the period under reference as
recorded in the Measurement Book excluding water charges and
sewerage charges but including cost of excess in respect of item upto
50 percent

C= Total value of Controlled materials used for the works as recorded in

Measurement Book and paid for at original basic rate plus the value of
materials used .
i) The quantity of the Controlled material adopted in working out the
value of ‘C’ shall be inclusive of permitted wastages as / if
mentioned in specifications.
ii) The basic rate for the supply of controlled material shall be
inclusive of all the components of cost of materials excluding
transport charges incurred for bringing the material from place of
delivery to the site.

Computations based on the above formula will be made for the

period of each bill separately and reimbursement will be made to
(when the result is plus) and refund will claimed from (when the
result is minus) the contractor’s next bill. The above formulae will
be replaced by the formulae in Annexure-I as and when mentioned
in special conditions of contract

The operative period of the contract for application of price

variation shall mean the period commencing from the date of
commencement of work mentioned in the work order and ending
on the date when time allowed for the work order and ending on
the date when time allowed for the work specified in the contract
for work expires, taking into consideration, the extension of time, if
any, for completion of the work granted by Engineer under the
relevant clause of the conditions of contract in cases other than
those where such extension is necessitated on account of default of
the contractor.

146
 The decision of the Engineer as regards the operative period of the
contract shall be finaland binding on the contractors.

iii) Where there is no supply of controlled items to contractor the

component ‘C’ shall be taken as zero.

C) Adjustment after completion: If the Contractor fails to complete the

works within the time for completion adjustment of prices thereafter
until the date of completion of the works shall be made using either the
indices or prices relating to the prescribed time for completion, or the
current indices or prices whichever is more favourable to the employer,
provided that if an extension of time is granted, the above provision
shall apply only to adjustments made after the expiry of such extension
of time.

D) Price variation will be calculated similarly and separately for extra items
and / or excess quantities and provisional sums calculated under Sub
Clause 10 (b)A (i)&(ii) and Sub Clause 10 (b) B(ii) based on the above
formula/formulae in Annexure-I as and when mentioned in Special
conditions of contract; IO and WO being the indices applicable to the
date on which the rates under Sub Clause 10 (a)A (i)&(ii) and Sub
Clause 10 (a) B(iii) are fixed. No price variation shall be admissible for
FAIR items created during execution.

80. Maximum Price Variation shall be as follows:

Time Period of Project Maximum limit of Price Variation

Up to 12 months No variation allowed

Above12 months to 24 months 5%

Above 24 months 10%

Note: 1) The extension in time period for the projects originally

estimated including monsoon results in change of price
variation slabs as mentioned above i.e.from first slab to second
slab or from second slab to third slab, then the maximum limit
of original slab will prevail.

147
 2)Operative period shall mean original or extended time period of
contract.

For example:
Extension of Time period Maximum Price Variation

If original period of 11 months No variation allowed

including monsoon extends to
16. The operative period will be
11+5 months.
If original period of 11 months Maximum 5% variation allowed
excluding monsoon extends to
16. The operative period will be
11+5 months.

Price Variation during Extended Period of Contract:

(i) Extension Due To Modification & Extension for delay due to MCGM :
The price variation for the period of extension granted shall be limited
to the amount payable as per the Indices. In case the indices increases
or decreases, above/below the indices applicable, to the last month of
the original or extended period vide clause8(l)(a)(i) and (ii) of standard
GCC

(ii) Extension Of Time For Delay Due To Contractor:

(a) The price variation for the period of extension granted shall be
limited to the amount payable as per the Indices in case the indices
increase, above the indices applicable, to the last month of the
original completion period or the extended period vide above clause
8(l)(a)(i) and (ii) of standard GCC.

(b) The price variation shall be limited to the amount payable as per the
indices, in case the indices decrease or fall below the indices
applicable, to the last month of original / extended period of
completion period vide above clause 8(l)(b) of standard GCC, then
lower indices shall be adopted.
(iii) Extension of Time For Delay due to reasons not attributable to MCGM
and Contractor (Reference Cl.8(d) of Standard GCC):

148
 The price variation for the period of extension granted shall be limited
to the amount payable as per the Indices in case the indices increases
or decreases, above/below the indices applicable, to the last month of
the original period.

81.Payment:
Interim Payment:

i) Interim bills shall be submitted by the Contractor from time to time

(but at an interval of not less than one month) for the works
executed. The Engineer shall arrange to have the bill s verified by
taking or causing to be taken, where necessary, the requisite
measurement of work.

ii) Payment on account for amount admissible shall be made on the

Engineer certifying the sum to which the Contractor is considered
entitled by way of interim payment for all the work executed, after
deducting there from the amount already paid, the security deposit /
retention money and such other amounts as may be deductible or
recoverable in terms of the contract.

iii) On request, the contractor will be paid upto 75 percent of the value
of the work carried out as an adhoc payment in the first week of next
month after deducting there from recoveries on account of advances,
interest, retention money, income tax etc. The balance payment due
will be paid thereafter.

iv) No interim payment will be admitted until such time the Contractor
have fully complied with the requirement of the Condition no.8 (g)
and 8 (h) concerning submission and approval of Network Schedule
for the works, as detailed in Condition 8 (h). A fixed sum shall be
held in abeyance at the time of next interim payment for non-
attainment of each milestone in the network and shall be released
only on attainment of the said milestone.

v) An interim certificate given relating to work done or material

delivered may be modified or corrected by a subsequent interim
certificate or by the final certificate. No certificate of the Engineer

149
 supporting an interim payment shall of itself be conclusive evidence
that any work or materials to which it relates is / are in accordance
with the contract.

82 Banning/De-Registration of Agencies of Construction works in

MCGM

 The regulations regarding Demotion/ Suspension Banning for specific

period or permanently / De-Registration shall be governed as per the
respective condition in Contractor Registration Rules of MCGM.
83. JOINT VENTURE (Deleted)

84. Compensation for delay:

If the Contractor fails to complete the works and clear the site on or
before the Contract or extended date(s) / period(s) of completion, he
shall, without prejudice to any other right or remedy of Municipal
Corporation on account of such breach, pay as agreed compensation,
amount calculated as stipulated below (or such smaller amount as
may be fixed by the Engineer) on the contract value of the whole work
or on the contract value of the time or group of items of work for
which separate period of completion are given in the contract and of
which completion is delayed for every week that the whole of the work
of item or group of items of work concerned remains uncompleted,
even though the contract as a whole be completed by the contract or
the extended date of completion. For this purpose the term ‘Contract
Value’ shall be the value of the work at Contract Rates as ordered
including the value of all deviations ordered:
• Completion period for projects (originally stipulated or as extended)
not exceeding 6 months :to the extent of maximum 1 percent per
week.
• Completion period for projects (originally stipulated or as extended)
exceeding 6 months and not exceeding 2 years: to the extent of
maximum ½ percent per week.
• Completion period for projects (originally stipulated or as extended)
exceeding 2 years: to the extent of maximum ¼ percent per week.

150
 When the delay is not a full week or in multiple of a week but involves
a fraction of a week the compensation payable for that fraction shall
be proportional to the number of days involved.
Provided always that the total amount of compensation for delay to be
paid this condition shall not exceed the undernoted percentage of the
Contract Value of the item or group of items of work for which a
separate period of completion is given.
i) Completion period (as originally stipulated or as extended) not
exceeding 6 months: 10 percent.
ii) Completion period (as originally stipulated or as extended)
exceeding 6 months and not exceeding 2 years :7½ percent.
iii) Completion period (as originally stipulated or as extended)
exceeding 2 years :5 percent.
The amount of compensation may be adjusted set off against any sum
payable to the contractor under this or any other contract with the
Municipal Corporation.
85. Action And Compensation Payable In Case Of Bad Work And Not
Done As Per Specifications
All works under or in course of execution or executed in pursuance of
the contract, shall at all times be open and accessible to the
inspection and supervision of the Engineer-in-charge, his authorized
subordinates in charge of the work and all the superior officers, officer
of the Vigilance Department of the MCGM or any organization engaged
by the MCGM for Quality Assurance and the contractor shall, at all
times, during the usual working hours and at all other times at which
reasonable notice of the visit of such officers has been given to the
contractor, either himself be present to receive orders and instructions
or have a responsible agent duly accredited in writing, present for that
purpose. Orders given to the Contractor’s agent shall be considered to
have the same force as if they had been given to the contractor
himself.
If it shall appear to the Engineer-in-charge or his authorized
subordinates in-charge of the work or to the officer of Vigilance
Department, that any work has been executed with unsound,
imperfect or unskilful workmanship or with materials of any inferior
description, or that any materials or articles provided by him for the
151
execution of the work are unsound or of a quality inferior to that
contracted for or otherwise not in accordance with the contract, the
contractor shall, on demand in writing which shall be made within
twelve months of the completion of the work from the Engineer-in-
Charge specifying the work, materials or articles complained of
notwithstanding that the same may have been passed, certified and
paid for forthwith rectify, or remove and reconstruct the work so
specified in whole or in part, as the case may require or as the case
may be, remove the materials or articles so specified and provide other
proper and suitable materials or articles at his own charge and cost.
In the event of the failing to doso within a period specified by the
Engineer-in-Charge in his demand aforesaid, then the contractor shall
be liable to pay compensation at the same rate as under clause 8.e. of
the general condition of contract in section 9 of tender document (for
Compensation for delay) for this default. In such case the Engineer-in
Charge may not accept the item of work at the rates applicable under
the contract but may accept such items at reduced rates as the
Engineer in charge may consider reasonable during the preparation of
on account bills or final bill if the item is so acceptable without
detriment to the safety and utility of the item and the structure or he
may reject the work outright without any payment and/or get it and
other connected and incidental items rectified, or removed and re-
executed at the risk and cost of the contractor. Decision of the
Engineer-in-Charge to be conveyed in writing in respect of the same
will be final and binding on the contractor.
If the penalization amount exceeds maximum limit with respect to
Clause 8.e of Standard General Conditions of Contract, then a show
cause notice shall necessarily be issued to the contract as to why the
contract should not be terminated.

The above clause is summarized to make it easy to understand as

follows:

1. The Engineer-in-charge shall issue notice to the contractor for

rectifying the defects or redoing of the work if necessary, within specific
time to achieve the desired quality and quantity of the work and this
152
should be governed by clause 8.f and 9.b of Standard General
Conditions of Contract.

2. If the contractor fails to comply the same, only then, the contractor
shall be liable to pay compensation at the same rate as under clause
8.e of the Standard General Condition of Contract (for Compensation for
delay) for this default.

3. If the penalization amount exceeds the maximum limit, then the

contractor will be liable for being banned/ deregistered from business
dealings with MCGM and this shall be governed by relative provision in
Registration Rules of MCGM and Standard General Conditions of
Contract.

4. This penalization shall be levied only on account of delay in work,

unsound, imperfect or unskilful workmanship or with materials of any
inferior description, or that any materials or articles provided by him for
the execution of the work are unsound or of quality inferior to that
contracted for or otherwise not in accordance with the con-tract.

86. Contractors remain liable to pay compensation:

In any case in which any of the powers conferred upon the Engineer
In-charge by the relevant clauses in documents that form a part of
contract as exercised or is exercisable in the event of any future case
of default by the Contractor, he is declared liable to pay compensation
amounting to the whole of his security deposit. The liability of the
Contractor for past and future compensation shall remain unaffected.
In the event of the Executive Engineer taking action against these
relevant clauses,he may, if he so desires, take possession of all or
any tools and plant, materials and stores in or upon the work of site
thereof or belonging to the Contractor or procured by him and
intended to be used for the execution of the work or any part thereof
paying or allowing for the same in account at the contract rates, or in
the case of contract rates not being applicable at current market rates
to be certified by the Executive Engineer, may after giving notice in
writing to the Contractor or his staff of the work or other authorized
153
 agent require him to remove such tools and plants, materials or stores
from the premises within a time to be specified in such notice and in
the event of the Contractor failing to comply with any such
requisition, the Executive Engineer may remove them at the
contractors expense of sell them by auction or private sell on account
of the Contractor at his risk in all respects and certificate of the
Executive Engineer as to the expense of any such removal and the
amount of the proceeds an expense of any such sell be final and
conclusive against the Contractor.

87. No Claim To Any Payment Or Compensation Or Alteration In Or

Restriction Of Work

(a) If at any time after the execution of contract documents, the

Engineer shall for any reason whatsoever, desires that the whole
or any part of the works specified in the Tender should be
suspended for any period or that the whole or part of the work
should not be carried out, at all, he shall give to the Contractor
a Notice in writing of such desire and upon the receipt of such
notice, the Contractor shall forthwith suspend or stop the work
wholly or in part as required after having due regard to the
appropriate stage at which the work should be stopped or
suspended so as not to cause any damage or injury the work
already done or endanger the safety thereof, provided that the
decision of the Engineer as to the stage at which the work or
any part of it could be or could have been safely stopped or
suspended shall be final and conclusive against the contractor.
The Contractor shall have no claim to any payment or
compensation whatsoever by reason of or in pursuance of any
notice as aforesaid, on account of any suspension, stoppage or
curtailment except to the extent specified hereinafter.
(b) Where the total suspension of Work Order as aforesaid
continued for a continuous period exceeding 90 days the
contractor shall be at liberty to withdraw from the contractual
obligations under the contract so far as it pertains to the
unexecuted part of the work by giving 10 days prior notice in
writing to the Engineer within 30 days of the expiry of the said
154
 period of 90 days, of such intention and requiring the
Engineering to record the final measurement of the work
already done and to pay final bill. Upon giving such Notice, the
Contractor shall be deem to have been discharged from his
obligations to complete the remaining unexecuted work under
his contract. On receipt of such notice the Engineer shall
proceed to complete the measurement and make such payment
as may be finally due to the contractor within a period of 90
days from the receipt of such Notice in respect of the work
already done by the contractor. Suchpayment shall not in any
manner prejudice the right of the contractor to any further
compensation under the remaining provisions of this clause.
(c) Where the Engineer required to Contractor to suspend the work
for a period in excess of 30 days at any time or 60 days in the
aggregate, the Contractor shall be entitled to apply to the
Engineer within 30 days of the resumption of the work after
such suspension for payment of compensation to the extent of
pecuniary loss suffered by him in respect of working machinery
remained ideal on the site of on the account of his having an to
pay the salary of wages and labour engaged by him during the
said period of suspension provided always that the contractor
shall not be entitled to any claim in respect of any such working
machinery, salary or wages for the first 30 days whether
consecutive or in the aggregate or such suspension or in respect
of any such suspension whatsoever occasion by unsatisfactory
work or any other default on his part, the decision of the
Engineer in this regard shall be final and conclusive against the
contractor.

88. Contractor to supply plant, ladder, scaffolding, etc and is liable

for damages arising from non-provision of lights, fencing, etc.

The Contractor shall supply at his own cost all material, plant, tools,
appliances, implements, ladders, cordage, tackle scaffolding and
temporary works requisite or proper for the proper execution of the
work, whether, in the original altered or substituted form and whether
included in the specification of other documents forming part of the
155
 contract or referred to in these conditions or not and which may be
necessary for the purpose of satisfying or complying with the
requirements of the Eng-In-Charge as to any matter as to which under
these conditions is entitled to be satisfied, or which is entitled to
require together with the carriage therefore to and from the work.
The Contractor shall also supply without charge, the requisite number
of person with the means and materials necessary for the purpose of
setting out works and counting, weighing and assisting in the
measurements of examination at any time and from time to time of
the work or materials, failing which the same may be provided by the
Engineer In-charge at the expense of the contractor and the expenses
may be deducted from any money due to the contractor under the
contract or from his security deposit or the proceeds of sale thereof, or
offers sufficient portion thereof.
The contractor shall provide all necessary fencing and lights required
to protect the public from accident and shall also be bound to bear the
expenses of defence of every suit, action or other legal proceedings,
that may be brought by any person for injury sustained owing to
neglect of the above precautions and to pay any damages and cost
which may be awarded in any such suit action or proceedings to any
such person or which may with the consent of the contractor be paid
for compromising any claim by any such person.

89. Prevention of Fire:

The contractor shall not set fire to any standing jungle, trees,
brushwood or grass without a written permit from the Engineer In-
charge. When such permit is given, and also in all cases when
destroying cut or dug up trees brushwood, grass, etc., by fire, the
contractor shall take necessary measure to prevent such fire
spreading to or otherwise damaging surrounding property. The
Contractor shall make his own arrangements for drinking water for
the labour employed by him.

90. Compensation for all damages done intentionally or unintentionally by

contractor’s labour whether in or beyond the limits of MCGM property
including any damage caused by spreading the fire shall be estimated
by the Engineer In-charge or such other officer as he may appoint and
156
 the estimate of the Engineer in-charge to the decision of the Dy. Chief
Engineer on appeal shall be final and the contractor shall be bound to
pay the amount of the assessed compensation on demand failing
which the same will be recovered from the Contractor as damages or
deducted by the Engineer In-charge from any sums that may be due
or become due from MCGM to contractor under this Contract or
otherwise. Contractor shall bear the expenses of defending any action
or other legal proceedings that may be brought to prevent the spread
of fire and he shall pay any damages and costs that may be awarded
by the Court in consequence.

91. In the case of Tender by partners, any change in the constitution of the
firm shall be forthwith, notified by the contractor through the
Engineer In-charge for his information.
92. Action where no specifications:
In the case of any class of work for which there is no such
specifications, such works shall be carried out in accordance with the
specifications and in the event of there being no such specifications,
then in such case, the work shall be carried out in all respects in
accordance with all instructions and requirements of the Engineer In-
charge.

93. Safety and medical help:

(i) The Contractor shall be responsible for and shall pay the
expenses of providing medical help to any workmen who may
suffer a bodily injury as a result of an accident. If such expenses
are incurred by MCGM, the same shall be recoverable from the
contractor forthwith and be included without prejudice to any
other remedy of MCGM from any amount due or that may become
due to the Contractor.
(ii) The contractor shall provide necessary personal safety equipment
and first-aid box for the use of persons employed on the site and
shall maintain the same in condition suitable for immediate use
at any time.

157
 (iii) The workers shall be required to use the safety equipments so
provided by the contractor and the contractor shall take adequate
steps to ensure the proper use of equipments by those concerned.
(iv) When the work is carried on in proximity to any place where there
is risk or drawing all necessary equipments shall be provided and
kept ready for use and all necessary steps shall be taken for the
prompt rescue of any person in danger.

94. No compensation shall be allowed for any delay caused in the starting
of the work on account of acquisition of land or in the case of
clearance of works, on account of ant delay in according to sanction of
estimates.

95. Anti-malaria and other health measures:

Anti-Malaria and other health measures shall be taken as directed by
the Executive Health Officer of MCGM. Contractor shall see that
mosquito genic conditions are created so as to keep vector population
to minimum level. Contractor shall carry out anti-malaria measures in
the area as per the guidelines issued by the Executive Health Officer
of MCGM from time to time.
In case of default, in carrying out prescribed anti-malaria measures
resulting in increase in malaria incidence, contractor shall be liable to
pay MCGM on anti-malaria measures to control the situation in
addition to fine.

158
 SECTION 11

SPECIFICATIONS
& SELECTION OF MATERIAL

159
 SPECIFICATIONS & SELECTION OF MATERIAL

The tender is prepared on the basis of Unified Schedule of Rates and

specifications 2013. The specifications of the items of USOR are available on
MCGM portal http://portal.mcgm.gov.inunder the Tender tab. Hence the
deserving contractor shall either download the same from MCGM portal or
the same may be collected in the soft copy format at the time of purchasing
the tender from this office.

SELECTION OF MATERIAL
1. All materials brought on the site of work and meant to be used in the
same, shall be the best of their respective kinds and to the approval of
the Engineer. The Engineer or his representative will accept that the
materials are really the best of their kinds, when it is proved be-yond
doubt that no better materials of the particular kind in question are
available in the market.
2. The contractor shall obtain the approval of the Engineer of samples of
all materials to be used in the works and shall deposit these samples
with him before placing an order for the materials with the suppliers.
The materials brought on the works shall conform in every respect to
their approved samples. Fresh samples shall be deposited with the
Engineer when-ever the type or source of any material changes.
3. The contractor shall check each fresh consignment of materials as it is
brought to the site of works to see that they conform in all respects to
the Specifications of the samples approved by the Engineer, or both.
4. The Engineer will have the option to have any of the materials tested
to find out whether they are in accordance with the Specifications and
the Contractor will bear all expenses for such testing. All B bills,
vouchers and test certificates, which in the opinion of the Engineer or
his representative are necessary to convince him as to the quality of
the materials or their suitability shall be produced for his inspection
when required.
5. Any materials that have not been found to conform to the
specifications will be rejected forthwith and shall be removed from the
site by the contractor at his own cost within 24 hours.

160
6. The Engineer shall have power to cause the Contractors to purchase
and use such materials from any particular source, as may in his
opinion be necessary for the proper execution of the work.
7. Notwithstanding the source, the sand shall be washed using sand
washing machine before use.

161
 SECTION 12

FRAUD AND CORRUPT PRACTICES

162
 FRAUD AND CORRUPT PRACTICES

The Applicants and their respective officers, employees, agents and

advisers shall observe the highest standard of ethics during the
Bidding Process. Notwithstanding anything to the contrary contained
herein, the Authority may reject an Application without being liable in
any manner whatsoever to the Applicant if it determines that the
Applicant has, directly or indirectly or through an agent, engaged in
corrupt practice, fraudulent practice, coercive practice, undesirable
practice or restrictive practice in the Bidding Process.

Without prejudice to the rights of the Authority under relevant Clause

hereinabove, if an Applicant is found by the Authority to have directly
or indirectly or through an agent, engaged or indulged in any corrupt
practice, fraudulent practice, coercive practice, undesirable practice or
restrictive practice during the Bidding Process, such Applicant shall
not be eligible to participate in any tender or RFQ issued by the
Authority during a period of 2 (two) years from the date such
Applicant is found by the Authority to have directly or indirectly or
through an agent, engaged or indulged in any corrupt practice,
fraudulent practice, coercive practice, undesirable practice or
restrictive practice, as the case may be.

For the purposes of this Clause, the following terms shall have the
meaning hereinafter respectively assigned to them:

A. “corrupt practice” means the offering, giving, receiving, or soliciting,

directly or indirectly, of anything of value to influence the actions of any
person connected with the Bidding Process (for avoidance of doubt,
offering of employment to, or employing, or engaging in any manner
whatsoever, directly or indirectly, any official of the Authority who is or
has been associated in any manner, directly or indirectly, with the
Bidding Process or the LOA or has dealt with matters concerning the
Concession Agreement or arising there from, before or after the
execution thereof, at any time prior to the expiry of one year from the

163
 date such official resigns or retires from or otherwise ceases to be in the
service of the Authority, shall be deemed to constitute influencing the
actions of a person connected with the Bidding Process); or

save and except as permitted under the relevant sub clause, engaging
in any manner whatsoever, whether during the Bidding Process or after
the issue of the LOA or after the execution of the Concession
Agreement, as the case may be, any person in respect of any matter
relating to the Project or the LOA or the Concession Agreement, who at
any time has been or is a legal, financial or technical adviser of the
Authority in relation to any matter concerning the Project;

B. “fraudulent practice” means a misrepresentation or omission of facts

or suppression of facts or disclosure of incomplete facts, in order to
influence the Bidding Process ;

C. “coercive practice” means impairing or harming or threatening to

impair or harm, directly or indirectly, any person or property to
influence any persons participation or action in the Bidding Process;

D. “undesirable practice” means (i) establishing contact with any

person connected with or employed or engaged by the Authority with
the objective of canvassing, lobbying or in any manner influencing or
attempting to influence the Bidding Process; or (ii) having a Conflict of
Interest; and

E. “Restrictive practice” means forming a cartel or arriving at any

understanding or arrangement among Applicants with the objective of
restricting or manipulating a full and fair competition in the Bidding
Process.

F. If the Employer/Financier determines that the Contractor has

engaged in corrupt, fraudulent, collusive, coercive or obstructive
practices, in competing for or in executing the Contract, then the
Employer may, after giving 14 days’ notice to the Contractor,
terminate the Contractor's employment under the Contract and expel
him from the Site, and the provisions of relevant Clause shall apply as
if such expulsion had been made.

164
G. Should any employee of the Contractor be determined to have engaged
in corrupt, fraudulent, collusive, coercive, or obstructive practice
during the execution of the Works, then that employee shall be
removed in accordance with relevant Clause.

For the purposes of this Sub-Clause:

i. “corrupt practice” is the offering, giving, receiving to soliciting,

directly or indirectly, of anything of value to influence
improperly the actions of another party;

ii. “another party” refers to a public official acting in relation to the

procurement process or contract execution. In this context,
“public official” includes Financer staff and employees of other
organizations taking or reviewing procurement decisions.

iii. “fraudulent practice” is any act or omission, including a

misrepresentation, that knowingly or recklessly misleads, or
attempts to mislead, a party to obtain a financial or other
benefit or to avoid an obligation;

iv. “collusive practice” is an arrangement between two or more parties

designed to achieve an improper purpose, including to influence
improperly the actions of another party;

v. “coercive practice” is impairing or harming, or threatening to impair

or harm, directly or indirectly, any party or the property of the
party to influence improperly the actions of a party;

vi. “obstructive practice” is deliberately destroying, falsifying,

altering or concealing of evidence material to the investigation or
making false statements to investigators in order to materially
impede the Financier investigation into allegations of a corrupt,
fraudulent, coercive or collusive practice; and/or threatening,
harassing or intimidating any party to prevent it from disclosing
its knowledge of matters relevant to the investigation or from
pursuing the investigation; or

vii. acts intended to materially impede the exercise of the Financer’s

inspection and audit rights provided .
165
viii. “party” refers to a public official; the terms “benefit” and
“obligation” relate to the procurement process or contract
execution; and the “act or omission” is intended to influence the
procurement process or contract execution.

ix. ”parties” refers to participants in the procurement process

(including public officials) attempting to establish bid prices at
artificial, non-competitive levels.

x. a “party” refers to a participant in the procurement process or

contract execution.

166
 SECTION –13

LIST OF APPROVED BANKS

167
 LIST OF APPROVED BANKS

1. The following Banks with their branches in Greater Mumbai and in

suburbs and extended suburbs up to Virar and Kalyan have been
approved only for the purpose of accepting Banker’s guarantee from
1997-98 onwards until further instructions.

2. The Bankers Guarantee issued by branches of approved Banks beyond

Kalyan and Virar can be accepted only if the said Banker’s Guarantee is
countersigned by the Manager of a branch of the same Bank, within the
Mumbai Limit categorically endorsing thereon that said bankers
Guarantee is binding on the endorsing Branch of the bank within
Mumbai limits and is liable to be on forced against the said branch of
the Bank in case of default by the contractor/supplier furnishing the
bankers Guarantee.

List of approved Banks:-

A S.B.I and its subsidiary Banks
1 State Bank Of India.
2 State Bank Of Bikaner & Jaipur.
3 State Bank Of Hyderabad.
4 State Bank Of Mysore.
5 State Bank Of Patiyala.
6 State Bank Of Saurashtra.
7 State Bank Of Travankore.
B Nationalized Banks
8 Allahabad Bank.
9 Andhra Bank.
10 Bank Of Baroda.
11 Bank Of India.
12 Bank Of Maharashtra.
13 Central Bank Of India.
14 Dena Bank.
15 Indian Bank.
16 Indian Overseas Bank.
17 Oriental Bank Of Commerce.
18 Punjab National Bank.
19 Punjab & Sindh Bank.
20 Syndicate Bank.
21 Union Bank Of India.
22 United Bank Of India.
23 UCO Bank.
24 Vijaya Bank.
24A Corporation Bank.
168
C Scheduled Commercial Banks
25 Bank Of Madura Ltd.
26 Bank Of Rajasthan Ltd.
27 Banaras State Bank Ltd.
28 Bharat Overseas Bank Ltd
29 Catholic Syrian Bank Ltd.
30 City Union Bank Ltd.
31 Development Credit Bank.
32 Dhanalakshmi Bank Ltd.
33 Federal Bank Ltd.
34 Indsind Bank Ltd.
35 I.C.I.C.I Banking Corporation Ltd.
36 Global Trust Bank Ltd.
37 Jammu & Kashmir Bank Ltd.
38 Karnataka Bank Ltd.
39 KarurVysya Bank Ltd.
40 Laxmi Vilas Bank Ltd.
41 Nedugundi Bank Ltd.
42 Ratnakar Bank Ltd.
43 Sangli Bank Ltd.
44 South Indian Bank Ltd.
45 S.B.I Corporation &Int Bank Ltd.
46 Tamilnadu Mercantile Bank Ltd.
47 United Western Bank Ltd.
48 Vysya Bank Ltd.
D Schedule Urban Co-op Banks
49 Abhyudaya Co-op Bank Ltd.
50 Bassein Catholic Co-op Bank Ltd.
51 Bharat Co-op Bank Ltd.
52 Bombay Mercantile Co-op Bank Ltd.
53 Cosmos Co-op Bank Ltd.
54 Greater Mumbai Co-op Bank Ltd.
55 JanataSahakari Bank Ltd.
56 Mumbai District Central Co-op Bank Ltd.
57 Maharashtra State Co-op Bank Ltd.
58 New India Co-op Bank Ltd.
59 North Canara G.S.B. Co-op Bank Ltd.
60 Rupee Co-op Bank Ltd.
61 Sangli Urban Co-op Bank Ltd.
62 Saraswat Co-op Bank Ltd.
63 ShamraoVithal Co-op Bank Ltd.
64 Mahanagar Co-op Bank Ltd.

65 Citizen Bank Ltd.

66 Yes Bank Ltd.
E Foreign Banks
67 ABM AMRO (N.Y.) Bank.
68 American Express Bank Ltd.
69 ANZ Grindlays Bank Ltd.
169
70 Bank Of America N.T. & S.A.
71 Bank Of Tokyo Ltd.
72 Bankindosuez.
73 BanqueNationale de Paris.
74 Barclays bank.
75 City Bank N.A.
76 Hongkong& Shanghai banking Corporation.
77 Mitsui Taiyokbe Bank Ltd.
78 Standard Chartered Bank.
79 Cho Hung Bank.

170
 SECTION –14

APPENDIX

171
 FORM OF TENDER

To,

The Municipal Commissioner for Greater Mumbai

Sir,

I/ We have read and examined the following documents relating to the

construction of _____________________________________________________

____________________________________________________________________

___________________________________________________________________

Notice inviting tender.

a. Directions to tenderers (General and special)
b. General condition of contract for Civil Works of the
Municipal Corporation of Greater Mumbai as amended up to date.
c. Relevant drawings
d. Specifications.
e. Special directions
f. Annexure A and B.
g. Bill of Quantities and Rates.

1A. I/We________________________________________________________

(full name in capital letters, starting with surname), the Proprietor/

Managing Partner/ Managing Director/ Holder of the Business, for the
establishment / firm / registered company, named herein below, do
hereby offer to
…………………………………………………………………………

…………………………………………………………………………………………
………………………………………………..………………………………………
……………………….………….…………….………………………………………
…

172
 Referred to in the specifications and schedule to the accompanying
form of contract of the rates entered in the schedule of rates sent
herewith and signed by me/ us” (strike out the portions which are not
applicable).

1B. I/We do here by state and declare that I/We, whose names are
given herein below in details with the addresses, have not filled in this
tender under any other name or under the name of any other
establishment /firm or otherwise, nor are we in any way related or
concerned with the establishment /firm or any other person, who
have filled in the tender for the aforesaid work.”

2. I/We hereby tender for the execution of the works referred to in the
aforesaid documents, upon the terms and conditions, contained or
referred to therein and in accordance with the specifications designs,
drawings and other relevant details in all respects.

* At the rates entered in the aforesaid Bill of Quantities and Rates.

3. According to your requirements for payment of Earnest Money

amounting to Rs. 1,87,000/-(Rs. One Lakh Eighty Seven Thousand
only)

*(a) I/We have deposited the amount through online payment gateways
with the C.E of the corporation not to bear interest.

4. I/We hereby request you not to enter into a contract with any other
person/s for the execution of the works until notice of non/acceptance of
this tender has first been communicated to me/us, and in consideration
of yours agreeing to refrain from so doing I/we agree not to withdraw the
offer constituted by this tender before the date of communication to
me/us of such notice of non/acceptance, which date shall be not later
than ten days from the date of the decision of the Standing Committee or
Education Committee of the Corporation, as maybe required under the
Mumbai Municipal Corporation Act, not to accept this tender.(Subject to
condition 5 below).

173
 5. I/We also agree to keep this tender open for acceptance for a
period of 180 days from the date fixed for opening the same and not to
make any modifications in its terms and conditions which are not
acceptable to the Corporation.

6. I/We agree that the Corporation shall, without prejudice to any

other right or remedy, be at liberty to forfeit the said earnest money
absolutely, if.

a. I/We fail to keep the tender open as aforesaid.

b. I/We fail to execute the formal contract or make the contract

deposit when called upon to do so.

c. I/we do not commence the work on or before the date

specified by the Engineer in his work order.

7. I/We hereby further agree to pay all the charges of whatsoever

nature in connection with the preparation, stamping and execution of
the said contract.

8. I/We further agree that, I/we shall register ourselves as ‘Employer’

with the Bombay Iron and Steel Labour Board’ and fulfill all the
obligatory provisions of Maharashtra Mathadi, Hamal and other Manual
workers (Regulation of Employment and Welfare) Act 1969 and the
Bombay Iron and Steel unprotected workers Scheme 1970.

9. “I/We………………………………………….…….. have failed in the

accompanying tender with full knowledge of liabilities and,
therefore, we will not raise any objection or dispute in any manner
relating to any action, including forfeiture of deposit and blacklisting, for
giving any information, which is found to be incorrect and against the
instructions and directions given in this tender.

10. “I/We further agree and undertake that in the event it is revealed
subsequently after the allotment of work/contract to me/us, that any
information given by me/us in this tender is false or incorrect, I/We
shall compensate the Municipal Corporation of Greater Mumbai for any

174
 such losses or inconvenience caused to the Corporation in any manner
and will not resist any claim for such compensation on any ground
whatsoever. I/we agree and undertake that I/we shall not claim in such
case any amount by way of damages or compensation for cancellation
of the contract given to me/us or any work assigned to me/us or is
withdrawn by the Corporation,”

Address Yours

faithfully
,

………………………………….

…………………………….……

Digital Signature of the Tenderer or the

Firm

1. ………………………………………………..

2. ………………………………………………..

3. ………………………………………………..

4. ………………………………………………..

5. ………………………………………………..

175
Full Name and private residential address A/c
of all the partners constituting the Firm No.………………………………………………

Name of the branch

1
……………………………………………………

……………………………………………………
2
……………………………………………………

Name of the branch

3
……………………………………………………

……………………………………………………
4
……………………………………………………

Vendor No…………………………………….
5
……………………………………………………

176
 AGREEMENT FORM

Tender / Quotation

dated ……………. 20…

Standing Committee/Education Committee Resolution No.

……..……………………………….

CONTRACT FOR THE WORKS

…….…………………………………………..………..…………
…………………………………………………………...………………………….…………
…………………………………………………………………...……………………………
…… ……………

This agreement made this day of ………… …………………………….

……………… …………

Twothousand……………………....…..……..………..…………………………………
………… Between
.……...……………...………………………………………………….…………….………

………………………………………………………..…………….…………………………..
…

inhabitants of Mumbai, carrying on business at……………………...…..……

……………………………………………………………………………...…………………
……….……………

in Bombay under the style and name of Messrs

……………………..…………………………………………………………………………
…………...…………………………………………… (Hereinafter called “the
contractor of the one part and Shri ………………………………
…………………………………………………………………………………….……………
.

177
the Director(E.S.&P.) (hereinafter called “the commissioner” in which
expression are included unless the inclusion is inconsistent with the
context, or meaning thereof, his successor or successors for the time being
holding the office of Director (E,S.& P)of the second part and the Municipal
Corporation of Greater Mumbai (hereinafter called “the Corporation”) of the
third part, WHEREAS the contractor has tendered for the construction,
completion and maintenance of the works described above and his tender
has been accepted by the Commissioner (with the approval of the Standing
Committee/Education Committee of the Corporation NOW THIS
AGREEMENT WITNESSETH as follows:-
1. In this agreement words and expressions shall have the same
meanings as are respectively assigned to them in the General
Conditions of Contract for works hereinafter referred to:-
2. The following documents shall be deemed to form and be read
and constructed as a part of this agreement viz.
a. The said Tender
b. The Drawings
c. The Specifications
d. General condition of contract for Civil Works of the Municipal
Corporation of Greater Mumbai as amended up to date
3. In consideration of the payments to be made by the
Commissioner to the contractor as hereinafter mentioned the
contractor hereby covenants with the Commissioner to construct,
complete and maintain the works in conformity in all respects
with the provision of the contract.
4. The Commissioner hereby covenants to pay to the Contractor in
consideration of the construction, completion and maintenance of
the works the contract sum, at times and in the manner
prescribed by the contract.
IN WITNESS WHERE OF the parties hereto have caused their respective
common seals to be herein to affixed (or have hereunto set their
respective hands and seals) the day and year above written.

Signed, Sealed and delivered by the

178
contractors

In the presence of Trading under the name and

style of

Full Name

Address Contractors

Signed by the Director (ES&P) in the Ex. Eng (Str) City/ WS/ ES
presence of

Director (ES&P)

The Common seal of the Municipal

Corporation of Greater Mumbai was
hereunto affixed on the ………… 20 in the
presence of two members of the Standing
Committee / Education Committee of
the Municipal Corporation.

1. 1.

2. 2.

And in the presence of the Municipal Municipal Secretary

Secretary

179
 ANNEXURE A

Name of work:- “Civil & Structural Repairs to KMJ Phule Hospital,

Kannamwarnagar, Vikhroli(East) in S ward.

1. The Engineer for this work City Engineer

2. Estimated cost of Tender

a. Civil works Rs. 1,45,74,540/-

b. Mechanical & Electrical works Rs. 41,18,780/-

Total Rs. 1,86,93,320/-

Electrical Rebate Rs.56,717/-

Earnest Money (1% of the Estimated

3. Rs. 1,87,000/-
cost to be paid through online system)

4. Time Period

16months
1. Contract as a whole Period completion
(* Inclusive of Monsoon)

**2. Part or Groups of items

i)Preliminary Works i) 1 months

ii)Structural Repair Works ii)

15 months
iii)Finishing Works iii)

5. Defect Liability Period

General 03 years

Structural 05 years

Waterproofing 05 years

.
Percentage to be charged as supervision charges for the work got executed
through other means ….. percent.

The “Actual cost of the work” shall mean in the case of percentage rate
contracts the actual cost of the work executed at the rates as mentioned in
the Contract Schedule adjusted by the Contractor's percentage rate and cost
of extra and excess, but excluding the cost on account of Water Charges and

180
Sewerage Charges if any, payable by the contractor and also excluding cost
on account of price variation claims as provided in condition no. 74 of these
conditions as amended up to date.

1. In case of item rate contracts the actual cost calculated for the work
executed at the rates mentioned in the contract schedule for different
items including cost of excess and extra items of the work excluding the
cost of water charges and sewerage charges if any, payable by the
contractor and excluding cost on account of price variation claims as
provided in extra excess conditions as amended up to date.
2. In case of lump sum contract the cost of the work actually carried out
as per break up and programme of the work and the schedule of
payment included in the contract including cost of any excess and/or
extra items, of the work, excluding the cost on account of water charges
and sewerage charges and also excluding cost on account of price
variation claims as provided in extra excess conditions as amended up
to date.

181
 ANNEXURE- B
On Rs. 500/- stamp paper
PRE-CONTRACT INTEGRITY PACT
The Bidder commits himself to take all measures necessary to prevent
corrupt practices, unfair means and illegal activities during any stage of his
bid or during any pre-contract or post-contract stage in order to secure the
contract or in furtherance to secure it and in particular commits himself to
the following:-
1. The Bidder will not offer, directly or through intermediaries, any bribe,
gift, consideration, reward, favour, any material or immaterial benefit
or other advantage, commission, fees, brokerage or inducement to any
official of the MCGM, connected directly or indirectly with the bidding
process, or to any person, organization or third party related to the
contract in exchange for any advantage in the bidding, evaluation,
contracting and implementation of the Contract.
2. The Bidder further undertakes that he has not given, offered or promised
to give, directly or indirectly any bribe, gift, consideration, reward,
favour, any material or immaterial benefit or other advantage,
commission, fees, brokerage or inducement to any official of the MCGM
or otherwise in procuring the Contract or forbearing to do or having done
any act in relation to the obtaining or execution of the Contract or any
other Contract with the Government for showing or forbearing to show
favour or disfavour to any person in relation to the Contract or any other
Contract with the Government.
3. The Bidder will not collude with other parties interested in the contract
to impair the transparency, fairness and progress of the bidding process,
bid evaluation, contracting and implementation of the contract.
4. The Bidder will not accept any advantage in exchange for any corrupt
practice, unfair means and illegal activities.
5. The Bidder, either while presenting the bid or during pre-contract
negotiations or before signing the contract, shall disclose any payments
he has made, is committed to or intends to make to officials of the
MCGM or their family members, agents, brokers or any other
intermediaries in connection with the contract and the details of services
agreed upon for such payments.

182
6. The Bidder shall not use improperly, for purposes of competition or
personal gain, or pass on to others, any information provided by the
MCGM as part of the business relationship, regarding plans, technical
proposals and business details, including information contained in any
electronic data carrier. The Bidder also undertakes to exercise due and
adequate care lest any such information is divulged.
7. The Bidder commits to refrain from giving any complaint directly or
through any other manner without supporting it with full and verifiable
facts.
8. The Bidder shall not instigate or cause to instigate any third person to
commit any of the actions mentioned above.
9. The Bidder and their respective officers, employees, agents and advisers
shall observe the highest standard of ethics during the Bidding Process.
Notwithstanding anything to the contrary contained herein, the
Authority may reject an Application without being liable in any manner
whatsoever to the Applicant if it determines that the Applicant has,
directly or indirectly or through an agent, engaged in corrupt practice,
fraudulent practice, coercive practice, undesirable practice or restrictive
practice in the Bidding Process
For the purposes of this Clause 9, the following terms shall have the
meaning herein after respectively assigned to them:
1. “fraudulent practice” means a misrepresentation or omission of facts
or suppression of facts or disclosure of incomplete facts, in order to
influence the Bidding Process ;

2. “coercive practice” means impairing or harming or threatening to

impair or harm, directly or indirectly, any person or property to
influence any persons participation or action in the Bidding Process;

3. “undesirable practice” means (i) establishing contact with any person

connected with or employed or engaged by the Authority with the
objective of canvassing, lobbying or in any manner influencing or
attempting to influence the Bidding Process; or (ii) having a Conflict
of Interest; and

183
4. “restrictive practice” means forming a cartel or arriving at any
understanding or arrangement among Applicants with the objective
of restricting or manipulating a full and fair competition in the
Bidding Process.

Signature of Tenderer/Bidder

184
 Annexure-C
(This is a draft format)
(On Rs. 500/- Stamp paper)
DECLARATION CUM-INDEMNITY BOND

I,_______________________________________Of__________________________
_______________________

do hereby declared and undertake as under.

1) I declared that I have submitted certificates as required to Executive
Engineer (Monitoring) at the time of registration of my firm/ company
_______________________and there is no change in the contents of the
certificates that are submitted at the time of registration.

2) I declared that I______________________________________________________ in

capacity as Manager/ Director / Partners / Proprietors of
_____________________________________has not been charged with any
prohibitory and /or penal action such as demotion, suspension, black
listing / de-registration or any other action under the law by any
Government and/ or Semi Government and/ or Government Undertaking.

3) I declared that, I have perused and examined the tender document

including addendum, condition of contract, specification, drawings, bill of
quantity etc. forming part of tender and accordingly, I submit my offer to
execute the work as per tender documents at the rates quoted by me in
capacity as__________________________________
of_______________________________________.

4) I further declared that if, I am allotted the work and I failed to carry out
the allotted work in accordance with the terms and conditions and within
the time prescribed and MCGM is entitled to carry out the work allotted to
me by any other means at my risk and cost, at any stage of the contract.

5)I also declared that I will not claim any charge / damages / compensation
for non-availability of site for the contract work at any time.

185
6)I Indemnify Municipal Commissioner and the other officers of MCGM or
their agents for any Damages, Loss, or Injury, any legal suit, proceeding or
legal action whatsoever that may be caused at any time by me or any other
staff of___________________________
company, for the work undertaken and all such damage, damages, injury or
loss, legal suit, legal action, I shall be solely responsible in individual as well
as official capacity and such loss, damages, injury shall be made good and/
or as the case may be shall be paid immediately by me / Company to the
satisfaction of the MCGM.

Dated day_____________ of , 20____

Identified by me,
Prioperitor/Partners/Directors/POA holder
(Seal of Firm/Co.)

Advocate

Before me

186
 Annexure- D

Rate Analysis
Item Description

Sr. Description of rate analysis Unit Quantity Rate Amount

No. parameter
1 Basic Material (Rate should be
inclusive of all taxes)

2 Machinery Hire Charges

3 Labour Type (labour

components

4 Total of all components

5 Overhead &Profit 15% on 4

6 Total Rate (4+5)

7 Per unit rate

Sign & Seal of the Tenderer

187
BANKERS GURANTEE IN LIEU OF TENDER & CONTRACT DEPOSIT FOR
WORK
THIS INDENTURE made this ______________day of __________ BETWEEN
THE ___________________BANK incorporated under the English/Indian
Companies Acts and carrying on business in Mumbai (hereinafter referred to
as 'the bank' which expression shall be deemed to include its successors
and assigns)of the first part __________________________________________
_________________________________ inhabitants carrying on business at
_______________________________ in Mumbai under the style and name of
Messer’s __________________(hereinafter referred to as 'the contractors') of the
second part Shri. _______________________________________
THE MUNICIPAL COMMISSIONER FOR GREATER MUMBAI
(hereinafter referred to as 'the commissioner' which expression shall be
deemed, also to include his successor or successors for the time being in the
said office of Municipal Commissioner ) of the third part and THE
MUNICIPAL CORPORATION OF GREATER MUMBAI (hereinafter referred to
as 'the Corporation') of the fourth part WHEREAS the contractors have
submitted to the Commissioner tender for the execution of the work of
''_________________________________________________________and the terms of
such tender /contract require that the contractors shall deposit with the
Commissioner as earnest money and /or the security a sum of
Rs.______________(Rupees __________________)AND WHEREAS if and when
any such tender is accepted by the Commissioner, the contract to be
entered into in furtherance thereof by the contractors will provide that such
deposit shall remain with and be appropriated by the Commissioner towards
the Security -deposit to be taken under the contract and be redeemable by
contractors, if they shall duly and faithfully carry out the terms and
provisions of such contract and shall duly satisfy all claims properly
chargeable against them there under AND WHEREAS the contractors are
constituents of the Bank and in order to facilitate the keeping of the
accounts of the contractors, the Bank with the consent and concurrence of
the contractors has requested the Commissioner to accept the undertaking
of the Bank hereinafter contained, in place of the contractors depositing
with the Commissioner the said sum as earnest money and /or security as
aforesaid AND WHEREAS accordingly the Commissioner has agreed to
accept such undertaking NOW THIS AGRREMENT WITHNESSES that in
188
consideration of the premises, the Bank at the request of the contractors (
hereby testified ) UNDERTAKES WITH the commissioner to pay to the
commissioner upon demand in writing , whenever required by him , from
time to time , so to do ,a sum not
exceeding in the whole Rs._________(Rupees___________________)under the
terms of the said tender and /or the contract .The B.G. Is valid upto
_________”Notwithstanding anything what has been stated above, our
liability under the above guarantee is restricted to Rs.___________only and
guarantee shall remain in force upto ____________ unless the demand or
claim under this guarantee is made on us in writing on or before
__________all your right under the above guarantee shall be forfeited and we
shall be released from all liabilities under the guarantee thereafter”

IN WITNESS WHEREOF
WITNESS(1)_________________
Name and _________________
address _________________

WITNESS(2)__________________
Name and __________________ the duly constituted Attorney Manager
address _____________________

the Bank and the said Messer’s ___________________________________

_______________________________________ (Name of the Bank)
WITNESS(1)_________________
Name and _________________
address _________________

WITNESS(2)_________________
Name and ___________________ For Messer’s ____________________
address ____________________
have here into set their respective hands the day and year first above
written.
The amount shall be inserted by the Guarantor, representing the Contract
Deposit in Indian Rupees.

189
 PROFORMAS

PROFORMA – I
The list of similar works as stated in Para ‘A’of Post qualification
during last seven years–
PROFORMA – I
Date of Stipulated/ Actual cost of work done in Rs. (year-wise)
Name Name of starting
Sr. Actual
of the the of work
No Date of
Project Employer 08- 09- 10- 11- 12- 13- 14- Total
Completion 09 10 11 12 13 14 15
1
2
3

NOTE:
1. Scanned Attested copies of completion/performance certificates
from the Engineer-in-Charge for each work should be annexed in
the support of information furnished in the above proforma.

2. Works shall be grouped financial year-wise.

PROFORMA – II

Yearly turnover of Civil Engineering Construction Works during the

last five years.

PROFORMA – II

Sr. Financial Annual Turnover of Updated value Maximum of Page

No. Year Civil Engineering Works to current year last 5 years No.
1
2
3
Total

NOTE: The above figures shall tally with the audited balance sheets
uploaded by the tenderers duly certified by Chartered Accountant.

190
 PROFORMA- III
At least similar work, as stated in para ‘A’ of Post qualification,

PROFORMAIII
Name of Name Cost of Date of Stipulat Actual Actua Remarks
the Project of the the is-sue of ed Date Date of l cost explaini
Em- Pro-ject work of Compl of ng
ployer Order Comple- e-tion work reasons
tion done for
delay, if
any
1 2 3 4 5 6 7 8

Note: Scanned Attested copies of completion/performance certificates from

the En- gineer-in-charge for each work should be annexed in support of
information furnished in the above proforma.

PROFORMA – IV (PERSONNEL)

PROFORMA – IV
Name Work Experience
Sr.
Post (Prime Candidate/ Qualification No. of Name of
No.
Alternate) Years Projects
1
2
3
4

NOTE: Scanned Attested copies of qualification certificates and details of

work experience shall be submitted/uploaded.

PROFORMA V/A (MACHINERY)

PROFORMA V / A
Sr. Owned / Leased /
Equipment No. Documents at Page
No. Assured Access
1 2 3 4 5

191
 PROFORMA V/B
PROFORMA V / B
Sr.
Equipment No Owned Documents at Page
No.
1 2 3 4 5

Note: The tenderer(s) shall furnish/upload the requisite Scanned Attested

documents of ownership/leased of machineries. The undertaking from
the suppliers will not be accepted.
PROFORMA - VI/A
Details of Existing Commitments and on-going works –

PROFORMA VI/A
Value of
Name &
Contract Value of Scheduled work Anticipated
Description Addresses
Place No. & Contract date of remaining date of
of work of
Date in Rs. completion to be completion
employer
completed
1 2 3 4 5 6 7 8

Note: Scanned Attested copies of completion/performance certificates from

the Engineer-in-Charge for each work should be annexed in the
support of information furnished in the above proforma.

PROFORMA - VI/B

Details of works for which bids are already uploaded –

PROFORMA VI/B
Date on
Name & Value of
Description Time which
Place Addresses of Contract in Remarks
of work Period decision is
employer Rs.
expected
1 2 3 4 5 6 7

Note: Scanned Attested copies of certificates from the Engineer-in-charge

for each work shall be annexed.

192
Scanned by CamScanner
Scanned by CamScanner
Scanned by CamScanner
Scanned by CamScanner