Construction Management and Economics (OctoberDecember 2006) 24, 10071018

Record keeping for contemporaneous delay analysis: a

model for effective event management
STUART CARMICHAEL1* and MARIA MURRAY2
1

School of Construction and Property Management, University of Salford, Bridgewater Building, Salford, Greater
Manchester, M7 9NU, UK
2
Department of Built Environment, University of Central Lancashire, Harris Building, Preston, Lancashire. PR1 2HE,
UK
Received 10 September 2004; accepted 2 November 2005

Increasingly sophisticated computer software is being utilized to support detailed critical path method (CPM)
analysis for resolving delay and disruption claims. The accurate determination of entitlement is however still
dependent on the quality of programme and progress information provided by all parties. A comparative
analysis of record-keeping methods in the UK and the US reveals that there is less rigour to this practice in the
UK, where parties are not required by the contract to provide such records. In most forms of US government
construction contract the contractor is required to produce a schedule using CPM software and to regularly
update this to reflect project progress and changes. Recent recommended best practice in the UK also stipulates
that the contractor should keep reliable and accurate progress and programme records to assist
contemporaneous assessment of the cause and effect of project changes. While not contractually imperative,
a clear method of managing information is important in UK construction and engineering projects to facilitate
more effective and accurate assessments of delay and disruption. The US experience and good practice
approaches in the UK demonstrate the importance of implementing and establishing an event management
strategy and archive at the outset of projects.
Keywords: Delay analysis, records, change event, event archive, programme, claims

Introduction
No matter what project controls are put in place,
unfortunately delay and disruption especially on large
or complex projects are almost inevitable. As
McCullough (1989) states, The basis of most construction claims is a delay. Delay is the situation where
the works take longer than originally intended. Delays
can be approval delays, information delays or work
undertaken later than originally planned. (Williams
et al., 2003). The variable which is affected by the event
is time-related. Disruption by contrast does not refer to
the timing of the works but to the situation where the
works are made more difficult by some act of hindrance
or prevention by the employer.

*Author for correspondence. E-mail: [email protected]

Delays might be due to changes in the initial design,

alterations to the specification and unforeseen circumstances such as unexpected ground conditions, poor
weather or poor design which is only discovered during
construction. Other delays are frequently caused by
supply chain problems, for example suppliers not delivering components to site on time, or specialist manufacturers having problems with their off-site production
processes. Delays and disruption can also be caused by
people issues, for example individuals or organizations not
responding to requested information within an appropriate time or individuals not agreeing on technical or
management issues for an unreasonable period of time.
Change management principles have been developed
to help manage delay as it happens and in so doing
reduce the likelihood of disagreements regarding
culpability for such delays and disruption. However,
many projects still end up in disputes regarding

Construction Management and Economics

ISSN 0144-6193 print/ISSN 1466-433X online # 2006 Taylor & Francis
http://www.tandf.co.uk/journals
DOI: 10.1080/01446190500521207

1008
extension of time (EOT) claims and/or prolongation
claims after the project has finished (when relationships
can start to break down). This situation is unlikely to
change in the future. In paragraph 9.4 of the Latham
Report, Latham states that disputes may arise despite
everyones best efforts to avoid them. Carnell (2000:
89) adds: It is a mistake to believe that the post
Latham and Egan construction industries will be free
from claims.
Carnell (2000: 107) also states that disputes will arise
not least because there will be instances where a genuine
difference occurs, where the parties hold sincere but
diametrically opposed opinions: One should not demonize construction disputes. The key is to understand the
place in which disputes and the available mechanisms for
their resolution occupy in the construction process.
Williams (2003) states that most good contractors will
try to avoid getting into claims situations where possible.
Zack (1993) however suggests that claimsmanship
often reduces transparency in the claims process and lists
11 claim games commonly played out by contractors
on public projects.
The use of delay analysis is currently increasingly
popular with the courts in identifying culpability and
ascertaining damages. The increasing use of computers
in recent years has enabled critical path programmes to
be analysed and, using a range of assessment methods,
highly complex projects can in theory be analysed for
delays and disruption and very specific answers
regarding the impact of delay events on the programme
are often provided to the courts.
The problem is that delay claims involve detailed
investigation of the project, often retrospectively,
which requires a vast number of documents to be
reviewed and people to be interviewed, which can be
a time-consuming and resource-hungry process.
Alkass et al. (1995) discuss the effort involved in this
and say that 70 per cent of the effort in a claim is
spent on searching and organizing information.
Effective delay analysis must consider all delaying
events and is dependent on the facts of the case.
Facts in this sense mean the projects factual records,
i.e. variations, correspondence, minutes of meetings,
progress reports and so on. If this process is not
managed effectively, claims can be at best very timeconsuming to assess in terms of validity and at worst
deceivingly inaccurate.
Gibson (2003) states:
Too often do we see extension of time and delay claims
submissions containing several lever arch files of these facts
with no specific linkage to the alleged events that caused the
delay. There may also be a bundle of computer printouts
indicating the claimed effects but the causal link is not clearly
defined. The referee is expected to find it and often its like
looking for a needle in a haystack!

Carmichael and Murray

The records kept on construction projects will be the
main source of information on which claims for time or
additional payments will be established by the contractor or assessed by the engineer or contract administrator. The importance of producing adequate delay
documentation has been recognized for many years
(Epling, 1984), and Jergeas and Hartman (1994)
stipulate that good record-keeping is crucial in helping
to avoid or resolve claims. There is a multitude of
different types of records including correspondence,
meeting minutes, delivery notes, progress records, site
diaries, day work sheets, photographs and invoices
(Scott, 1990). Updated programmes can also record
progress. The purpose of keeping records is to enable
the assessment of progress, to confirm work has been
carried out and to record resource use and expenditure
for payment.
The quality and rigour with which records are kept
varies wildly between different organizations. Many
have different procedures for keeping records and on
many jobs quality procedures for record-keeping are
not implemented effectively. Recent studies show
that producing inadequate records is among
the principal generic causes identified as leading to
delays in substantiation/assessment of EOT claims
(Kumaraswamy and Yogeswaran, 2003). Courts and
boards of contract appeals stress the importance of
contemporaneous records in proving delay and
other claims and often the outcome of such cases
hinges on such documentation (Bramble and Callahan,
2000). However the production of information is often
of insufficient quality to enable an effective investigation into issues of delay and disruption to be undertaken in retrospect, as Major and Ranson (1980)
observe:
It is all to common, when seeking to establish what actually
happened on a project, to find that even a considerable
amount of investigation will produce only an incomplete
picture. It will often be necessary to analyse minutes of
progress meetings, valuations, diaries, and various charts
and programmes which neither individually nor collectively
enable an actual progress chart to be produced or a detailed
history of the project to be written. This is a common
and substantial area of failure in site and head office
management.

Delays and disruption are therefore common, and

although change management and delay analysis have
been introduced to try and avoid and resolve delay and
disruption claims it is suggested that they will never
disappear. The problem is that records are kept in
multiple forms inconsistently and in various locations,
and because the analysis is normally retrospective and
requires the assessment of disparate documents, it is
always difficult to clearly show causation.

1009

Record keeping for delay analysis

In recent years in the UK the importance of keeping
contemporaneous records has become more widely
understood with the development of the Delay and
Disruption Protocol (Society of Construction Law,
2002) by the UKs Society of Construction Law, which
offers guidance on change management issues associated with the assessment of project delay and
disruption.
Record keeping
There are a multitude of different types of records kept
on construction projects, which are documented with
varying degrees of rigour depending on who is
responsible for their completion, as well as being
dependent on project management effectiveness from
one project to the next. The records that are of
particular importance in the assessment of delay and
disruption are daily logs, progress reports, period
reports, job meeting minutes, programme updates
and revisions. Such documents enable the continuing
effect of problems to be communicated to all parties
involved. However if these are not related clearly to
specific delaying events they are unlikely to provide the
required clarity of evidence needed to substantiate a
claim effectively. Therefore separate and independent
reports will often be required which are specifically
aimed at documenting and substantiating a delay,
including specific schedule analysis. The SCL protocol,
which explains how parties should go about establishing a suitable project procedure to enable this, is
perhaps the most well known recent document in the
UK.
Key principles of the SCL protocol
The SCL protocol provides guidance on how to
potentially resolve matters that might lead to disputes
regarding extension of time and/or compensation for
the additional time and resources required to complete
a project. The principle objectives of the protocol
(Black and Caletka, 2002) can be defined as trying to
promote:

N
N
N
N

agreed
agreed
agreed
agreed

critical path at time of delay;

float available at time of delay;
EOT entitlement at time of delay; and
compensation at time of delay

and to prevent:

N
N
N
N

wait and see approach to determining EOT;

cost of formal dispute resolution;
cost of establishing cause-effect nexus forensically; and
disruption to operations/management

The protocol addresses the key issues of programme

preparation and updating as well as the production of
accurate progress records. These issues form the first
core principle relating to delay and compensation in
the protocol entitled Programme and Records
(Society of Construction Law, 2002: para 1). This
stipulates:
To reduce the number of disputes relating to delay, the
contractor should prepare and the Contract Administrator
(CA) should accept a properly prepared programme showing
the manner and sequence in which the contractor plans to
carry out the works. The programme should be updated to
record actual progress and any extensions of time (EOTs)
granted. If this is done, then the programme can be used as a
tool for managing change, determining EOTs and periods of
time for which compensation may be due. Contracting parties
should also reach a clear agreement on the type of records that
should be kept.

SCL recommendations: programme updates

The protocol suggests that the programme is a dynamic
document that needs to be updated according to actual
progress to enable proper monitoring of the project.
The protocol further recommends that getting an
approved programme and keeping it up to date is so
important that any disputes in relation either to
approval or to updating should be referred to adjudication or whatever dispute resolution procedure is
available in the contract. It should be added that the
updating of the programme to reflect actual progress
does not mean that there is any admission of fault by
either side for any delay. But ensuring such transparency will require a significant alteration in mindsets
(Klein, 2002).
Regarding programme information, the protocol
(Society of Construction Law, 2002: para 2.2) specifically states: As early as possible in the project, the
contractor should submit and the CA should accept a
programme (using commercially available critical path
method project planning software) showing the manner
and sequence in which the contractor plans to carry out
the works.
The SCL protocol (Society of Construction Law,
2002: para 2.2.1.5) also suggests that the programme
should be updated on a regular basis to provide good
contemporaneous evidence of what happened on the
project, in case of dispute.

SCL recommendations: progress records

The protocol makes two key points regarding records
(Society of Construction Law, 2002: para 2.2.1.2):

1010
(1) Records are required to show what work was
carried out and when; and
(2) the contractor and employer should agree what
records are to be kept.
While such an approach if implemented would
undoubtedly afford significant benefits to the employer,
it will clearly require a level of rigour that is unusual
with regard to normal project change management
practices. Indeed this recommended approach has been
criticized by some as placing too much of an administrative burden on the parties in terms of programming
and record-keeping, which will inexorably increase
construction costs (Henchie, 2002). Contractors are
under considerable pressure to minimize their profit
margins and it is sensible to assume that any additional
obligations that require extra resources and for which
there are no immediate benefits to the contractor will to
some extent be opposed. However, these potential
barriers also exist in the US, yet contractors on many
projects are very careful to provide contemporaneous
documentation and programme updates.

The US compared to the UK approach

As this paper suggests, much of the recommendations
are similar to established practice in the USA, and
while the SCL protocol provides well founded and
sensible advice, the extent to which this advice will be
adopted in practice is less clear. In the US, recommended methods for claims management including
procedures for proving progress records are more
comprehensively written into the common forms of
contract and are generally more widely accepted as a
result. While the recommendations contained in the
SCL protocol regarding programme updates and
progress record provision are sensible, its success will
depend upon the extent to which the main bodies for
the standard contracts adopt its principles. Currently
the Institution of Civil Engineers (ICE) and the Joint
Contracts Tribunal (JCT) do not include the recommendations in their standard forms.
One could argue that the principles adopted in the
protocol are not completely new. The SCLs guidelines
for evaluating time extensions during the course of a
project are analogous to the Corps of Engineers
Modification Impact Evaluation Guide which was
published as far back as July 1979. Certainly many of
the principles adopted in the protocol are akin to
accepted principles in US Construction Law (Nash,
2002). For example, under US law an updated CPM
programme must be used to prove entitlement to an
EOT, and this principle has been adopted in the
protocol. The protocol also adopts the US principle

Carmichael and Murray

that requires the employer to grant a justifiable EOT in
a timely manner.
In response to a sharp increase in litigation in the
construction industry in the early 1970s, in the United
States public works lawyers developed contractual
mechanisms to facilitate the analysis of delay and
disruption that was frequently being experienced on
projects. The aim of these mechanisms was to minimize expensive and time consuming disputes as to a
contractors entitlement to extensions of time and
additional payments for disrupted working (DaviesEvans and Harvey, 2003).
The US approach to project management would
generally seem to place a greater emphasis on the
importance of scheduling and change management
than is the norm in the UK and most other
construction markets, for that matter. For many years
undertaking construction work for the US government,
for example the United States Agency for International
Development (USAID) and the military, has required a
level of scheduling and record-keeping rigour beyond
what is widespread in the international contracting
community.
This requires considerable resources on the part of
the contractor regarding both time and money and may
be viewed by some as onerous. However, it is strictly
enforced by the government agencies with stringent
scheduling specifications and rigorous project documentation requirements. Provisions have been added to
many US construction contracts for public works that
require the contractor to provide pre-determined
scheduling documentation at specified intervals
throughout the duration of a project. The primary
purpose of these provisions is to provide the owner with
appropriate and contemporaneous documentation in
the event that a dispute involving a delay and/or
disruption claim occurs.
These requirements have filtered down to commercial entities that are following the US governments
lead, meaning that even contractors who are not
undertaking public works are aware of the required
methods. The greater level of experience regarding
formal procedures for dealing with delay and disruption
has created important legal precedents as to the proof
required for a contractor to demonstrate delay and
disruption.
Drivers for improved record keeping
The practical influence of such provisions is dependent
on the extent to which they are implemented and
enforced. In the US there would seem to be greater
clarity regarding what is expected of the contractor, and
therefore it is perhaps easier to penalize the contractor
if he fails to conform to clearly defined requirements. In

1011

Record keeping for delay analysis

Table 1

Requirements of US and Commonwealth contract forms

Requirements and/or recommendations

Baseline programme
Periodic updates (period specified)
Scheduling software specified
Resource and cost loading per activity (labour and equipment)
Progress payment tied to schedule updates
Report logic changes for each update
Time impact analysis (TIA) used for time extensions
Designate scheduler with resume (payments not processed
until acceptable person)
Activity coding
Limited activity duration

the US the consequences for non-conformance can be

harsh. For example, not only may a contractor be
denied interim progress payments if it does not provide
the specified documentation timeously; a contractor
who has failed to supply the specified documentation in
accordance with the contractual provisions may be
deemed to have failed to demonstrate an otherwise
valid entitlement to an extension of time or additional
payment. It is a different matter, however, if these
requirements are not clearly defined, as is more the case
in the UK. Table 1 illustrates this point by comparing
the contractual requirements of the Unified Facilities
Guide Specifications (UFGS) contract used on US
military contracts with the Conditions of Contract for
Construction contract form of the Federation
Internationale Des Ingenieurs-Conseils (FIDIC) and
the SCL protocol recommendations. The UFGS is a
result of collaboration between the US Army Corps of
Engineers (USACE), the Naval Facilities Engineering
Command (NAVFAC) and the Air Force Civil
Engineer Support Agency (AFCESA). The UFGS is
used whenever the US military agrees construction
contracts.
A notable point about the UFGS requirements is
that progress payments are dependent on programme
updates. The basis for payment is the actual progress
made against the percentage complete value of the
activity. If the programme is not updated, the
contractor will not receive progress payments.
Obviously this makes the efficient updating of the
programme an extremely important process and is
carefully monitored and updated by all parties to the
contract. In many cases the employer and the
contractor will employ a programming consultant to
monitor the programme on an ongoing basis.
UK and Commonwealth: common contracts
As can be seen from Table 2, the basic standard
contracts make little reference to the level of detail

UFGS

AIA

FIDIC4

SCL

3
3
3
3
3
3
3
3

3
3

3
3

3
3

3
3
3

required within a programme. The common forms of

contract that require a programme to be produced do
stipulate a variety of conditions under which the
programme should be updated. These are detailed in
Table 2.
In the new FIDIC form of contract from 1999
onwards, programme requirements have become more
rigorous, requiring the engineer to comment by notice
if the programme does not comply with the contract
within 21 days. The contractor must also submit a
revised programme whenever the previous programme
is inconsistent with actual progress. The contract sets
out the basic information to be included in the
programme which should now be resourced.
Implications for successful record keeping
Many delay claims have been unsuccessful directly
because there was a lack of accurate records produced
contemporaneously at the time of the delay. Bramble
and Callahan (2000) summarize the case of Bath Iron
Works Corp v United States (1995) in which the
contractor failed to maintain a claims management
system. It therefore was unable to effectively collect any
additional performance costs from disputed change
orders and had no way of verifying that estimates
(derived from random sample analysis) were accurate,
complete and probative of any operative issues. The
court rejected the contractors claims.
The principle of how important it is for a contractor
to keep contemporaneous records is further illustrated
in Bechtel National Inc (1990). Here the contractors
claims for delay and disruption were denied because
the contractor did not maintain project logs or diaries
and did not produce documentation that substantiates
the extent of the cumulative impact claimed.
The consistency with which claim documentation
has been produced is also of great importance. In Circle,
Inc, the Board of Contract Appeals drew an inference
that there was no differing site condition from the

1012
Table 2

Carmichael and Murray

Contractual requirements for programme updates in common contract forms

Contract requirements
Baseline programme required
Periodic updates (as contract)
Periodic updates (contractors
discretion)
Update programme when
instructed by CA if behind
programme
Update programme only
when an EOT granted
Update programme only if
there is a variation
Update programme when CA
gives notice that programme
is inconsistent with contract
or actual progress

GC/Works1 NEC ICE 6/7 MW NEC2

& 98
6DB
3
3

3
3
3

3
3
3

3
3
3

3
3
3

MTC
89

JCT
80&98

FIDIC/
Build 98

3
3
3

contractors failure to document actual site conditions

in one area in the same manner that it documented
site conditions in another area (Bramble and Callahan,
2000: 819). In Lucerne Construction Corp, the
board noted the contractors total failure to document
the delays, even in simple daily logs, was almost
inexcusable.
There is clear precedent regarding failure to adequately keep and provide such records, as is determined
in Falkland Islands v Gordon Forbes Construction, para
11, which was under the FIDIC 4 contract, in which
acting judge Sanders states:
It is argued by the Applicant that the intention of Clause 53
is to provide a disciplined way of dealing with claims for
additional payment. Such is the overall clarity of Clause 53
that it would be hard not to agree with this proposition. Subclauses 53.1 to 53.3 set out a clear and ordered way of
dealing with any claim for an additional payment: claims
have to be notified at the time they arise, contemporary
records have to be kept and regular accounts rendered. The
whole contractual system is aimed at the early resolution of
any queries at the time the claim arises, and with the strong
likelihood that plant, manpower, experts and witnesses are
still on site. It is designed to avoid prolonged disputes.

The case also addressed a very important issue and one

that in the authors experience occurs on a regular
basis: that of a party who when bringing a claim fails to
provide contemporary records but then produces
records in support of the claim at a later date.
Regarding non-compliance of Clause 53, Sanders
states the following:
It would be perverse, I believe, if a contractor who fails to
comply with the terms of the contract should then be allowed
to introduce non-contemporary records (this is to say a
document which is neither a record nor a contemporary

FIDIC 4 DB95
M&E87

document) to support a claim, particularly as this cannot be

properly investigated by the employer. The rights of the
employer to inspect the records at the time the claim arises, to
conduct his own investigation as to the veracity of the claim
with others on site, and to challenge the extent of the claim at
the time the claim arises are fundamental to the FIDIC
procedure. A contractor who fails to meet his contractual
obligations cannot put himself in a better position by so
doing, and must accept the consequential detriment as a
result if he fails to keep comprehensive contemporary records.
(Falkland Islands v Gordon Forbes Construction: para 29)

Sanders determined in his judgment that Where

there is no contemporary record to support a claim,
then the claim fails (Falkland Islands v Gordon Forbes
Construction: para 33(8)). This is pertinent to both the
failure in providing programme updates and also to the
frequent instances when claims for alleged delays are
not evidenced with other contemporary records such as
progress reports. However, while precedent exists for
some contract forms and there is a good deal of
pressure for parties to rigorously implement recordkeeping and updating procedures in US public contracts, in the UK such procedures are considerably less
enforceable due to a lack of specific contract requirements. Generally, therefore, in the UK it is left far
more to managers to implement claims or change
management systems that adopt the recommended
principles of, for example, the SCL protocol and to
add such clauses to the contract if deemed to be
required.

Discussion
As discussed, there is a significant difference between the
US and the UK regarding the rigour with which parties

Record keeping for delay analysis

document and record project progress, largely due to the
lack of contractual requirement in UK-based projects.
The principal problem is that many records are difficult to
relate to a specific delaying event and are often not related
directly to the master programme and rarely to activities
within it. Figure 1 describes a widespread approach for
dealing with change events which in the authors
experience commonly occurs on construction projects.
The model suggests that project records are frequently kept as part of a general project archive, which
might be made up of a number of different types of
record such as site diaries (SD in Figure 1), progress
records (PR), meeting minutes (MM), drawings (D),
variation orders and instructions (VO) and
other general correspondence (GC). As the project

1013
progresses (represented by the black arrow in the
diagram) these records are continually added into this
general archive incorporating tender and contract
documentation which may be critical to the resolution
of disputes arising later in the project. On many
projects this archive is fragmented and disparate and
project records exist in different offices, scattered across
the entire project organization. It is becoming more
common for some form of electronic system to be used,
especially for drawing and document management,
which makes it easier to access files (but does not
necessarily mean they are ordered, cross-referenced or
managed any more effectively).
At some point in time as the project continues, the
occurrence of some form of change event is almost

Figure 1 Common process for dealing with project change events (EV1: change event 1; MS: management system; CA:
contract administrator; BP: baseline programme; MP: master programme; M: mitigation; C: claimant; RI:
retrospective investigation; CD: claims documentation)

1014
inevitable (Ev1 in Figure 1). Once a change event has
been notified by the contractor or identified by the
employer, there are a range of different ways in which it
will be dealt with by management Normally some form
of assessment is undertaken regarding the potential for
cost increases resulting from the change, but rarely will
effects on the project programme be considered or
the programme be formally updated. Frequently the
specifics of the change event are not recorded at
the time and the project progresses until slippage in the
programme manifests itself. At this point, if the
contractor believes he has been subjected to some form
of employer delay, he will submit a request for an
extension of time using evidence based on progress
information contained in the general project archive.
Some of this information will have been submitted to
the engineer/employer and some will not have been.
The contractor administrator (the engineer in this
example) will then attempt to make an assessment of
the change event to determine if any EOT is deserved.
And this can be where the problem starts. If none of the
records in the general project archive have been directly
related to the change event, the engineer must undertake an often complex assessment to determine cause
and effect, in a relatively short period of time (time
period being determined by the contract) in order to
check the contractors claim. Frequently the limited
records available make an accurate assessment difficult,
which leaves the door open for the contractor to quite
legitimately question the engineers analysis as lacking
the conclusive evidence on which to reach an unequivocal decision.
A separate process of investigating the event retrospectively then arises, often involving additional
resources such as external consultants, and which
frequently leads to arbitration and even litigation.
Meanwhile the project continues to progress and other
change events occur with similar results, which can lead
to numerous disparate disputes on events being dealt
with at the same time. This can seriously hinder any
attempts to mitigate delays due to the team not being
able to accurately assess the impact of concurrent or
parallel delays occurring on the project. This in itself is
rarely a simple task as there are many differing
approaches to assessing concurrent delay claims
(Martin, 2002). Mitigation strategies are therefore
often limited due to their reacting to specific events in
isolation. Even if all these disputes are resolved through
mediation, the time and resource expended in obtaining agreement can be monumental. It is also interesting
to note that so often the point at which reliable
information regarding a specific change event is
collated, documented and filed properly (in what we
term here as a claims archive) is when the initial

Carmichael and Murray

process of investigating a claim by the contract
administrator at a project level is complete.
Simply put, a lack of method or procedure for
dealing with project change events before the start of
the project (whether this is contained within a claims
management system or a change management system)
will frequently result in a haphazard and disparate
method of dealing with claims for delay and disruption.
Figure 2 presents a model which describes a possible
solution to the scenario described in Figure 1. The first
difference between this and Figure 1 is that an event
management strategy is established at the front end of the
project. (Components of the event management
strategy are indicated on Figure 2 with boxes containing bold text). This can be based on an approach
similar to the UFGS, or can adopt recommendations
from the SCL protocol. The event management
strategy needs to be agreed as soon as possible after
the main contract has been awarded (or before if
possible, for example under a partnering or framework
agreement) and needs to contain an agreed method
statement which should be used to produce the initial
baseline programme. Documentation that is produced
in the general project archive should be structured
using the method statement rules (for example progress
record activities should relate to activities on the
construction programme and template forms can be
used to standardize and structure records). This will
enable better quality records to be produced throughout the project, which in turn will enable a more
efficient and accurate analysis of the cause and effect
of specific delaying events to be undertaken as and
when they occur. As Figure 2 illustrates, a delay
claim can occur at any point in the project. By
structuring general project records better and recording
change events as they occur throughout the project in
the event archive, the process of resolving a claim for
delay or disruption should be made considerably more
efficient and considerably less arduous for the contract
administrator.
A more detailed description of the components
required of an effective front-end event management
strategy is provided below. This describes the elements
that should be considered in the front-end strategy. It
is not meant to be exclusive. Principles are adopted
from best practice guidance such as the UFGS, the
SCL protocol and the PFE Change Management
Supplement (Pickavance Fenwick Elliott, 2003).
Components of the event management strategy
Baseline programme
A realistic baseline is required for any analysis that
establishes a starting point for the work and illustrates

1015

Record keeping for delay analysis

Figure 2 Proposed process for dealing with project change events (Ev1: change event 1; MS: management strategy; CA:
contract administrator; BP: baseline programme; MP: master programme; M: mitigation; GPA: general project
archive)

the contractors intent at the time. (It should be based on

realistic durations and logic as to when the contractor
intended to perform each phase of the work).
Adopt good practice in structuring the programme
This should be embodied in the contractors method
statement, a description of the activities, durations,
sequence and resources in accordance with the contractors critical path network. See SCL Protocol (Society of
Construction Law, 2002) and PFE Change Management Supplement (Pickavance Fenwick Elliott, 2003).

Periodic updates
The update period needs to be specified and it needs to
be agreed that in the event of a departure from the
master programme the contractor will provide a revised
programme. The logic changes for each update also
need to be reported.
Scheduling software specified
In order to overcome issues of incompatibility it is
prudent to agree the type of software to be used for
programming.

1016
Resource and cost loading

Carmichael and Murray

In the US progress payments are often tied to schedule

updates, which acts as a great incentive for contractors
to provide up-to-date information. However, in the UK
there are some potential barriers to this.

will directly affect the diligence with which the

programme is updated. As a result, this will determine
the accuracy of any analysis undertaken using this
updated programme. Therefore the manner with which
this progress information is structured must be
compatible with the structure of the programme itself
regarding the planned activities. (In the approach
described by Figure 2, this information will be contained in the method statement). It will for example be
far less useful to record the progress of all the concrete
floor slabs in a car park collectively as one activity (car
park floor slabs) if each floor slab is represented by a
separate activity on the programme.

Time impact analysis (TIA) used for time extensions

Penalties

If the event management system is used effectively, the

progress and programme information required for
effective time impact analysis (TIA) will be in place.
TIA is widely viewed as being the most rigorous form of
analysis but requires good quality progress records.

Determine if any penalties (such as liquidated

damages) will be incurred for non-compliance with
the front-end event management strategy and of
specific criteria contained within.
The principles contained in the front-end event
management strategy could be included as a contract
supplement or be a non-contractual agreement established by the parties. This will very much depend on
the project and the relationship between the relevant
organizations. For example, on a longer-term project
with partnering arrangements in place, an agreed
method statement might suffice. On other projects, a
more contractually binding approach may be required.
The most important aspect is to obtain as much
voluntary agreement from the parties as possible at
the projects front end. An important aspect to ensure
established is a method of capturing progress that can
be related in some form directly to the activities on the
construction programme. This will make the process of
impacting and updating the programme far more
simple and accurate than if general progress records
reporting on different level activities (which are more or
less detailed than those contained on the programme)
have to be used. Figure 2 addresses this by recommending a method statement is established prior to the
production of the baseline programme.
From this a clear method of capturing the required
information arising from a specific change event can be
established. Figure 2 shows that once this has been
implemented the occurrence of a change event can be
dealt with immediately to determine its likely impact on
the programme. The aim here is to log the change event
in an event archive which records the cause of the event
and if possible the likely effect of the event on the
programme (denoted by Update MP in Figure 2).
The employer should also record the intended mitigation of any delays occurring from the event. This will
capture the intent of project management at the time
the event occurred, which is normally very difficult to

Many programmes do not include such information as

resource and cost loading per activity (labour and
equipment). However if this is undertaken rigorously it
can provide valuable information to the mitigation
process for any disruption caused and in assessing
prolongation claims.
Progress payment tied to schedule updates

Agree time periods for updates and analysis

The frequency with which the programmes need to be
updated as a minimum (i.e. if no change events occur),
and also how quickly particular assessments and
decisions need to be made, should be agreed.
Selection of programming personnel
The role of the scheduler has even greater importance
when utilizing a change management approach and the
selection of a properly skilled individual or team is critical.
Determine how float will be handled
There is a lot of advice on how float should be handled.
Ideally this should be agreed between parties. If not, a
recommended approach (for example, the SCLs)
should be adopted.
Recording an event
As has been discussed, this is critical. The aim is to
create and agree a uniform approach to record-keeping
at the front end that enables specific information relating
to an event to be identified and entered into the event
archive for immediate use or future reference. These
event specific records need to then be accurately
interpolated into network information for impacting on
the current programme, which is often undertaken
through the use of logic-linked fragnets. Careful
consideration of activity coding should be given to
enable specific events to be identified on the programme.
Recording progress
Assuming event records are well recorded, the thoroughness with which the progress records are produced

1017

Record keeping for delay analysis

identify when undertaking retrospective analysis. While
it is sometimes difficult to predict accurately the effect
of a specific event, the process of capturing event
specific records in the event archive will enable the
engineer to determine more quickly and accurately any
entitlement for EOT or prolongation once a request has
been submitted by the contractor. Such an assessment
will be based on a greater amount of factual evidence
than is often the case and there is a far greater chance
that agreement will be made earlier in the process
rather than pursuing the claim through arbitration or
litigation because the evidence (if recorded correctly)
will be unequivocal.
Of course, there is a balance to this allocation of
resources which could be described as cost now or cost
later. The team do not want to be burdened with timeconsuming obligations to prepare countless documents
that may not be required if a claim does not arise.
However, due to the fact that many construction claims
are for EOT or prolongation costs, this is unlikely,
especially on projects of any scale or complexity. It is
further proposed that the process of populating the
event archive is more an issue to establishing a method
and ensuring all relevant parties provide the information in the agreed format rather than undertaking any
unnecessary tasks. Another important factor in establishing such a system is that the ability to undertake
accurate what if scenarios is enhanced if the team are
working with up-to-date programme and progress
information. This provides the team with far more
accurate and reliable information with which to develop
mitigation strategies and to make decisions at the time
an event occurs. Therefore such an approach facilitates
effective project management and is not simply
restricted to being a claims management system.
Generally therefore the proposed process model for
dealing with change events presented in Figure 2 differs
from the common process described by Figure 1 in that
it has the following attributes:
(1)

(2)

(3)

An event management strategy is agreed at the

project front end which contains core principles
for producing and managing project records,
including recommended practice for producing
and updating project programmes;
The information recorded in the general
project archive is compiled adhering to a
common format in accordance with the method
statement and front-end event management
strategy;
Once a change event occurs, records are
reviewed and further analysis of a specific
event is documented in the event archive,
where matters relating to cause and effect are
recorded;

(4)

(5)

Initial analysis of events regarding delay and

disruption can be undertaken more quickly due
to information in the general project archive
being more associated with the project programme and planned activities;
All information pertaining to the analysis of
delay and disruption claims is recorded in an
event archive, which assists the team in recording event-specific information for immediate or
subsequent use in determining EOT or prolongation claims.

Conclusion
It is clear that common problems associated with the
production of project records in the UK may be
expedited through implementation of the SCL protocol
recommendations for procedures to help project teams
deal with delay and disruption.
The US currently has more rigorous and onerous
procedures regarding the production and maintenance
of project records, especially on public contracts.
However, certain barriers exist that might prevent such
an approach being adopted in the UK, notably public
sector clients disinclination to implement such recordkeeping as a contractual requirement.
While in the UK parties are not obliged to produce
the same degree of rigour when documenting project
change events or when recording project progress, it is
nonetheless imperative that they carefully establish
methods and procedures for dealing with such events
at the project front end. The implementation of such a
strategy within claims management or change management systems will avoid unnecessary and costly
investigations and will mitigate, where possible, legal
disputes for client organizations.
Figure 1 describes the common process for dealing
with project change events and illustrates how conventional methods of record-keeping can make assessing
the extent of delay and disruption complicated and
time consuming. Figure 2 suggests an approach which
overcomes these problems and which contains an event
management strategy and event archive. By following
the principles required to establish and implement a
front-end event management strategy as described in
Figure 2 and by establishing and maintaining an event
archive, the cause and effect of events can be analysed
more accurately and more efficiently. Such an approach
will reduce the amount of resource expended on the
assessment of change events when determining delay
and disruption entitlement and culpability and will
enable more effective and responsive mitigation strategies to be made before the negative impacts of a change

1018
event can fully manifest themselves. It will also enable
disputing parties to agree cause and effect on unequivocal evidence at a much earlier stage, thereby reducing
the likelihood of parties having to pursue the dispute
through arbitration or litigation.

References
Alkass, S., Mazerolle, M., Tribaldos, E. and Harris, F. (1995)
Computer aided construction delay analysis and claims
preparation. Construction Management and Economics, 13,
33552.
Bechtel National Inc (1990) NASABCA no 11867, 90
BCA (Board of Contracts Appeals Decisions) para 22,
549.
Black, M. and Caletka, A. (2002) A report of the SCL
Lecture given by Michael Black, QC, and Anthony
Caletka, 10 Oct. 2002, at 2 Temple Gardens, Society of
Construction Law, Wantage, UK.
Bramble, B.C. and Callahan, M.T. (2000) Construction Delay
Claims, 3rd edn, Construction Law Library, Aspen Law &
Business, New York.
Carnell, N.J. (2000) Causation and Delay in Construction
Disputes, Blackwell Science, Oxford, pp. 8990.
Davies-Evans, J. and Harvey, D.T. (2003) Schedule
update. PMI-COS, Spring conference, New Orleans,
May.
Epling, J.A. (1984) Expediting delay payments a suggested
method. Project Management, 2(3).
Falkland Islands v Gordon Forbes Construction (Falklands)
Limited (No 2), Falklands Island Supreme Court, Sanders
Acting Judge, 14 March 2003, Determination on preliminary point of law, para 11.
Gibson, R. (2003) Analysis of project delay theoretical or
interrogation of the facts TECBAR Review, June, 3-4.
Henchie, N. (2002) Just cool it. Building Magazine, 5 July,
4647.

Carmichael and Murray

Jergeas, G.F. and Hartman, F.T. (1994) Contractors
construction-claims avoidance. Journal of Construction
Engineering and Management, 120(3), 55360.
Klein, R. (2002) A better way to sort out delays. Construction
News, 10 Jan. 2002, available at http://www.cnplus.co.uk/
constructionnews/index.asp.
Kumaraswamy, M.M. and Yogeswaran, K. (2003)
Substantiation and assessment of claims for extensions of
time. International Journal of Project Management, 21, 2738.
Lucerne Construction Corp. VACAB No. 1494, 82-2 BCA
(CCH) 16.101 (198).
McCullough, R.B. (1989) CPM schedules in construction
claims. Cost Engineering, 31(5), 1821.
Major, W.T. and Ranson, A. (1980) Building and Engineering
Claims, 1st edn, Oyez Publishing, London.
Martin, J. (2002) Concurrent delay, paper given at meeting of
Society of Construction Law, London, 5 Feb. 2002.
Nash, S. C. (2002) Delay and disruption: legal considerations, SCL, London, available at http://www.scl.org.uk.
Pickavance Fenwick Elliott (PFE) (2003) The PFE Change
Management Supplement, 1st edn (Nov. 2003), Pickavance
Consulting Limited and Fenwick Elliott Solicitors,
London, pp. 223.
Scott, S. (1990) Keeping better records. Project Management,
8(4).
Society of Construction Law (SCL) (2002) Delay and
Disruption Protocol, SCL, London.
Unified Facilities Guide Specifications (UFGS) (2005)
Network Analysis Schedule, available at http://www.ccb.org/
docs/ufgshome/UFGSToc.htm February 200.
Williams, T. (2003) Assessing extension of time delays on
major projects. International Journal of Project Management,
21, 1926.
Williams, T., Ackermann, F. and Eden, C. (2003)
Structuring a delay and disruption claim: an application
of cause-mapping and system dynamics. European Journal
of Operational Research, 148(1), 192204.
Zack, J.G. (1993) Claimsmanship: current perspective.
Journal of Construction Engineering and Management,
119(3), 4809.