Jhlasalle 014300 Quality Assurance

PROPOSED TWO-STOREY JAIME HILARIO INTEGRATED SCHOOL - LA
SALLE
DIVISION
1 - GENERAL REQUIREMENTS
SECTION 01 43 00
- Quality Assurance
May 2013
Project :
Location :
DIVISION
Proposed Two-Storey Jaime Hilario Integrated School - La Salle

Banawang, Bagac, Bataan
1
SECTION 01 43 00
1.1
GENERAL REQUIREMENTS
-
Quality Assurance
GENERAL
Notwithstanding anything herein specified or provided that may be construed to
the contrary, all materials, and equipment must conform to all laws, ordinances,
regulations and building codes now or hereafter may be in force and applicable
during the period of construction, and the Contractor shall obtain the necessary
permits and pay the required fees therefore to the proper authorities. The
Contractor shall bear any and all damages by reason of any delay in the work
arising from his failure to comply with the provisions of this clause.
1.2
EQUIPMENT
A.
B.
Quality of Equipment: In order to establish standards of quality, the Architect

and the Engineer have, in the detailed Specifications, referred to certain
equipment by name and catalog number. This procedure is not to be
construed as eliminating from competition other products of equal or better
quality by other manufacturers where fully suitable in design.
1.
The Contractor shall furnish the complete list of proposed substitutions

prior to the signing of the Contract, together with such engineering and
catalog data as the Architect and the Engineer may require.
2.
The Contractor shall abide by the Architects and the Engineers

judgments when proposed substitute items of equipment are judged to be
acceptable and shall furnish the specified item of equipment in such case.
All proposals for substitutions shall be submitted in writing by the General
Contractor and not by individual trades or material suppliers.
The
Architect and the Engineer will approve or disapprove proposed
substitutions in writing within a reasonable time. No substitute equipment
shall be used unless approved in writing.
Equipment Approval Data:

The Contractor shall furnish four copies of
complete catalog data for every manufactured item of equipment and all
components to be used in the work, including specific performance data,
Quality Assurance
01 43 00
Page 1 of 5

SALLE
DIVISION
SECTION 01 43 00
- Quality Assurance
May 2013
material description, rating, capacity, working pressure, material gauge or
thickness, brand name, catalog number and general type.
1.
This submission shall be complied by the Contractor and approved by the

Architect and the Engineer before any of the equipment is ordered.
2.
Each data sheet or catalog in the submission shall be indexed according

to specification section and paragraph for easy reference.
3.
After written approval, this submission shall become a part of the

Contract, and may not be deviated from except upon written approval of
the Architect and the Engineer.
4.
Catalog data for equipment approved does not in any case supersede the
Contract Documents. The approval of the Architect and the Engineer shall
not relieve the Contractor from responsibility for deviations from Drawings
or Specifications, unless he has in writing called their attention to such
deviations at the time of submission, nor shall it relieve him from responsibility for errors of any sort in the items submitted. The Contractor shall
check the work described by the catalog data with the Contract
Documents for deviations and errors.
5. It shall be the responsibility of the Contractor to insure that items to be

furnished fit the space available.
He shall make necessary field
measurements to ascertain space requirements, including those for
connection, and shall order such sizes and shapes of equipment that the
final installation shall suit the true intent and meaning of the Drawings and
Specifications.
6.
1.3
Where equipment requiring different arrangement of connections from

those shown is approved, it shall be the responsibility of the Contractor to
install equipment to operate properly, and in harmony with the intent of
the Drawings and Specifications, and to make all changes in the work
required by the different arrangement of connections.
MATERIALS FURNISHED BY THE CONTRACTORS

A.
Manufacturers and Dealers: Names of proposed manufacturers, material men,

and dealers who are to furnish materials, fixtures, appliances or other fittings
shall be submitted to the Architect for approval as early as possible, to afford
proper investigation and checking.
1.
No manufacturer will be approved for any material to be furnished under

this Contract unless he shall be of good reputation, shall have plant of
ample capacity and adequate quality control and shall have successfully
produced similar products.
2.
All transactions with manufacturers or subcontractors shall be through the

Contractor.
Quality Assurance
01 43 00
Page 2 of 5

SALLE
DIVISION
SECTION 01 43 00
- Quality Assurance
May 2013
B.
C.
3.
In asking for prices on materials, the Contractor shall provide

manufacturer or dealer with complete information from Specifications and
Drawings, and shall inform manufacturer or dealer of all pertinent contract
requirements.
4.
The manufacturers or dealers shall have the materials, equipment,

fixtures, and appliances or other fittings supplied by him properly coded
or identified in accordance with existing standards for same to indicate
class grade or quality.
Samples of Materials: The Contractor shall furnish for approval, with such
promptness as to cause no delay in work, samples as specified or required.
Work shall be in accordance with the approved samples.
1.
Unless otherwise specified, three samples shall be submitted, and of

adequate size to show quality, type, color, range, finish and texture of
material.
2.
Each sample shall be labeled, bearing material name and quality, the
Contractors name, date, project name and other pertinent data.
3.
Where specifications require manufacturers printed installation

directions, such directions shall accompany samples submitted for
approval.
4.
A letter of transmittal in triplicate from the Contractor requesting approval

shall accompany all sets of samples.
5.
Transportation charges to the Architects Office must be prepaid on all

samples forwarded.
6.
Materials shall not be ordered until approval is received in writing from the
Architect. All materials shall be furnished equal in every respect to
approved samples.
Trade Name And Material Substitutes

1.
Whenever item or class of materials is specified exclusively by trade

name, by manufacturers name or by catalogue reference, only such item
shall be used except as provided for in paragraph (2) hereof.
2.
No substitution shall be made for any material, article, or process required

under contract unless approved in writing by the Architect.
3.
Materials and articles installed or used without such approval shall be at

the risk of subsequent rejections.
4.
Samples of materials for use in reinforced concrete work such as steel

bars, cement, and aggregates and their certificates of origin are to be
approved by the Architect.
Quality Assurance
01 43 00
Page 3 of 5

SALLE
DIVISION
SECTION 01 43 00
- Quality Assurance
May 2013
D.
Testing Samples of Materials: the Contractor shall submit to the Architect as

many samples as may be needed for purposes of testing. Testing of all
samples shall comply with the Specifications and government standards and
shall be performed by a competent entity or testing laboratory approved by
the Architect. All costs for shipment, delivery, handling and testing of samples
are to be paid by the Contractor.
E.
Quality of Materials: Unless otherwise specified, all materials shall be new.

The quality of materials shall be of the best grade of their respective kinds for
the purpose. The work shall be performed in the best and most acceptable
manner in strict accordance with the requirements of the Drawings and
Specifications. The decision of the Architect as to quality and quantity of work
and material shall be final and precedent to the Contractors right to receive
any money hereunder.
F.
Storage and Stockpiling of Materials
G.
1.
The Contractor shall allot suitable space to subcontractors for storage of

their materials and for erection of their sheds and tool houses.
2.
All cement, lime, and other materials affected by moisture shall be stored
on platforms and protected from weather. Materials shall be so stored as
to insure the preservation of their quality and fitness for the work. Stored
materials shall be located so as to facilitate prompt inspection.
3.
Should it be necessary at any time to move materials, sheds or storage

platforms, the Contractor shall do so at his own expense.
Defective Materials: All materials not conforming to the requirements of these

Specifications shall be considered as defective. No defective materials, the
defects of which have been subsequently corrected, shall be used until
approval has been given. Upon failure on the part of the Contractor to comply
forthwith any order of the Architect made pursuant to the provisions of this
Article, the Architect shall have authority to remove and replace defective
materials and to deduct the cost of removal and replacement from any
payment due or to become due the Contractor.
1.
The apparent silence of the Specifications, Drawings, Special Provisions

and Supplementary Specifications, as to any detail or
description concerning any point shall be regarded as meaning that only
the best general practice is to prevail and that only materials and
workmanship of first class quality are to be used.
2.
Failure or neglect on the part of the Architect, or any part of his agents to
condemn or reject bad or inferior materials shall not be construed to imply
an acceptance of the materials if said bad or inferior materials are
discovered at any time prior to the final acceptance of the work by the
Owner and the release of the Contractor.
Quality Assurance
01 43 00
Page 4 of 5

SALLE
DIVISION
SECTION 01 43 00
- Quality Assurance
May 2013
1.4
MATERIALS FURNISHED BY THE OWNER:

Materials specifically indicated shall be furnished by the Owner. The fact that
the Owner is to furnish materials is conclusive evidence of its acceptability for
the purpose intended, and the Contractor may continue to use it until
otherwise directed.
If the Contractor discovers any defect in material
furnished by the Owner, he shall notify the Architect. The contractor shall be
responsible for material loss or damage after receipt of material.
1.5
ROYALTIES AND PATENTS:

The Contractor shall pay all royalties and license fees on all patented
materials and processes furnished by him. He shall defend all suits or claims
corresponding thereto for infringement of any patent rights and shall save the
Owner harmless from loss on account thereof.
1.6
MANUFACTURERS DIRECTIONS:
All manufactured articles, materials and equipment shall be applied, installed,

connected, erected, used, cleaned and conditioned, in accordance with
manufacturers printed directions, unless herein specified to the contrary.
Where reference is made to manufacturers directions, the Contractor shall
submit specified number of copies of such directions to the Architect.
End of 01 43 00.
Quality Assurance
01 43 00
Page 5 of 5

Jhlasalle 014300 Quality Assurance

Uploaded by

Copyright:

Available Formats

Jhlasalle 014300 Quality Assurance

Uploaded by

Document Information

Original Description:

Copyright

Available Formats

Share this document

Share or Embed Document

Sharing Options

Did you find this document useful?

Is this content inappropriate?

Copyright:

Available Formats

Jhlasalle 014300 Quality Assurance

Uploaded by

Copyright:

Available Formats

PROPOSED TWO-STOREY JAIME HILARIO INTEGRATED SCHOOL - LA

Proposed Two-Storey Jaime Hilario Integrated School - La Salle

Quality of Equipment: In order to establish standards of quality, the Architect

The Contractor shall furnish the complete list of proposed substitutions

The Contractor shall abide by the Architects and the Engineers

Equipment Approval Data:

PROPOSED TWO-STOREY JAIME HILARIO INTEGRATED SCHOOL - LA

This submission shall be complied by the Contractor and approved by the

Each data sheet or catalog in the submission shall be indexed according

After written approval, this submission shall become a part of the

5. It shall be the responsibility of the Contractor to insure that items to be

Where equipment requiring different arrangement of connections from

MATERIALS FURNISHED BY THE CONTRACTORS

Manufacturers and Dealers: Names of proposed manufacturers, material men,

No manufacturer will be approved for any material to be furnished under

All transactions with manufacturers or subcontractors shall be through the

PROPOSED TWO-STOREY JAIME HILARIO INTEGRATED SCHOOL - LA

In asking for prices on materials, the Contractor shall provide

The manufacturers or dealers shall have the materials, equipment,

Unless otherwise specified, three samples shall be submitted, and of

Where specifications require manufacturers printed installation

A letter of transmittal in triplicate from the Contractor requesting approval

Transportation charges to the Architects Office must be prepaid on all

Trade Name And Material Substitutes

Whenever item or class of materials is specified exclusively by trade

No substitution shall be made for any material, article, or process required

Materials and articles installed or used without such approval shall be at

Samples of materials for use in reinforced concrete work such as steel

PROPOSED TWO-STOREY JAIME HILARIO INTEGRATED SCHOOL - LA

Testing Samples of Materials: the Contractor shall submit to the Architect as

Quality of Materials: Unless otherwise specified, all materials shall be new.

Storage and Stockpiling of Materials

The Contractor shall allot suitable space to subcontractors for storage of

Should it be necessary at any time to move materials, sheds or storage

Defective Materials: All materials not conforming to the requirements of these

The apparent silence of the Specifications, Drawings, Special Provisions

PROPOSED TWO-STOREY JAIME HILARIO INTEGRATED SCHOOL - LA

MATERIALS FURNISHED BY THE OWNER:

ROYALTIES AND PATENTS:

All manufactured articles, materials and equipment shall be applied, installed,

You might also like